Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
02/24/2009 13 Fire Station No. 94 Addition Agreement with Brockway Opfer Raab Architecture
BUSINESS OF THE CITY COUNCIL YAKIMA, WASHINGTON AGENDA STATEMENT Item No. t 3 For Meeting of February 24, 2009 ITEM TITLE: Architectural Services Agreement with Brockway Opfer Raab Architecture for Fire Station No. 94 Addition. (2204 W. Wash. Blvd.) SUBMITTED BY: Fire Department — Charlie Hines, Fire Chief CONTACT PERSON/TELEPHONE: Dave Willson, Deputy Fire Chief, 575 -6165 SUMMARY EXPLANATION: The Fire Department respectfully requests City Council approval of a Resolution authorizing the City Manager to execute the attached architectural services agreement with Brockway Opfer Raab Architecture for design of the addition to Fire Station No. 94, 2204 W. Washington Blvd. The Station 94 improvement project consists of adding 1320 sq. ft. of floor space to accommodate separate sleeping quarters and a female shower/restroorn. The other living space will receive much needed updating of carpet, cabinets and paint. This project was approved for remodel in the 2009 City budget by the City Council using REET 1 monies from the Fire Capital Fund. Once executed, Brockway Opfer Raab Architecture will begin the design phase in coordination with the Fire Department Administration, Fire Fighters and sub - consultants. The Architect will carry the contract through public bid and award and construction. The attached fee proposal is for an amount not to exceed $64,000 for architectural services for the entire construction project. Resolution X Ordinance Contract X Other (Specify) Funding Source 2009 Policy Issue — station 94 re- model, Fire Capital Funds APPROVED FOR SUBMITTAL /A /p ity Manager STAFF RECOMMENDATION: Approve the attached Resolution authorizing and directing the City Manager of the City of Yakima to execute an architectural services agreement with Brockway Opfer Raab Architecture for remodel of Fire Station 94, 2204 W. Washington Blvd. BOARD /COM', °ISSION RECOMMENDATION: 40 COUNCIL ACTION: • February 18, 2009 RESOLUTION NO. R -2009- A RESOLUTION ratifying and authorizing execution of an architectural services agreement between the City of Yakima and Brockway Opfer Raab Architecture, P.L.L.C., to develop specifications for the addition of approximately 1320 square feet to Fire Station No 94, 2204 W. Washington Blvd, Yakima, Washington, and for minor alterations to Fire Station No. 94 to address functional needs and code requirements. WHEREAS, the Fire Department requires the addition of approximately 1320 square feet and certain modifications to Fire Station No. 94 to improve its functionality and to meet code requirements, and livable space for firefighters of mixed genders; and WHEREAS, the Fire Department requires professional architectural services to develop specifications for said construction and renovation activities; and WHEREAS, the Fire Department does not have the staffing levels or specialized expertise necessary to provide said architectural services; and WHEREAS, Brockway Opfer Raab Architecture, P.L.L.C., offers to provide said ip architectural services in accordance with the terms and conditions of the attached agreement; and WHEREAS, the City Council deems it to be in the best interest of the City of Yakima to authorize execution of the attached agreement with Brockway Opfer Raab Architecture, P.L.L.C., for professional architectural services, now, therefore, BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF YAKIIVIA: The City Manager is hereby directed and authorized to execute the attached and incorporated architectural services agreement between the City of Yakima and Brockway Opfer Raab Architecture, P.L.L.C., to develop specifications for the addition of approximately 1320 square feet to Fire Station No. 94, and for other alterations to Fire Station No. 94 to address functional needs and code requirements. ADOPTED BY THE CITY COUNCIL this 24 day of February, 2009. ATTEST: David Edler, Mayor City Clerk 2009 MAJOR POLICY ISSUES/ SUPPLEMENTAL BUDGET REQUESTS DEPARTMENT: Fire DIVISION: Support Services POLICY ISSUE TITLE: FIRE STATION 94 REMODEL 1. Proposal - Fire Station 94 remodel. Remodel to include separate sleeping quarters to accommodate co -ed crews and female restroom faculties. 2. a. Fiscal Impact - $600,000 b. Proposed Funding Source -REET 1 funds in Fire Capital. c. Public Impact - Allow crews to continue to occupy fire station for coverage in South West Yakima. Also allow dignitaries and military personnel to use facilities at the fire station without incident. d. Personnel Impact - Improve substandard living conditions of makeshift ID women's bathroom and living quarters separated by pieces of plywood and home made lockers. e. Required Changes in City Regulations or Policies - N/ A f. Legal Constraints, if applicable N/A g. Viable`Alternatives - None viable 3. Conclusion and/or Staff Recommendation = The staff strongly recommends this project. This project has been delayed over 20 years due to possibility of building a new fire station 94. This possibility has not been realized nor does it seem a viable alternative. Crews have been living in substandard conditions for a municipal building. The women's restroom was built in the coatroom by firefighters nearly ten years ago. The sleeping quarters for men and women are separated by sheets of plywood installed by the crews. PI -2005 1 7/21/2008 • , Arios';"-N\ EW E . - INTERDEPARTMENTAL 1RTMENTAL, MEMO TO- Robert Desgrosellier, Senior Engineer FROM: Dave Willson, Deputy Chief RE: Architect selection DATE: January 21, 2009 Robert, I have completed a quick phone interview with four architectural firms for the purpose of re- modeling our fire station 94 at 2205 West Washington Ave. The firms called were: KDF Architecture Traho Architecture Brockway/ Opfer/ Raab Architects Wardell Architecture You will find copies of the questions asked each firm. I would like to continue this process with the firm of Brockway Opfer Raab for several reasons. 1. This firm remodeled station 92, built station 93, built the training tower, and remodeled the training offices. They have a lot of experience with emergency services buildings. 2. This firm has a track record with the city of completing projects in a professional and timely manor. 3. I was involved in the station 92 project in the second half of the project. Brockway Opfer Raab showed me that they were forthright and represented the city in the utmost manor. This firm demands quality out of the construction company and also demands that the builder provide all services as promised in the contract. 4. The firm of Brockway Opfer Raab has already done preliminary drawings and projections by request of Steve Scott as part of another building project. All drawings were retained and updated by Brockway Opfer Raab concerning this project. 1110 ‘,20-ze-v • CONSU ANT` INTERVIEW EVALUATION Fir FIRM: Traho Architecture 4/52 `06 REVIEWER: Dave Willson DATE January 2009 Question Rating Weight Score Comments (l to 5) Does your firm have experience with projects in emergency services 4e s buildings ID Are you available to start work on a 1320 sq. ft. addition to a fire station pc olonbt - beginning in March Do you have experience working with the City of Yakima on City I 3 Ves CAp• -iid r,...te - construction projects Total Score Rating Range 1 -5, 5 = Excellent, 3 Average, 1 = Poor Weight Relative value of question Score Rating x Weight = Score Total Score Summation of scores for all questions CONSULTANT INTERVIEW EVALUATION FORM FIRM: Brockway Opfer Raab Architecture REVIEWER: Dave Willson DATE January 2009 Question Rating Weight Score Comments to 5) Does your firm have experience with projects, in emergency services 1 Sta, 91 d,r;►► - tower - 1 0 Sfia. 92 V a. i ri riy vices buildings sta Are you available to start work on a 1320 sq. ft. addition to a fire station 3 , � des di ro , eat drawl 5 s a\re y ro vv. Zoo't -F r beginning in March P cat szan -had Do you have experience working with the City of Yakima on City S `des rw wt.er c s construction projects Total Score Rating Range 1 -5, 5 = Excellent, 3 = Average, 1 = Poor Weight Relative value of question Score Rating x Weight = Score Total Score Summation of scores for all questions • • CONSU ANT' INTERVIEW EVALUATION ®r •`; FIRM: KID Architecture 575 - 5 `/p8 REVIEWER: Dave Willson DATE Jailuary 2009 Question Rating Weight Score Comments (lto5) Does your firm have experience with projects in emergency services buildings 1 2, Are you available to start work on a 1320 sq. ft. addition to a fire station /J beginning in March '1 3 1 2. Ye Do you have experience working with the City of Yakima on City ` Cc,. ;40 construction projects 3. Total Score 17 Rating Range 1 -5, 5 = Excellent, 3 = Average, 1 = Poor Weight Relative value of question Score Rating x Weight = Score Total Score Summation of scores for all questions CONSULTANT INTERVIEW EVALUATION FORM FIRM: Wardell Architecture 4(53 - % 93 REVIEWER: Dave Willson DATE January 2009 Question Rating Weight Score Comments (1 to 5) Does your firm have experience with projects in emergency services 2 © 5a-ma buildings Are you available to start work on a 1320 sq. ft. addition to a fire station 1 / / 2 tvq be 0.14e_ beginning in March / 3 Do you have experience working with the City of Yakima on City 1 r4 L f ' Qo t ic.e P vJ - c nve a Ce,ter. construction projects Total Score 2 Rating Range 1 -5, 5 = Excellent, 3 = Average, 1 = Poor Weight Relative value of question Score Rating x Weight = Score Total Score Summation;of scores for all questions 0 III III , 1 nt . y?„ .2 -tz�, x , III 1 t ',77.,', . BRA./ 9 ♦ AY • P FE ® R AAB s ®■ ty :!;:::,7::,,,! ! . C I T' E C T U E, P.L. L.c. January 14, 2009 Mr. David Willson, Deputy Chief Yakima Fire Department 401 North Front Street Yakima, Washington 98901 RE: Station 94 Additions and Alterations Yakima Fire Department Dear Mr. Willson, Brockway • Opfer • Raab • Architecture is pleased to submit the following fee proposal additions and alterations to Station 94 for the Yakima Fire Department. - Based on our past experience on projects of similar scope we propose a fee for basic architectural and engineering ii services of $64,000. This fee is based on a scope of work including architectural, electrical, mechanical and structural engineering services for Design through the Construction Phase as per the attached Project Budget. We would also like to request extra services for special electrical engineering, civil engineering and landscape architecture in the amount of $11,100, as per the attached Project Budget. We are very pleased to have the opportunity to continue providing professional services for Yakima Fire Department. It is very important to us to work within your budget restraints and . to propose fees that are manageable. Please review the above fee as it relates to your vision of the project and contact me with any questions or comments. , Best regards, Brockway • Opfer • Raab • Architecture, P.L.L.C. 4 . p yn • ckway Accepted by: City of Yakima By: Date: Dick Zais, City Manager 0 Attest: Date: City Clerk 0818 1320 N. 16TH AVENUE SUITE C YAKIMA, WASHINGTON 98902 (509) 454 -3299 FAX (509) 454 -3254 • • January 14, 2009 Station 94 Improvements Yakima Fire Department PROPOSED PROTECT BUDGET New Construction 1,320 $225 $297,000 Renovation 1,322 $95 $125,590 Sub Total $422,590 Construction Contingency @ 8% $33,807 Sub Total $456,397 Architectural/Engineering Fees $64,000 Electrical Engineering Extra Services $5,000 Civil Engineering Fee $5,000 • Landscape Architectural Fee $1,100 Sales Tax @ 8.2 %, $37,425 Plan Review and Permit $2,000, Misc. Expenses (Document Printing, etc.) $7,500 Sub Total $122,025 Estimated Total $578,422 Other Costs Utility Connection Fees $0 *Data/Communications Allowance $7,500 *Appliances and Furnishings Allowance $7,500 *Other $2,500 Estimated Total Other Costs $17,500 (Project Grand Total $595,922 Owner's Budget $600,000 Difference $4,078 Note: " *" Indicates Owner budgeted Items #0818 • t ocum nt B141 -1997 Part 1 Standard Form of Agreement Between Owner and Architect with Standard Form of Architect's Services TABLE OF ARTICLES ADDITIONS AND DELETIONS: The author of this document has 1.1 INITIAL INFORMATION added information needed for its completion. The author may also 1.2 RESPONSIBILITIES OF THE PARTIES have revised the text of the original AEA standard form. An Additions and 1.3 TERMS AND CONDITIONS Deletions Report that notes added information as well as revisions to " 1.4 SCOPE OF SERVICES AND OTHER SPECIAL TERMS AND CONDITIONS the standard form text is available from the author and should be 1.5 ; COMPENSATION reviewed. A vertical line in the left margin of this document indicates AGREEMENT made as of the day of in the year where the author has added necessary information and where (In words, indicate day, month and year) the author has added to or deleted from the original AIA text. BETWEEN the Architect's client identified as the Owner: ( Name, address and other information) This document has important legal consequences. Consultation with an ID Yakima Fire Department, City of Yakima attorney is encouraged with respect 401 North Front Street to its completion or modification. Yakima, WA 98901 and the Architect: (Name, address and other information) Brockway, Opfer, Raab Architecture P.L.L.C. • 1620 North 16th Avenue, Suite, C Yakima, WA 98902 Telephone Number: 509 454 -3299 Fax Number: 509 454 -3254 For the following Project: (Include detailed description of Project) Station No 94 Improvements Yakima Air Terminal Yakima, WA 98908 Provide basic architectural and engineering services for the addition of approximately 1,320 square feet to the east of the existing Fire Station No 94: Alterations to the 1,300 square foot existing living quarters of the station may also be included, as required, to address functional needs and code requirements. The basic services include electrical, mechanical, and structural engineering. The Owner and Architect agree as follows: AIA Document 6141TM —1997 Part 1. Copyright © 1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987 and 1997 by The 1111Init. American Institute of Architects. All rights reserved. WARNING: This NA Document is protected by U.S. Copyright Law and International Treaties. 1 Unauthorized reproduction or distribution of this AIA® Document, or any portion of it may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:39:54 on 02/13/2009 under Order No.1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes: (1752424671) Z ARTICLE 1.1 INITIAL INFORMATION - § 1.1.1 This Agreement is based on the following information and assumptions. (Note the disposition for the following items by inserting the requested information or a statement such as "not applicable," "unknown at time of execution" or "to be determined later by mutual agreement. ") § 1.1.2 PROJECT PARAMETERS § 1.1.2.1 The objective or use is: (Identify or describe, if appropriate, proposed use or goals.) The objective of this project is to provide space to accommodate Yakima Fire Department staff on a 24 hour a day basis. § 1.1.2.2 The physical parameters are: (Identify or describe, tf appropriate, size, location, dimensions, or other pertinent information, such as geotechnical reports about the site.) 1 The project is to provide an approximately 1,320 square foot addition to the east side of the existing Fire Station No 94. The property is currently covered with lawn. § 1.1.2.3 The Owner's Program is: (Identify documentation or state the manner in which the program will be developed.) . I The Yakima Fire Department has developed a program of needs, as well as, a conceptual floor plan for use in the design process. § 1.1.2.4 The legal parameters are: (Identify pertinent legal information, including, if appropriate, land surveys and legal descriptions and restrictions of the site.) 10 None have been provided by the City at this time. § 1.1.2.5 The financial parameters are as follows. .1 Amount of the Owner's overall budget for the Project, including the Architect's compensation, is: $600,000.00 .2 Amount of the Owner's budget for the Cost of the Work, excluding the Architect's compensation, is: $422,600.00 § 1.1.2.6 The time parameters are: (Identify, if appropriate, milestone dates, durations or fast track scheduling.) 1 Prepare the design and construction documents in order to issue a bid package within 2009 § 1.1.2.7 The proposed procurement or delivery method for the Project is: (Identify method such as competitive bid, negotiated contract, or construction management.) Competitive bid § 1.1.2.8 Other parameters are: (Identify special characteristics or needs of the Project such as energy, environmental or historic preservation requirements.) § 1.1.3 PROJECT TEAM § 1.1.3.1 The Owner's Designated Representative is: (List name, address and other information.) :: . _..... AIA Document B141 =1997 Part t. Copyright 01917, 1926, 1948, 1.951, i 1958 1961, 1963, 1966, 1967 1970, 1974, 1977, 1987 and 1997 by The II - Init. American tnstitute Architects . All rights reserved. WARNING: This-AlA Document is protected by Copyright Law and International Treaties: Unauthorized reproduction or distribution of this AIA Document, or any portion of it, may result in severe civil and criminal penalties, and will be / prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:39:54 on 02/13/2009 under Order No.1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes: (1752424671) 110 Dave Willson, Deputy Chief 401 North Front Street Yakima, WA 98901 § 1.1.3.2 The persons or entities, in addition to the Owner's Designated Representative, who are required to review the Architect's submittals to the Owner are: (List name, address and other information.) Charlie Hines, Fire Chief Yakima Fire Department 401 North Front Street Yakima, WA 98901 § 1.1.3.3 The Owner's other consultants and contractors are: (List discipline and, if known, identify them by name and address.) None identified. § 1.1.3.4 The Architect's Designated Representative is: (List name, address and other information.) Sherlyn M. Brockway , 1320 North 16 Avenue, Suite C Yakima, WA 98902 Telephone Number: 509 454 -3299 Fax Number: 509 454 -3254 sbrockway@borarch.com § 1.1.3.5 The consultants retained at the Architect's expense are: (List discipline and, if known, identify them by name and address.) Electrical Engineering: Conley Engineering, Inc. 205 North 40th Avenue Yakima, WA .98908 Structural Engineering: Womer & Associates 1819 East Springfield . Spokane, WA 99202 Mechanical Engineering: Northwest Engineering 8817 E Mission Ave. Ste. 201 Spokane Valley, WA 99212 § 1.1.4 Other important initial information is: Special Electrical Engineering, Civil Engineering, and Landscape Architecture Services are considered Extra Services. § 1.1.5 When the services under this Agreement include contract administration services, the General Conditions of the Contract for Construction shall be the edition of AIA Document A201 current as of the date of this Agreement, or as follows: AIA Document B141m - 1997 Part 1. Copyright © 1917, 1926, 1948, 1951, 1953,1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987 and 1997 by The Init.. American Institute of Architects. ° All rights reserved:- WARNING: This - Ale -Document is protected by U.S. Copyright Law and international Treaties. 3 Unauthorized reproduction or distribution of this AIA Document, or any portion of it, may result In severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:39:54 on 02/13/2009 under Order No.1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes: (1752424671) • • § 1.1.6 The information contained in this Article 1.1 may be reasonably relied upon by the Owner and Architect in determining the Architect's compensation. Both parties, however, recognize that such information may change and, in that event, the Owner and the Architect shall negotiate appropriate adjustments in schedule, compensation and Change in Services in accordance with Section 1.3.3. ARTICLE 1.2 RESPONSIBILITIES OF THE PARTIES § 1.2.1 The Owner and the Architect shall cooperate with one another to fulfill their respective obligations under this Agreement. Both parties shall endeavor to maintain good working relationships among all members of the Project team. § 1.2.2 OWNER § 1.2.2.1 Unless otherwise provided under this Agreement, the Owner shall provide full information in a timely manner regarding requirements for and limitations on the Project. The Owner shall furnish to the Architect, within 15 days after receipt of a written request, information necessary and relevant for the Architect to evaluate, give notice of or enforce lien rights. § 1:21,2 The Owner shall periodically update the budget for the Project, including that portion allocated for the Cost of the Work. The Owner shall not significantly increase or decrease the overall budget, the portion of the budget allocated for the Cost of the Work, or contingencies included in the overall budget or a portion of the budget, without the agreement of the Architect to a corresponding change in the Project scope and quality. § 1.2.2.3 The Owner's Designated Representative identified in Section 1.1.3 shall be authorized to act on the Owner's behalf with respect to the Project. The Owner or the Owner's Designated Representative shall render decisions in a timely manner pertaining to documents submitted by the Architect in order to avoid unreasonable delay in the orderly and sequential progress of the Architect's services. • § 1.2.2.4 The Owner shall furnish the services of consultants other than those designated in Section 1.1.3 or authorize the Architect to furnish them as a Change in Services when such services are requested by the Architect and are reasonably required by the scope of the Project. § 12.2.5 Unless otherwise provided in this Agreement, the Owner shall furnish tests, inspections and reports required by law or the Contract Documents, 'such as structural, mechanical, and chemical tests, tests for air and water pollution, and tests for hazardous materials. § 1.22.6 The Owner shall furnish all legal, insurance and accounting services, including auditing services, that may be reasonably necessary at any time for the Project to meet the Owner's needs and interests. § 1.2.2.7 The Owner shall provide prompt written notice to the Architect if the Owner becomes aware of any fault or defect in the Project, including any errors, omissions or inconsistencies in the Architect's Instruments of Service. § 1.2.3 ARCHITECT § 1.2.3.1 The services performed by the Architect, Architect's employees. and Architect's consultants shall be as enumerated in Article 1.4. 1.2.3.2 The Architect's services shall be performed as expeditiously as is consistent with professional skill and care and the orderly progress of the Project. The Architect shall submit for the Owner's approval a schedule for the performance of the Architect's services which initially shall be consistent with the time periods established in Section 1.1.2.6 and which shall be adjusted, if necessary, as the Project proceeds. This schedule shall include allowances for periods of time required for the Owner's review, for the performance of the Owner's consultants, and for approval of submissions by authorities having jurisdiction over the Project. Time limits established by this schedule approved by the Owner shall not, except for reasonable cause, be exceeded by the Architect or Owner. § 1.2.3.3 The Architect's Designated Representative identified in Section 1.1.3 shall be authorized to act on the Architect's behalf with respect to the Project. 4 1) AIA Document 8141TM —1997 Part 1. Copyright ©1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987 and 1997 by The Init. T American Institute of. Architects. All rights reserved. WARNING: This Ale Document Is protected by U.S. Copyright Law and International Treaties. -- - - - - -- Unauthorized reproduction or distribution of this Ale Document, or any portion of It, may result in severe civil and criminal penalties, and will be _ / prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09 :39:54 on 02/13/2009 under Order No.1000342225_1 which expires on 2/16 /2009, and is not for resale. User Notes: (1752424671) i §1.Z3.4 The Architect shall maintain the confidentiality of information specifically designated as confidential by the Owner, unless withholding such information would violate the law, create the risk of significant harm to the public or prevent the Architect from establishing a claim or defense in an adjudicatory proceeding. The Architect shall require of the Architect's consultants similar agreements to maintain the confidentiality of information specifically designated as confidential by the Owner. § 1.2.3.5 Except with the Owner's knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect's professional judgment with respect to this Project. § 1.2.3.6 The Architect shall review laws, codes, and regulations applicable to the Architect's services. The Architect shall respond in the design of the Project to requirements imposed by governmental authorities having jurisdiction over the Project. § 1.2.3.7 The Architect shall be entitled to rely on the accuracy and completeness of services and information furnished by the Owner. The Architect shall provide prompt written notice to the Owner if the Architect becomes aware of any errors, omissions or inconsistencies in such services or information.' ARTICLE 1.3' TERMS AND CONDITIONS § 1.3.1 COST OF THE WORK § 1.3.1.1 The Cost of the Work shall be the total cost or, to the extent the Project is not completed, the estimated cost to the Owner of all elements of the Project designed or specified by the Architect: § 1.3.12 The Cost of the Work shall include the cost at current market rates of labor and materials furnished by the Owner and equipment designed, specified, selected or specially provided for by the Architect, including the costs of fra management or supervision of construction or installation provided by a separate construction manager or contractor, plus a reasonable allowance for their overhead and profit. In addition, a reasonable allowance for contingencies shall be included for market conditions at the time of bidding and for changes in the Work. § 1.3.1.3 The Cost of the Work does not include the compensation of the Architect and the Architect's consultants, the costs of the land, rights -of -way and financing or other costs that are the responsibility of the Owner. § 1.32 INSTRUMENTS OF SERVICE § 1.3.2.1 Drawings, specifications and other documents, including those in electronic form, prepared by the Architect- and the Architect's consultants are Instruments of Service for use solely with respect to this Project. The Architect and the Architect's consultants shall be deemed the authors and owners of their respective Instruments of Service and shall retain all common law, statutory and other reserved rights, including copyrights. § 1.3.2.2 Upon execution of this Agreement, the Architect grants to the Owner a nonexclusive license to reproduce the Architect's Instruments of Service solely for purposes of constructing, using and maintaining the Project, provided that the Owner shall comply with all obligations, including prompt payment of all sums when due, under this Agreement. The Architect shall obtain similar nonexclusive licenses from the Architect's consultants consistent with this Agreement. Any termination of this Agreement prior to completion of the Project shall terminate this license. Upon such termination, the Owner shall refrain from making further reproductions of Instruments of Service and shall return to the Architect within seven days of termination all originals and reproductions in the Owner's possession or control. If and upon the date the Architect is adjudged in default of this Agreement, the foregoing license shall be deemed terminated and replaced by a second, nonexclusive license permitting the Owner to authorize other similarly credentialed design professionals to reproduce and, where permitted by law, to make - changes, corrections or additions to the Instruments of Service solely for purposes of completing, using and maintaining the Project. § 1.3.2.3 Except for the licenses granted in Section 1.3.2.2, no other license or right shall be deemed granted or implied under this Agreement. The Owner shall not assign, delegate, sublicense, pledge or otherwise transfer any license granted herein to another party without the prior written agreement of the Architect. However, the Owner shall be permitted to authorize the Contractor, Subcontractors, Sub- subcontractors and material or equipment suppliers to reproduce applicable portions of the Instruments of Service appropriate to and for use in their execution AIA Document B141 TM - 1997 Part 1. Copyright O 1917, 1926, 1948, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987 and 1997 by The - American' Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. - Unauthorized reproduction or distribution of this AIA Document, or any portion of It, may result in severe civil and criminal penalties, and will be 5 prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:39:54 on 02/13/2009 under Order No. 1000342225_1 which expires on 2/16/2009, and is notforresale. User Notes: (1752424671) of the Work by license granted in Section 1.3.2.2. Submission or distribution of Instruments of Service to meet official regulatory requirements or for similar purposes in connection with the Project is not to be construed as publication in derogation of the reserved rights of the Architect and the Architect's consultants. The Owner shall not use the Instruments of Service for future additions or alterations to this Project or for other projects, unless the Owner obtains the prior written agreement of the Architect and the Architect's consultants. Any unauthorized use of the Instruments of Service shall be at the Owner's sole risk and without liability to the Architect and the Architect's consultants. § 132.4 Prior to the Architect providing to the Owner any Instruments of Service in electronic form or the Owner providing to the Architect any electronic data for incorporation into the Instruments of Service, the Owner and the Architect shall by separate written agreement set forth the specific conditions governing the format of such Instruments of Service or electronic data, including any special limitations or licenses not otherwise provided in this Agreement. § 1.3.3 CHANGE IN SERVICES § 1.3.3.1 Change in Services of the Architect, including services required of the Architect's consultants, may be accomplished after execution of this Agreement, without invalidating the Agreement, if mutually agreed in writing, if required by circumstances beyond the Architect's control, or if the Architect's services are affected as described in Section 1.3.3.2. In the absence of mutual agreement in writing, the Architect shall notify the Owner prior to providing such services. If the Owner deems that all or a part of such Change in Services is not required, the Owner shall give prompt written notice to the Architect, and the Architect shall have no obligation to provide those services. Except for a change due to the fault of the Architect, Change in Services of the Architect shall entitle the Architect to an adjustment in compensation pursuant to Section 1.5.2, and to any Reimbursable Expenses described in Section 1.3.9.2 and Section 1.5.5. § 1.3.3.2 If any of the following circumstances affect the Architect's services for the Project, the Architect shall be entitled to an appropriate adjustment in the Architect's schedule and compensation: .1 change in the instructions or approvals given by the Owner that necessitate revisions in Instruments • of Service; .2 enactment or revision of codes, laws or regulations or official interpretations which necessitate changes to previously prepared Instruments of Service; .3 decisions of the Owner not rendered in a timely manner; .4 significant change in the Project including, but not limited to size, quality, complexity, the Owner's schedule or budget, or procurement method; .5 failure of performance on the part of the Owner or the Owner's consultants or contractors; .6 preparation for and attendance at a public hearing, a dispute resolution proceeding or a legal proceeding except where the Architect is party thereto; .7 change in the information contained in Article 1.1. § 1.3.4 MEDIATION 1 § 1.3.4.1 1 § 1.3.4.2 1 § 1.3.4.3 § 1.3.5 ARBITRATION 1 § 1.3.5.1 § 1.3.5.2 1 § 1.3.5.3 1 § 1.3.5.4 1 § 1.3.5.5 AIA Document 8141 TM —1997 Part 1. Copyright © 1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987 and 1997 by The • _ ,_ Init. American Institute of Architects. All rights reserved: -WARNING: This AIA® Document is protected by U.S. Copyright Law and International Treaties. • - Unauthorized reproduction or distribution of this Ale Document, or any portion of It, may result In severe civil and criminal penalties, and will be 6 prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:39.54 on 02/13/2009 under Order No.1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes: (1752424671) § 1.3.6 CLAIMS FOR CONSEQUENTIAL DAMAGES § 1.3.7 MISCELLANEOUS PROVISIONS § 1.3.7.1 This Agreement shall be governed by the law of the principal place of business of the Architect, unless otherwise provided in Section 1.4.2. § 13.71 Terms in this Agreement shall have the same meaning as those in the edition of AIA Document A201, General Conditions of the Contract for Construction, current as of the date of this Agreement. §1.33.3 Causes of action between the parties to this Agreement pertaining to acts or failures to act shall be deemed to have accrued and the applicable statutes of limitations shall commence to run not later than either the date of Substantial Completion for acts or failures to act occurring prior to Substantial Completion or the date of issuance of the final Certificate for Payment for acts or failures to act occurring after Substantial Completion. In no event shall such statutes of limitations commence to run any later than the date when the Architect's services are substantially completed. § 1.3.7.4 To the extent damages are covered by property insurance during construction, the Owner and the Architect waive all rights against each other and against the contractors, consultants, agents and employees of the other for damages, except such rights as they may have to the proceeds of such insurance as set forth in the edition of AIA Document A201, General Conditions of the Contract for Construction, current as of the date of this Agreement. The Owner or the Architect, as appropriate, shall require of the contractors, consultants, agents and employees of any of them similar waivers in favor of the other parties enumerated herein. § 1.3.7.5 Nothing contained in this Agreement shall create a contractual relationship with or a cause of action in favor of a third party against either the Owner or Architect. 410 § 1.3.7.6 Unless otherwise provided in this Agreement the Architect and Architect's consultants shall have no responsibility for the discovery, presence, handling, removal or disposal of or exposure of persons to hazardous materials or toxic substances in any form at the Project site. §1 3.7.7 The Architect shall have the right to include photographic or artistic representations of the design of the Project among the Architect's promotional and professional materials. The Architect shall be given reasonable access to the completed Project to make such representations. However, the Architect's materials shall not include the Owner's confidential or proprietary information if the Owner has previously advised the Architect in writing of the specific information considered by. the Owner to be confidential or proprietary. The Owner shall provide professional credit for the Architect in the Owner's promotional materials for the Project. § 1.3.7.8 If the Owner requests the Architect to execute certificates, the proposed language of such certificates shall be submitted to the Architect for review at least 14 days prior to the requested dates of execution. The Architect shall not be required to execute certificates that would require knowledge, services or responsibilities beyond the scope of this Agreement. § 1.3.7.9 The Owner and Architect, respectively, bind themselves, their partners, successors, assigns and legal representatives to the other party to this Agreement and to the partners, successors, assigns and legal representatives of such other party with respect to all covenants of this Agreement. Neither the Owner nor the Architect shall assign this Agreement without the written consent of the other, except that the Owner may assign this Agreement to an institutional lender providing financing for the Project. In such event, the lender shall assume the Owner's rights and obligations under this Agreement. The Architect shall execute all consents reasonably required to facilitate such assignment. § 1.3.8 TERMINATION OR SUSPENSION § 1.3.8.1 If the Owner fails to make payments to the Architect in accordance with this Agreement, such failure shall be considered substantial nonperformance and cause for termination or at the Architect's option, cause for suspension of performance of services under this Agreement. If the Architect elects to suspend services, prior to suspension of services, the Architect shall give seven days' written notice to the Owner. In the event of a suspension AIA Document B141 T " - 1997 Part 1. Copyright © 1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987 and 1997 by The _ - -- Init American institute of Architects.- All rights reserved.- WARNING: This AIA Document Is protected by U.S. Copyright Law and International Treaties. - -- - - -- Unauthorized reproduction or distribution of this Ale Document or any portion oft, may result In severe civil and criminal penalties, and will be 7 prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09 :39:54 on 02/13/2009 under Order No. 1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes: (1752424671) of services, the Architect shall have no liability to the Owner for delay or damage caused the Owner because of such • suspension of services. Before resuming services, the Architect shall be paid all sums due prior to suspension and any expenses incurred in the interruption and resumption of the Architect's services. The Architect's fees for the remaining services and the time schedules shall be equitably adjusted. 1.3.8.2 If the Project is suspended by the Owner for more than 30 consecutive days, the Architect shall be compensated for services performed prior to notice of such suspension. When the Project is resumed, the Architect shall be compensated for expenses incurred in the interruption and resumption of the Architect's services. The Architect's fees for the remaining services and the time schedules shall be equitably adjusted. § 1.3.8.3 If the Project is suspended or the Architect's services are suspended for more than 90 consecutive days, the Architect may terminate this Agreement by giving not less than seven days' written notice. § 1.3.8.4 This Agreement may be terminated by either party upon not less than seven days' written notice should the other party fail substantially to perform in accordance with the terms of this Agreement through no fault of the party initiating the termination. § 1.3.8.5 This Agreement may be terminated by the Owner upon not less than seven days' written notice to the Architect for the Owner's convenience and without cause. I § 1.3.8.6 In the event of termination not the fault of the Architect, the Architect shall be compensated for services performed prior to termination, together with Reimbursable Expenses then due 1 § 1.3.8.7 § 1.3.9 PAYMENTS TO THE ARCHITECT § 1.3.9.1 Payments on account of services rendered and for Reimbursable Expenses incurred shall be made monthly upon presentation of the Architect's statement of services. No deductions shall be made from the Architect's compensation on account of penalty, liquidated damages or other sums withheld from payments to contractors, or on • account of the cost of changes in the Work other than those for which the Architect has been adjudged to be liable. § 13.9.2 Reimbursable Expenses are in addition to compensation for the Architect's services and include expenses incurred by the Architect and Architect's employees and consultants directly related to the Project, as identified in the following Clauses: .1 transportation in connection with the Project, authorized out -of -town travel and subsistence, and electronic communications; .2 fees paid for securing approval of authorities having jurisdiction over the Project; .3 reproductions, plots, standard form documents, postage, handling and delivery of Instruments of Service; .4 expense of overtime work requiring higher than regular rates if authorized in advance by the Owner; .5 renderings, models and mock -ups requested by the Owner; .6 expense of professional liability insurance dedicated exclusively to this Project or the expense of additional insurance coverage or limits requested by the Owner in excess of that normally carried by the Architect and the Architect's consultants; .7 reimbursable expenses as designated in Section 1.5.5; .8 other similar direct Project- related expenditures. § 1.3.9.3 Records of Reimbursable Expenses, of expenses pertaining to a Change in Services, and of services performed on the basis of hourly rates or a multiple of Direct Personnel Expense shall be available to the Owner or the Owner's authorized representative at mutually convenient times. § 1.3.9.4 Direct Personnel Expense is defined as the direct salaries of the Architect's personnel engaged on the Project and the portion of the cost of their mandatory and customary contributions and benefits related thereto, such as employment taxes and other statutory employee benefits, insurance, sick leave, holidays, vacations, employee retirement plans and similar contributions. AIA Document B141 - 1997 Part 1. Copyright ©1917,1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987 and 1997 by The ill Init. American Institute of Architects. All rights reserved.' WARNING: This A!A Document is protected by U.S. Copyright Law and International Trestles: _ - Unauthorized reproduction or distribution of this Ale Document, or any portion of It, may result In severe civil and criminal penalties, and will be 8 / prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:39:54 on 02/13/2009 under Order No.1000342225_1 which expires on 2116 /2009, and is not for resale. User Notes: (1752424671) • ARTICLE 1.4 SCOPE OF SERVICES AND OTHER SPECIAL TERMS AND CONDITIONS § 1A.1 Enumeration of Parts of the Agreement. This Agreement represents the entire and integrated agreement • between the Owner and the Architect and supersedes all prior negotiations, representations or agreements, either written or oral. This Agreement may be amended only by written instrument signed by both Owner and Architect This Agreement comprises the documents listed below. § 1.4.1.1 Standard Form of Agreement Between Owner and Architect, AIA Document B 141 -1997. §1A1.2 Standard Form of Architect's Services: Design and Contract Administration, AIA Document B141 or as follows: (List other documents, if any, delineating Architect's scope of services.) § 1.4.1.3 Other documents as follows: (List other documents, if any, forming part of the Agreement.) I Exhibit A, Hourly Rates Schedule § 1.4.2 Special Terms and Conditions. Special terms and conditions that modify this Agreement are as follows: Special Electrical Engineering, Civil Engineering, and Landscape Architectural services are considered extra services (in the amount of $11,100). ARTICLE 1.5 COMPENSATION 1.5.1 For the Architect's services as described under Article 1.4, compensation shall be computed as follows: • The basic fee of $64,000 is based on the estimated construction cost of $422:600. The fee will be broken down by project phase as follows: Schematic Design Phase: Fifteen percent (15%) Design Phase: Twenty percent (20 %) Construction Documents Phase: Forty percent (40 %) Bidding or Negotiation Phase: Five percent (5 %) Construction Phase: Twenty percent (20 %) Special Electrical Engineering, Civil Engineering, and Landscape Architectural services are considered extra services (in the amount of $11,100). § 1.5.2 If the services of the Architect are changed as described in Section 1.3.3.1, the Architect's compensation shall be adjusted. Such adjustment shall be calculated as described below or, if no method of adjustment is indicated in this Section 1.5.2, in an equitable manner. (Insert basis of compensation, including rates and multiples of Direct Personnel Expense for Principals and employees, and identify Principals and classify employees, if required. Identify specific services to which particular methods of compensation apply.) Additional services shall be provided on a time and expense basis using the hourly billing rates as shown in the attached Hourly Rates Schedule, Exhibit A § 1.5.3 For a Change in Services of the Architect's consultants, compensation shall be computed as a multiple of One and one -tenth ( 1.10 ) times the amounts billed to the Architect for such services. § 1.5.4 For Reimbursable Expenses as described in Section 1.3.9.2, and any other items included in Section 1.5.5 as Reimbursable Expenses, the compensation shall be computed as a multiple of One and one- tenth ( 1.10 ) times the expenses incurred by the Architect, and the Architect's employees and consultants. AIA Document B141Tm –1 Part 1. Copyright Q 1917, 1926, 1948, 1851, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987 and 1997 by The Init. — ® ___ American institute of Architects All rights reserved: WARNING: This AIA • Document protected by U.S.- CopyrlghC6aw a I nternational Treaties.- • - - -� Unauthorized reproduction or distribution of this Ale Document, or any portion of It, may result in severe civil and criminal penalties, and will be g prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:39:54 on 02/13/2009 under Order No.1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes: (1752424671) § 1.5.5 Other Reimbursable Expenses, if any, are as follows: § 1.5.6 The rates and multiples for services of the Architect and the Architect's consultants as set forth in this Agreement shall be adjusted in accordance with their normal salary review practices. § 1.5.7 An initial payment of Zero Dollars and Zero Cents ($ 0.00 ) shall be made upon execution of this Agreement and is the minimum payment under this Agreement. It shall be credited to the Owner's account at final payment. Subsequent payments for services shall be made monthly, and where applicable, shall be in proportion to services performed on the basis set forth in this Agreement. - § 1.5.8 Payments are due and payable Thirty (30 ) days from the date of the Architect's invoice. (Insert rate of interest agreed upon.) (Usury laws and requirements under the Federal Truth in Lending Act, similar state and local consumer credit laws and other regulations at the Owner's and Architect's principal places of business,- the location of the Project and elsewhere may affect the validity of this provision. Specific legal advice should be obtained with respect to deletions or modifications, and also regarding requirements such as written disclosures or waivers.) § 1.5.9 If the services covered by this Agreement have not been completed within Twenty -four ( 24) months of the date hereof, through no fault of the Architect, extension of the Architect's services beyond that time shall be . compensated as provided in Section 1.5.2. This Agreement entered into as of the day and year first written above. ' OWNER ARCHIT T L 9 (Signature) (Si: ature) Mir I R.A. Zais, City Manager She u rencipal (Printed name and title) (Printed name and title) ` 40 Init. AIA Document B 1 4 1 - 1997 Part 1. Copyright ©1917, 1926,'1948, 1951, 1853, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987 and 1997 by The American Institute of Architects., All rights reserved WARNING:. This AIA ®Document Is protected by U.S. Copyright Law and International Treaties. - - - -- Unauthorized reproduction or distribution of this Ale Document or any portion of it, may result in severe civil and criminal penalties, and will be 10 / prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:39:54 on 02/13/2009 under Order No. 1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes: (1752424671) 0 i lls _ =� BROCKWA • OPFER • RAAB - I -IITE rI-'LTI�E Ik EXIT A HOURLY RATES SCHEDULE 2009 Principal: $120.00 Principals: Sherlyn M. Brockway Allen G. Opfer Richard A. Raab Project Architect: $100.00 Personnel assigned to project supervision / Project Managers. Architect I / Specialties Technician: $90,00 ® Personnel assigned to project with five years plus experience or assigned to a project with specific specialties in services to be rendered (licensed or unlicensed). Architect 1 / Technician I: $80.00 Personnel assigned to a project with two to five years experience, drafters (licensed or unlicensed). Architect III / Technician H: $65.00 Personnel assigned to a project with two or less years experience. Graduate from an accredited University or drafter in training to become an architect (unlicensed). Technician III: $60.00 Intern assigned to a project.. Still in School / part time employee / apprentice in training (unlicensed). Technician IV / Clerical: $50.00 Expert Witness Testimony: $250.00 Services of consultants at a multiple of 1.1 times the amounts billed to the Architect for such services. Reimbursable Expenses at a multiple of 1.1 times the actual amount expended. 0 1320 N. 16111 AVENUE SUITE C YAKIMA, WASHINGTON 98902 (509) 454 -3299 FAX (509) 454 - 3254 Additions and Deletions Report for AIA Document B 141 —1997 Part 1 This Additions and Deletions Report, as defined on page 1 of the associated document, reproduces below all text the author has added to the standard form AIA document in order to complete it, as well as any text the author may have added to or deleted from the original AIA text. Added text is shown underlined. Deleted text is indicated with a horizontal line through the original AIA text. Note: This Additions and Deletions Report is provided for information purposes only and is not incorporated into or constitute any part of the associated AIA document. This Additions and Deletions Report and its associated document were generated simultaneously by AIA software at 09:39:54 on 02/13/2009. PAGE1 Yakima Fire Department, City of Yakima 401 North Front Street Yakima, WA 98901 Brockway, Opfer, Raab Architecture P.L.L.C. 1620 North 16 Avenue, Suite C Yakima, WA 98902 Telephone Number: 509454 -3299 Fax Number: 509 454 -3254 Station No 94 Improvements • Yakima Air Terminal Yakima, WA 98908 Provide basic architectural and engineering services for the addition of approximately 1,320 square feet to the east of the existing Fire Station No. 94. Alterations to the 1,300 square foot existing living quarters of the station may also be included, as required, to address functional needs and code requirements. The basic services include electrical, mechanical, and structural engineering. PAGE 2 The obiective of this project is to provide space to accommodate Yakima Fire Department staff on a 24 hour a day basis. The project is to provide an approximately 1,320 square foot addition to the east side of the existing Fire Station No. 94. The property is currently covered with lawn. The Yakima Fire Department has developed a program of needs, as well as, a conceptual floor plan for use in the design process. None have been provided by the City at this time. Additions and Deletions Report for AIA Document B141TM —1997 Part i. Copyright © 1917, 1926, 1948,1.951; 1953, 1958, 1961, 1963, 1966, 1967, 1970, -- . 1974,`1977, 1987 and 1997 by The American Institute of Architects. All rights reserved. WARNING: This AIA® Document Is protected by U.S. Copyright Law and International Treaties: Unauthorized reproduction or distribution of this Ale . Document, or any portion of It may result In severe civil and - criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:39:54 on 02/13/2009 under Order No. 1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes: (1752424671) ,1 Amount of the Owner's overall budget for the Project, including the Architect's compensation, is: $600,000.00 .2 Amount of the Owner's budget for the Cost of the Work, excluding the Architect's compensation, is: $422,600.00 Prepare the design and construction documents in order to issue a bid package within 2009 Competitive bid PAGE3 Dave Willson, Deputy Chief 401 North Front Street Yakima, WA 98901 Charlie Hines, Fire Chief Yakima Fire Department 401 North Front Street Yakima, WA 98901 None identified. Sherlyn M. Brockway 1320 North 16 Avenue, Suite C Yakima, WA 98902 Telephone Number: 509 454 -3299 Fax Number: 509 454 -3254 sbrockway@borarch.com Electrical Engineering: Conley Engineering, Inc. 205 North 40th Avenue Yakima, WA 98908 Structural Engineering: Womer & Associates 1819 East Springfield Spokane, WA 99202 Mechanical Engineering: Additions and Deletions Report for AIA Document 8141 *b -1997 Part 1. Copyright © 1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, glir —1974, 1977, 1987 and 1997 by The American Institute of Architects: -All rights reserved. WARNING: This AIA Document Is protected by U.B. Copyright - Law and International Treaties. Unauthorized reproduction or distribution of thisAlA Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09 :39:54 on 02/13 /2009 under Order No. 1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes: (1752424671) Northwest Engineering 8817 E Mission Ave. Ste. 201 Spokane Valley, WA 99212 Special Electrical Engineering, Civil Engineering, and Landscape Architecture Services are considered Extra Services. PAGE 6 §1.3.4.3 _ . . §1.3.5.1 .. • - • • -, • Suction 1.3.1. §1.3.5.2 §1.3.5.4 _, - - __ • -- • - , ..: : : Additions and Deletions Report for AIA Document B141 1997 Part 1. Copyright © 1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, - 1974, -1977, 1987and by The American Institute of Architects. All rights reserved. - WARNING: This AIA® Document is protected by US. Copyright - - Law and International Treaties. Unauthorized reproduction or distribution of this Ale Document or any portion of It may result In severe civil and 3 criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:39:54 on 02/13/2009 under Order No.1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes: (1752424671) §1.3.5.5 - PAGE 7 PAGE 8 § 1.3.8.6 In the event of termination not the fault of the Architect, the Architect shall be compensated for services performed prior to termination, together with Reimbursable Expenses then due _ .. _ - defined in Suction 1.3.8.7. PAGE 9 Exhibit A, Hourly Rates Schedule Special Electrical Engineering, Civil Engineering, and Landscape Architectural services are considered extra services (in the amount of $11,100). The basic fee of $64,000 is based on the estimated construction cost of $422.600. The fee will be broken down by protect phase as follows: Schematic Design Phase: Fifteen percent (15 %) Design Phase: Twenty percent (20%) Construction Documents Phase: Forty percent (40%) Bidding or Negotiation Phase: Five percent (5 %) Construction "Phase: Twenty percent (20 %) Special Electrical Engineering, Civil Engineering, and Landscape Architectural services are considered extra services (in the amount of $11,100). Additional services shall be provided on a time and expense basis using the hourly billing rates as shown in the attached Hourly Rates Schedule. Exhibit A § 1.5.3 For a Change in Services of the Architect's consultants, compensation shall be computed as a multiple of One and one -tenth ( 1.10 ) times the amounts billed to the Architect for such services. § 1.5.4 - For Reimbursable Expenses as described in Section 1.3.9.2, and any other items included in Section 1.5.5 as Reimbursable Expenses, the compensation shall be computed as a multiple of One and one -tenth ( 1.10 ) times the expenses incurred by the Architect, and the Architect's employees and consultants. PAGE 10 Additions and Deletions Report for AIA Document 8141TM - 1997 Part 1. Copyright © 1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987 and 1997 by Amencan Institute of Architects. — All rights reserved. WARNING: This AIAe Document Is protected by U.S. Copyright - Law and International Treaties. Unauthorized reproduction or distribution of this Ale Document, or any portion of it, may result in severe civil and 4 criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:39:54 on 02/13/2009 under Order No. 1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes: (1752424671) § 1.5.7 An initial payment of Zero Dollars and Zero Cents ($ 0.00) shall be made upon execution of this Agreement and is the minimum payment under this Agreement. It shall be credited to the Owner's account at final payment. Subsequent payments for services shall be made monthly, and where applicable, shall be in proportion to services performed on the basis set forth in this Agreement. § 1.5.8 Payments are due and payable Thirty ( 30 ) days from the date of the Architect's invoice. #n3euuts-unpaid § 1.5.9 If the services covered by this Agreement have not been completed within Twentv -four (24) months of the date hereof, through no fault of the Architect, extension of the Architect's services beyond that time shall be compensated as provided in Section 1.5.2. R.A. Zais, City Manager Sherlyn M. Brockway, Principal • Additions and Deletions Report for AIA Document 8141 1997 Part 1. Copyright O 1917, 1926, 1948, 1951, 1953, 1958 1961, 1963, 1966, 1967, 1970; 1974 ,- 1977, 1987 and-1997 -by -The American Institute of Architects. All rights reserved. WARNING; This AIA® Document Is, protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of It may result In severe civil and . 5 criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:39:54 on 02/13/2009 under Order No.1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes: (1752424671) ill Certification of Document's Authenticity MA® Document D401 TM — 2003 I, Sherlyn Brockway, hereby certify, to the best of my knowledge, information and belief, that I created the attached final document simultaneously with its associated Additions and Deletions Report and this certification at 09 :39:54 on 02/13/2009 under Order No. 1000342225_1 from AIA Contract Documents software and that in preparing the attached final document I made no changes to the original text of AIA Document B141TM 1997 Part 1- Standard Form of Agreement Between Owner and Architect with Standard Form of Architect's Services, as published by the AIA in its software, other than those additions and deletions shown in the associated Additions and Deletions Report. (Signed) il, fitieled), ale. / (Title) (Dated) III NA Document 0401 - 2003. Copyright © 1992 and 2003 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document - - Is protected by U.S. Copyright Law and International Treaties: Unauthorized reproduction or distribution of this AIA®'Document, or any portion of it, - -1 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:39 :54 on 02/13/2009 under Order No. 1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes: (1752424671) • t1 AIA Document 141 —199' Part 2 Standard Form of Architect's Services: Design and Contract Administration • TABLE OF ARTICLES ADDITIONS AND DELETIONS: The author of this document has 2.1 PROJECT ADMINISTRATION SERVICES added information needed for its completion. The author may also 2.2 SUPPORTING SERVICES have revised the text of the original AIA standard form. An Additions and 2.3 EVALUATION AND PLANNING SERVICES Deletions Report that notes added information as well as revisions to 2.4 DESIGN SERVICES the standard form text is available from the author and should be 2.5 CONSTRUCTION PROCUREMENT SERVICES reviewed. A vertical line in the left margin of this document indicates 2.6 CONTRACT ADMINISTRATION SERVICES where the author has added necessary information and where 2.7 FACILITY OPERATION SERVICES the author has added to or deleted from the original AIA text. 2.8 SCHEDULE OF SERVICES This document has important legal • 2.9 MODIFICATIONS consequences. Consultation with an attorney is encouraged with respect to its completion or modification. ARTICLE 2.1 PROJECT ADMINISTRATION SERVICES § 2.1.1 The Architect shall manage the Architect's services and administer the Project. The Architect shall consult with the Owner, research applicable design criteria, attend Project meetings, communicate with members of the Project team and issue progress reports. The Architect shall coordinate the services provided by the Architect and the Architect's consultants with those services provided by the Owner and the Owner's consultants. § 2.1.2 When Project requirements have been sufficiently identified, the Architect shall prepare, and periodically update, a Project schedule that shall identify milestone dates for, decisions required of the Owner, design services furnished by the Architect, completion of documentation provided by the Architect, commencement of construction and Substantial Completion of the Work. § 2.1.3 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program, budget and aesthetics in developing the design for the Project. § 2.1.4 Upon request of the Owner, the Architect shall make a presentation to explain the design of the Project to representatives of the Owner. § 2;1.5 The Architect shall submit design documents to the Owner at intervals appropriate to the design process for purposes of evaluation and approval by the Owner. The Architect shall be entitled to rely on approvals received from the Owner in the further development of the design. 0 AIA Document B141 TM —1997 Part 2. Copyright © 1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966,1967, 1970, 1974, 1977, 1987 and 1997 by The Init. = A mencan' I ns Gt u te of A A ll rights reserved: WARNING: This'AIA® Document is protected by U.S. Copyright kaw and International Treaties. -- Unauthorized reproduction or distribution of this AIA Document, or any portion of It, may result in severe civil and criminal penalties, and will be - 1 / prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09 :47;08 on 02/13/2009 under Order No.1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes: (3155828330) 2.1.6 The Architect shall assist the Owner in connection with the Owner's responsibility for filing documents required for the approval of governmental authorities having jurisdiction over the Project. § 2.1.7 EVALUATION OF BUDGET AND COST OF THE WORK § 2.1.7.1 When the Project requirements have been sufficiently identified, the Architect shall prepare a preliminary estimate of the Cost of the Work. This estimate may be based on current area, volume or similar conceptual estimating techniques. As the design process progresses through the end of the preparation of the Construction Documents, the Architect shall update and refine the preliminary estimate of the Cost of the Work. The Architect shall advise the Owner of any adjustments to previous estimates of the Cost of the Work indicated by changes in Project requirements or general market conditions. If at any time the Architect's estimate of the Cost of the Work exceeds the Owner's budget, the Architect shall make appropriate recommendations to the Owner to adjust the Project's size, quality or budget, and the Owner shall cooperate with the Architect in making such adjustments. § 2.1.7.2 Evaluations of the Owner's budget for the Project, the preliminary estimate of the Cost of the Work and updated estimates of the Cost of the Work prepared by the Architect represent the Architect's judgment as a design professional familiar with the construction industry. It is recognized, however, that neither the Architect nor the Owner has control over the cost of labor, materials or equipment, over the Contractor's methods of determining bid prices, or over competitive bidding, market or negotiating conditions. Accordingly, the Architect cannot and does not warrant or represent that bids or negotiated prices will not vary from the Owner's budget for the Project or from any estimate of the Cost of the Work or evaluation prepared or agreed to by the Architect. § 2.1.7.3 In preparing estimates of the Cost of the Work, the Architect shall be permitted to include contingencies for design, bidding and price escalation; to determine what materials, equipment, component systems and types of construction are to be included in the Contract Documents; to make reasonable adjustments in the scope of the Project and to include in the Contract Documents alternate bids as may be necessary to adjust the estimated Cost of the Work to meet the Owner's budget for the Cost of the Work. If an increase in the Contract Sum occurring after execution of the Contract between the Owner and the Contractor causes the budget for the Cost of the Work to be exceeded, that budget shall be increased accordingly. • § 2.1.7.4 If bidding or negotiation has not commenced within 90 days after the Architect submits the Construction Documents to the Owner, the budget for the Cost of the Work shall be adjusted to reflect changes in the general level of prices in the construction industry. § 2.1.7.5 If the budget for the Cost of the Work is exceeded by the lowest bona fide bid or negotiated proposal, the Owner shall: .1 give written approval of an increase in the budget for the Cost of the Work; .2 authorize rebidding or renegotiating of the Project within a reasonable time .3 terminate in accordance with Section 1.3.8.5; or .4 cooperate in revising the Project scope and quality as required to reduce the Cost of the Work. § 2.1:7.6 If the Owner chooses to proceed under Section 2.1.7.5.4, the Architect, without additional compensation, shall modify the documents for which the Architect is responsible under this Agreement as necessary to comply with the budget for the Cost of the Work. The modification of such documents shall be the limit of the Architect's responsibility under this Section 2.1.7. The Architect shall be entitled to compensation in accordance with this Agreement for all services performed whether or not construction is commenced. ARTICLE 2.2 SUPPORTING SERVICES § 2.2.1 Unless specifically designated in Section 2.8.3, the services in this Article 2.2 shall be provided by the Owner or the Owner's consultants and contractors. § 2.2.1.1 The Owner shall furnish a program setting forth the Owner's objectives, schedule, constraints and criteria, including space requirements and relationships, special equipment, systems and site requirements. § 2.2.1.2 The Owner shall furnish surveys to describe physical characteristics, legal limitations and utility locations for the site of the Project, and a written legal description of the site The surveys and legal information shall include, as applicable, grades and lines of streets, alleys, pavements and adjoining property and structures;, adjacent drainage; rights -of -way, restrictions, easements, encroachments, zoning, deed restrictions, boundaries and contours of the site; AIA Document 13141 T " - 1997 Part 2. Copyright © 1917,1926, 1948,1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987 and 1997 by The Init. _ - American Institute of Architects. All rights reserved. WARNING: This Ale Document is protected by U.S. Copyright Law and International Treaties. 2 Unauthorized reproduction or distribution of this AIA® Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:47118 on 02/13/2009 under Order No.1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes:. (3155828330) locations, dimensions and necessary data with respect to existing buildings, other improvements and trees; and information concerning available utility services and lines, both public and private, above and below grade, including inverts and depths. All the information on the survey shall be referenced to a Project benchmark. § 2.2.1.3 The Owner shall furnish services of geotechnical engineers which may include but are not limited to test borings, test pits, determinations of soil bearing values, percolation tests, evaluations of hazardous materials, ground corrosion tests and resistivity tests, including necessary operations for anticipating subsoil conditions, with reports and appropriate recommendations. - ARTICLE 2.3 EVALUATION AND PLANNING SERVICES § 2.3.1 The Architect shall provide a preliminary evaluation of the information furnished by the Owner under this Agreement, including the Owner's program and schedule requirements and budget for the Cost of the Work, each in terms of the other. The Architect shall review such information to ascertain that it is consistent with the requirements of the Project and shall notify the Owner of any other information or consultant services that may be reasonably needed for the Project. § 2.3.2 The Architect shall provide a preliminary evaluation of the Owner's site for the Project based on the information provided by the Owner of site conditions, and the Owner's program, schedule and budget for the Cost of the Work. § 2.3.3 The Architect shall review the Owner's proposed method of contracting for construction services and shall notify the Owner of anticipated impacts that such method may have on the Owner's program, financial and time requirements, and the scope of the Project. ARTICLE 2.4 DESIGN SERVICES § 2.4.1 The Architect's design services shall include normal structural, mechanical and electrical engineering services. ® § 2.4.2 SCHEMATIC DESIGN DOCUMENTS § 2.4.2.1 The Architect shall provide Schematic Design Documents based on the mutually agreed -upon program, schedule, and budget for the Cost of the Work. The documents shall establish the conceptual design of the Project illustrating the scale and relationship of the Project components. The Schematic Design Documents shall include a conceptual site plan, if appropriate, and preliminary building plans, sections and elevations. At the Architect's option; the Schematic Design Documents may include study models, perspective sketches, electronic modeling or combinations of these media. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 2.4.3 DESIGN DEVELOPMENT DOCUMENTS §2A.3.1 The Architect shall provide Design Development Documents based on the approved Schematic Design Documents and updated budget for the Cost of the Work. The Design Development Documents shall illustrate and describe the refinement of the design of the Project, establishing the scope, relationships, forms, size and appearance of the Project by means of plans, sections and elevations, typical construction details, and equipment layouts. The Design Development Documents shall include specifications that identify major materials and systems and establish in general their quality levels. § 2.4.4 CONSTRUCTION DOCUMENTS _ § 2.4.4.1 The Architect shall provide Construction Documents based on the approved Design Development Documents and updated budget for the Cost of the Work. The Construction Documents shall set forth in detail the requirements for construction of the Project. The Construction Documents shall include Drawings and Specifications that establish in detail the quality levels of materials and systems required for the Project. § 2.4.4.2 During the development of the Construction Documents, the Architect shall assist the Owner in the development and preparation of: (1) bidding and procurement information which describes the time, place and conditions of bidding; bidding or proposal forms; and the form of agreement between the Owner and the Contractor; and (2) the Conditions of the Contract for Construction (General, Supplementary and other Conditions). The Architect also shall compile the Project Manual that includes the Conditions of the Contract for Construction and ® Specifications and may include bidding requirements and sample forms. AIA Document B141 TM - 1997 Part 2. Copyright ©1917,1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987 and 1997 by The Init._ _ _ ® American Institute of - Architects: - All rights reserved. WARNING: This AIA - Document Is protected by U.S. Copyright Law and. International Treaties. - - - Unauthorized reproduction or distribution of this MA Document, or any portion of It, may result In severe civil and criminal penalties, and will be 3 _ prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09 :47:08 on 02/13/2009 under Order No.1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes: (3155828330) ARTICLE 2.5 CONSTRUCTION PROCUREMENT SERVICES § 2.5.1 The Architect shall assist the Owner in obtaining either competitive bids or negotiated proposals and shall assist the Owner in awarding and preparing contracts for construction. § 2.5.2 The Architect shall assist the Owner in establishing a list of prospective bidders or contractors. § 2.5.3 The Architect shall assist the Owner in bid validation or proposal evaluation and determination of the successful bid or proposal, if any If requested by the Owner, the Architect shall notify all prospective bidders or contractors of the bid or proposal results. § 2.5.4 COMPETITIVE BIDDING § 2.5.4.1 Bidding Documents shall consist of bidding requirements, proposed contract forms, General Conditions and Supplementary Conditions, Specifications and Drawings. § 2.5.4.2 If requested by the Owner, the Architect shall arrange for procuring . the reproduction of Bidding Documents for distribution to prospective bidders. The Owner shall pay directly for the cost of reproduction or shall reimburse the Architect for such expenses. § 2.5.4.3 If Fequested by the Owner, the Architect shall distribute the Bidding Documents to prospective bidders and request their return upon completion of the bidding process. The Architect shall maintain a log of distribution and retrieval, and the amounts of deposits, if any, received from and returned to prospective bidders. § 2.5.4.4 The Architect shall consider requests for substitutions, if permitted by the Bidding Documents, and shall prepare and distribute addenda identifying approved substitutions to all prospective bidders. § 2.5.4.5 The Architect shall participate in or, at the Owner's direction, shall organize and conduct a pre -bid conference for prospective bidders. § 2.5.4.6 The Architect shall prepare responses to questions from prospective bidders and provide clarifications and interpretations of the Bidding Documents to all prospective bidders in the form of addenda. § 2.5.4.7 The Architect shall participate in or, at the •Owner's direction, shall organize and conduct the opening of the bids. The Architect shall subsequently document and distribute the bidding results, as directed by the Owner. § 2.5.5 NEGOTIATED PROPOSALS § 2.5.5.1 § 2.5.5. (Paragraphs deleted) § 2.5.5.3 § 2.5.5.4 § 2.5.5.5 ARTICLE 2.6 CONTRACT ADMINISTRATION SERVICES § 2.6.1 GENERAL ADMINISTRATION § 2.6.1.1 The Architect shall provide administration of the Contract between the Owner and the Contractor as set forth below and in the edition of AIA Document A201, General Conditions of the Contract for Construction, current as of the date of this Agreement. Modifications made to the General Conditions, when adopted as part of the Contract Documents, shall be enforceable under this Agreement only to the extent that they are consistent with this Agreement or approved in writing by the Architect. § 2.6.1.2 The Architect's responsibility to provide the Contract Administration Services under this Agreement commences with the award of the initial Contract for Construction and terminates at the issuance to the Owner of the Init. AIA Document B141 TM - 1997 Part 2. Copyright O 1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987 and 1997 by The American Institute of Architects Ail rights reserved. WARNING: This AIA® Document Is protected by U.S. Copyright Law and International •Treaties. - - -- - — Unauthorized reproduction or distribution of this AIA Document, or any portion of It, may result In severe civil and criminal penalties, and will be _ prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:47:08 on 02/13/2009 under Order No.1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes: (3155828330) • final Certificate for Payment. 'However, the Architect shall be entitled to a Change in Services in accordance with Section 2.8.2 when Contract Administration Services extend 60 days after the date of Substantial Completion of the Work. § 2.6.1.3 The Architect shall be a representative of and shall advise and consult with the Owner during the provision of the Contract Administration Services. The Architect shall have authority to act on behalf of the Owner only to the extent provided in this Agreement unless otherwise modified by written amendment. § 2.6.1.4 Duties, responsibilities and limitations of authority of the Architect under this Article 2.6 shall not be restricted, modified or extended without written agreement of the Owner and Architect with consent of the Contractor, which consent will not be unreasonably withheld. § 2.6.1.5 The Architect shall review properly prepared, timely requests by the Contractor for additional information about the Contract Documents. A properly prepared request for additional information about the Contract Documents shall be in a form prepared or approved by the Architect and shall include a detailed written statement that indicates the specific Drawings or Specifications in need of clarification and the nature of the clarification requested. § 2.6.1.6 If deemed appropriate by the Architect, the Architect shall on the Owner's behalf prepare, reproduce and distribute supplemental Drawings and Specifications in response to requests for information by the Contractor. § 2.6.1.7 The Architect shall interpret and decide matters concerning performance of the Owner and Contractor under, and requirements of, the Contract Documents on written request of either the Owner or Contractor. The Architect's response to such requests shall be made in writing within any time limits agreed upon or otherwise with reasonable promptness. §' 2.6.1.8 Interpretations and decisions of the Architect shall be consistent with the intent of and reasonably inferable from the Contract Documents and shall be in writing or in the form of drawings. When making such interpretations and initial decisions, the Architect shall endeavor to secure faithful performance by both Owner and Contractor, shall not show partiality to either, and shall not be liable for the results of interpretations or decisions so rendered in good faith. • § 2.6.1.9 The Architect shall render initial decisions on claims, disputes or other matters in question between the Owner and Contractor as provided in the Contract Documents. However, the Architect's decisions on matters relating to aesthetic effect shall be final if consistent with the intent expressed in the Contract Documents. § 2.6.2 EVALUATIONS OF THE WORK § 2.6.2.1 The Architect, as a representative of the Owner, shall visit the site at intervals appropriate to the stage of the Contractor's operations, or as otherwise agreed by the Owner and the Architect in Article 2.8, (1) to become generally familiar with and to keep the Owner informed about the progress and quality of the portion of the Work completed, (2) to endeavor to guard the Owner against defects and deficiencies in the Work, and (3) to determine in general if the Work is being performed in a manner indicating that the Work, when fully completed, will be in accordance with the Contract Documents. However, the Architect shall not be required to make exhaustive or continuous on -site inspections to check the quality or quantity of the Work. The Architect shall neither have control over or charge of, nor be responsible for, the construction means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Work, since these are solely the Contractor's rights and responsibilities under the Contract Documents. § 2.6.2.2 The Architect shall report to the Owner known deviations from the Contract Documents and from the most recent construction schedule submitted by the Contractor. However, the Architect shall not be responsible for the Contractor's failure to perform the Work in accordance with the requirements of the Contract Documents. The Architect shall be responsible for the Architect's negligent acts or omissions, but shall not have control over or charge of and shall not be responsible for acts or omissions of the Contractor, Subcontractors, or their agents or employees, or of any other persons or entities performing portions of the Work. § 2.6.2.3 The Architect shall at all times have access to the Work wherever it is in preparation or progress. - Init.-._ -. _ AIA Document 8141 TM - 1997 Part 2. Copyright ©1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963,1966, 1967,1970, 1974, 1977, 1987 and 1997 by The American Institute of Architects. " All rights reserved_ WARNING: This Document is protected by ua Copyright Law and International - Treaties. - Unauthorized reproduction or distribution of this Ale Document, or any portion of it,•may result in severe civil and criminal penalties, and will-be 5 prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09 :47:08 on 02/13/2009 under Order No.1000342225 1 which expires on 2/16/2009, and is not for resale. User Notes: (3155828330) § 2.6.2.4 Except as otherwise provided in this Agreement or when direct communications have been specially authorized, the Owner shall endeavor to communicate with the Contractor through the Architect about matters arising out of or relating to the Contract Documents. Communications by and with the Architect's consultants shall be through the Architect. § 2.6.2.5 The Architect shall have authority to reject Work that does not conform to the Contract Documents. Whenever the Architect considers it necessary or advisable, the Architect will have authority to require inspection or testing of the Work in accordance with the provisions of the Contract Documents, whether or not such Work is fabricated, installed or completed. However, neither this authority of the Architect nor a decision made in good faith either to exercise or not to exercise such authority shall give rise to a duty or responsibility of the Architect to the Contractor, Subcontractors, material and equipment suppliers, their agents or employees or other persons or entities performing portions of the Work. § 2.6.3 CERTIFICATION OF PAYMENTS TO CONTRACTOR § 2.6.3.1 The Architect shall review and certify the amounts due the Contractor and shall issue Certificates for Payment in such amounts. The Architect's certification for payment shall constitute a representation to the Owner, based on the Architect's evaluation of the Work as provided in Section 2.6.2 and on the data comprising the Contractor's Application for Payment, that the Work has progressed to the point indicated and that, to the best of the Architect's knowledge, information and belief, the quality of the Work is in accordance with the Contract Documents. The foregoing representations are subject (1) to an evaluation of the Work for conformance with the Contract Documents upon Substantial Completion, (2) to results of subsequent tests and inspections, (3) to correction of minor deviations from the Contract Documents prior to completion, and (4) to specific qualifications expressed by the Architect. § 2.6.3.2 The issuance of a Certificate for Payment shall not be a representation that the Architect has (1) made exhaustive or continuous on -site inspections to check the quality or quantity of the Work, (2) reviewed construction means, methods, techniques, sequences or procedures, (3) reviewed copies of requisitions received from Subcontractors and material suppliers and other data requested by the Owner to substantiate the Contractor's right to payment, or (4) ascertained how or for what purpose the Contractor has used money previously paid on account of the Contract Sum. § 2.6.3.3 The Architect shall maintain a record of the Contractor's Applications for Payment. § 2.6.4 SUBMITTALS § 2.6.4.1 The Architect shall review and approve or take other appropriate action upon the Contractor's submittals such as Shop Drawings, Product Data and Samples, but only for the limited purpose of checking for conformance with information given and the design concept expressed in the Contract Documents. The Architect's action shall be taken with such reasonable promptness as to cause no delay in the Work or in the activities of the Owner, Contractor or separate contractors, while allowing sufficient time in the Architect's professional judgment to permit adequate review. Review of such submittals is not conducted for the purpose of determining the accuracy and completeness of other details such as dimensions and quantities, or for substantiating instructions for installation or performance of equipment or systems, all of which remain the responsibility of the Contractor as required by the Contract Documents. The Architect's review shall not constitute approval of safety precautions or, unless otherwise specifically stated by the Architect, of any construction means, methods, techniques, sequences or procedures. The Architect's approval of a specific item shall not indicate approval of an assembly of which the item is a component. §2.6.4.2 The Architect shall maintain a record of submittals and copies of submittals supplied by the Contractor in accordance with the requirements of the Contract Documents. § 2.6.4.3 If professional design services or certifications by a design professional related to systems, materials or equipment are specifically required of the Contractor by the Contract Documents, the Architect shall specify appropriate performance and design criteria that such services must satisfy. Shop Drawings and other submittals related to the Work designed or certified by the design professional retained by the Contractor shall bear such professional's written approval when submitted to the Architect. The Architect shall be entitled to rely upon the adequacy, accuracy and completeness of the services, certifications or approvals performed by such design professionals. AIA Document 9141 -1997 Part 2. Copyright © 1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987 and 1997 by The ill init. _ _ American Institute of Architects. All rights- reserved. - WARNING: This Ale Document -Is protected by U.S. Copyright Law .and .international Trestles. _ _ _ - Unauthorized reproduction or distribution of this ANA Document, or any portion of it, may result in severe civil and criminal penalties, and will be s prosecuted to the maximum extent possible under the Jaw. This document was produced by AIA software at 09 :47:08 on 02/13/2009 under Order No.1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes: (3155828330) 2.6.5 CHANGES IN THE WORK § I § 2.6.5.1 The Architect shall prepare Change Orders and Construction Change Directives for the Owner's approval and execution in accordance with the Contract Documents. The Architect may authorize minor changes in the Work not involving an adjustment in Contract Sum or an extension of the Contract Time which are consistent with the intent of the Contract Documents. If necessary, the Architect shall prepare, reproduce and distribute Drawings and Specifications to describe Work to be added, deleted or modified, as provided in Section 2.8.2. § 2.6.5.2 The Architect shall review properly prepared, timely requests by the Owner or Contractor for changes in the Work, including adjustments to the Contract Sum or Contract Time A properly prepared request for a change in the Work shall be accompanied by sufficient supporting data and information to permit the Architect to make a reasonable determination without extensive investigation or preparation of additional drawings or specifications. If the Architect determines that requested changes in the Work are not materially different from the requirements of the Contract Documents, the Architect may issue an order for a minor change in the Work or recommend to the Owner that the requested change be denied. - § 2.6.5.3 If the Architect determines that implementation of the requested changes would result in a material change to the Contract that may cause an adjustment in the Contract Time or Contract Sum, the Architect shall make a recommendation to the Owner, who may authorize further investigation of such change. Upon such authorization, and based upon information furnished by the Contractor, if any, the Architect shall estimate the additional cost and time that might result from such change, including any additional costs attributable to a Change in Services of the Architect. With the Owner's approval, the Architect shall incorporate those estimates into a Change Order or other appropriate documentation for the Owner's execution or negotiation with the Contractor. § 2.6.5.4 The Architect shall maintain records relative to changes in the Work. § 2.6.6 PROJECT COMPLETION § 2.6.6.1 The Architect shall conduct inspections to determine the date or dates of Substantial Completion and the ® date of final completion,; shall receive from the Contractor and forward to the Owner, for the Owner's review and records, written warranties and related documents required by the Contract Documents and assembled by the Contractor, and shall issue a final Certificate for Payment based upon a final inspection indicating the Work complies with the requirements of the Contract Documents. § 2.6.6.2 The Architect's inspection shall be conducted with the Owner's Designated Representative to check conformance of the Work with the requirements of the Contract Documents and to verify the accuracy and completeness of the list submitted by the Contractor of Work to be completed or corrected. § 2.6.6.3 When the Work is found to be substantially complete, the Architect shall inform the Owner about the balance of the Contract Sum remaining to be paid the Contractor, including any amounts needed to pay for final completion or correction of the Work. § 2.6.6.4 The Architect shall receive from the Contractor and forward to the Owner: (1) consent of surety or sureties, if any, to reduction in or partial release of retainage or the making of final payment and (2) affidavits, receipts, releases and waivers of liens or bonds indemnifying the Owner against liens. ARTICLE 2.7 FACILITY OPERATION SERVICES § 2.7.1 The Architect shall meet with the Owner or the Owner's Designated Representative promptly after Substantial Completion to review the need for facility operation services. § 2.7.2 Upon request of the Owner, and prior to the expiration of one year from the date of Substantial Completion, the Architect shall conduct a meeting with the Owner and the Owner's Designated Representative to review the facility operations and performance and to make appropriate recommendations to the Owner. ARTICLE 2.8 SCHEDULE OF SERVICES § 2.8.1 Design and Contract Administration Services beyond the following limits shall be provided by the Architect as a Change in Services in accordance with Section 1.3.3: .1 up to Two ( 2 ) reviews of each Shop Drawing, Product Data item, sample and similar submittal of the Contractor. AIA Document 8141 T"' - 1997 Part 2. Copyright © 1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987 and 1997 by The Init. . — ._ Amencan - Institute of Architects: All rights reserved. WARNING: This Ale Document is protected by U.S. Copyright Law and - International - Treaties. - - - - Unauthorized reproduction or distribution of this Ale Document or any portion of it may result in severe civil and criminal penalties, and will be 7 prosecuted to the maximum extent possible under the law. This document was produced by AR software at 09 :47 :08 on 02/13/2009 under Order No.1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes: (3155828330) .2 up to Twenty -four ( 24 ) visits to the site by the Architect over the duration of the Project during construction. .3 up to Two ( 2 ) inspections for any portion of the Work to determine whether such portion of the Work is substantially complete in accordance with the requirements of the Contract Documents. .4 up to Two ( 2 ) inspections for any portion of the Work to determine final completion. § 2.8.2 The following Design and Contract Administration Services shall be provided by the Architect as a Change in Services in accordance with Section 1.3.3: .1 review of a Contractor's submittal out of sequence from the submittal schedule agreed to by the Architect; .2 responses to the Contractor's requests for information where such information is available to the Contractor from a careful study and comparison of the Contract Documents, field conditions, other Owner- provided information, Contractor- prepared coordination drawings, or prior Project correspondence or documentation; .3 Change Orders and Construction Change Directives requiring evaluation of proposals, including the preparation or revision of Instruments of Service; .4 providing consultation concerning replacement of Work resulting from fire or other cause during construction; .5 evaluation of an extensive number of claims submitted by the Owner's consultants, the Contractor or others in connection with the Work; .6 evaluation of substitutions proposed by the Owner's consultants or contractors and making subsequent revisions to Instruments of Service resulting therefrom; .7 preparation of design and documentation for alternate bid or proposal requests proposed by the Owner; or .8 Contract Administration Services provided 60 days after the date of Substantial Completion of the Work. § 2.8.3 The Architect shall furnish or provide the following services only if specifically designated:. Services - Responsibility Location of Service Description (Architect, Owner or Not Provided) .1 Programming Owner .2 Land Survey Services Owner If required .3 Geotechnical Services Owner If required .4 Space Schematics /Flow Diagrams Architect 2.4.2 .5 Existing Facilities Surveys N.P. .6 Economic Feasibility Studies N.P. .7 Site Analysis and Selection N.P. .8 Environmental Studies and Reports N.P. .9 Owner - Supplied Data Coordination N.P. .10 Schedule Development and Monitoring Architect .11 Civil Design Architect - Extra Following this table Service .12 Landscape Design Architect - Extra Following this table Service .13 Interior Design Architect .14 Special Bidding or Negotiation N.P. .15 Value Analysis N.P. .16 Detailed Cost Estimating Architect -. .17 On -Site Project Representation N.P. .18 Construction Management N.P. .19 Start -up Assistance N.P. .20 Record Drawings Architect Following this table .21 Post- Contract Evaluation N.P. AMA Document B141 TM - 1997 Part 2. Copyright O 1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977. 1987 and 1997 by The l - American institute of Architects. rights reserved. WARNING: This A!A' Document is protected by US. Copyright Law and International Treaties: - 8- Unauthorized reproduction or distribution of this AlA Document, or any portion of It may result In severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09 :47:08 on 02/13/2009 under Order No.1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes: (3155828330) 411 .22 Tenant- Related Services N.P. .23 .24 .25 Description, of Services. (Insert descriptions of the services designated.) Description of Services. 2.8.3.11 Special Electrical Engineering, Civil Engineering, and Landscape Architectural services will be provided by the Architect as an extra service. The scope of these services will be determined as the project requirements are developed. - 2.8.3.20 Record Drawings will be provided as part of the basic services in the form of marked up drawings provided by the contractor during the course of construction. The Architect will convert these mark -ups into electronic format as an extra service at their standard hourly rates. ARTICLE 2.9 MODIFICATIONS § 2.9.1 Modifications to this Standard Form of Architect's Services: Design and Contract Administration, if any are as follows: By its execution, this Standard Form of Architect's Services: Design and Contract Administration and modifications hereto are incorporated into the Standard Form of Agreement Between the Owner and Architect, AIA Document B 141 -1997, that was entered into by the parties as of the date: ® OWNER ARCHIT T (Signature) (Si: nature) glIMI R.A. Zais, City Manager Sh• .:OMI , Principal (Printed name and title) (Printed name and title) • AIA Document B141 T" - 1997 Part 2. Copyright 1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987 and 1997 by Init. _ _ -_ -American Institute of Architects All rights reserved WARNING This AIA _ Document Is protected by U.S. Copyright Law and International Treaties. ch Unauthorized reproduction or distribution of this Ale Document, or any portion of It may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:47:08 on 02/13/2009 under Order No.1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes: (3155828330) • Report for . Additions and Deletions Re p AIA Document B141 " 1997 Part 2 This Additions and Deletions Report, as defined on page 1 of the associated document, reproduces below all text the author has added to the standard form AIA document in order to complete it as well as any text the author may have added to or deleted from the original AIA text. Added text is shown underlined. Deleted text is indicated with a horizontal line through the original AIA text. Note: This Additions and Deletions Report is provided for information purposes only and is not incorporated into or constitute any part of the associated AIA document. This Additions and Deletions Report and its associated document were generated simultaneously by AIA software at 09:47:08 on 02/13/2009. PAGE 4 §2.5.5.1 • - = __ • _ 4 2.5.5. § 2.5.5.3 = . ', § 25.5.4 - _ - - -. • - §2.5.5.5 _ Owlet PAGE 7 .1 up to Two (2) reviews of each Shop Drawing, Product Data item, sample and similar submittal of the Contractor. .2 up to Twenty -four (24 ) visits to the site by the Architect over the duration of the Project during construction. 3 up to Two ( 2) inspections for any portion of the Work to determine whether such portion of the Work is substantially complete in accordance with the requirements of the Contract Documents. .4 up to Two ( 2) inspections for any portion of the Work to determine final completion. PAGE8 .1 Programming Owner .2 Land Surve Services Owner If re' uired 3 Geotechnical Services Owner If required, .4 Space Schematics /Flow Diagrams Architect 2.4.2 .5 Existing Facilities Surveys N.P. .6 Economic Feasibility Studies NP. .7 Site Analysis and Selection N.P. .8 Environmental Studies and Reports N.P. .9 Owner - Supplied Data Coordination N.P. .10 Schedule Development and Monitoring Architect Document B141 Ta -199 Part 2. Copyright 01917 1926 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970,. Additions and Deletions Report for AIA , 1974, 1977 1987 and 1997 by The American Institute Architects: rights reserved:' WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this Ale Document, or any portion of it, may result in severe civil and 1 criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:47 :08 on 02/13/2009 under Order No.1000342225_1 which expires on 2/16/2009, and is not for resale. - User Notes: (3155828330) • .11 Civil Design Architect — Extra Following this table Service .12 Landscape Design Architect — Extra Following this table Service .13 Interior Design Architect .14 Special Bidding or Negotiation N_P. .15 Value Analysis N.P. .16 Detailed Cost Estimating Architect .17 On -Site Project Representation = N.P. . .18 Construction Management N.P. .19 Start -up Assistance NJ:). .20 Record Drawings Architect Following this table .21 Post- Contract Evaluation N.P. _ .22 Tenant- Related Services N.P. PAGE 9 Description of Services. 2.83.11 Special Electrical Engineering, Civil Engineering, and Landscape Architectural services will be provided by the Architect as an extra service. The scope of these services will be determined as the project requirements are developed. - 2.8.3.20 Record Drawings will be provided as part of the basic services, in the form of marked up drawings provided by the contractor during the course of construction. The Architect will convert these mark -ups into electronic format as an extra service at their standard hourly rates. R.A. Zais, City Manager Sherlyn M. Brockway, Principal , 1110 Additions and Deletions Report for AIA Document B141 TM - 1997 Part 2. Copyright © 1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966,1967, 1970, 1974, and 1997 by The American Institute of Architects. All rights reserved. WARNING: This °AIA Document is protected by U.S. - Copyright - - — 2 Law and International Treaties .Unauthorized reproduction or distribution of this AIA Document, or any portion of It, may result In severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:47:08 on 02/13/2009 under Order No.1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes: (3155828330) Certification of Document's Authenticity Al* Document D401 TM — 2003 I, Sherlyn Brockway, hereby certify, to the best of my knowledge, information and belief, that I created the attached final document simultaneously with its. associated Additions and Deletions Report and this certification at 09 :47 :08 on 02/13/2009 under Order No 1000342225_1 from AIA Contract Documents software and that in preparing the attached final document I made no changes to the original text of MA Document B 141TM =1997 Part 2- Standard Form of Architect's Services: Design and Contract Administration, as published by the AIA in its software, other than those additions and deletions shown in the associated Additions and Deletions Report. (Signed) )cr04 l (Title) .7.2/zeic (Dated) • MA Document D401 - 2003. Copyright m - 1992 and 2003 by The American Institute of Architects. All rights reserved. WARNING: ThIs AIA Document Is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of It, - - may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:47:08 on 02/13/2009 under Order N o.1000342225_1 which expires on 2/16/2009, and is not for resale. User Notes: (3155828330)