HomeMy WebLinkAboutR-1991-D5964 R.W. Beck & Associates / Ranney Collector•
RESOLUTION NO. D 59 6 4
A RESOLUTION authorizing the City Manager and City Clerk of
the City of Yakima to execute Amendment No. 2 to
the agreement with R. W. Beck & Associates for
professional engineering services.
WHEREAS, in connection with the water well and pumphouse
replacement of the Ranney Collector, it is necessary for the
City to engage professional engineering services to provide
technical assistance during construction; and
WHEREAS, R. W. Beck & Associates has offered to perform
those professional services; and the City Council deems it to
be in the best interest of the City that Amendment No. 2 to
the agreement document be executed by the City; now, there-
fore,
BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF YAKIMA:
The City Manager and City Clerk of the City of Yakima are
hereby authorized and directed to execute "Amendment No. 2 To
Professional Services Agreement with City of Yakima Dated May
19, 1989," which Amendment is attached hereto and by reference
made a part hereof.
ADOPTED BY THE CITY COUNCIL this //d° day of?.5-e4-
1991.
ATTEST:
City Clerk
(res/beck.3v)
Mayor
WW-1405-AA1-AA June 25, 1991
AMENDMENT NO. 2
To Professional Services Agreement
with City of Yakima
Dated May 19, 1989
The Professional Services Agreement between R. W. Beck and Associates and the
City of Yakima for the Domestic Water Well Project is hereby amended as follows:
PART II—PAYMENT
Change the first sentence in the third paragraph to the following:
"On the basis of the Scope of Services outlined in this Agreement, the
estimated total amount to be paid by the Client for services furnished and
expenses reimbursed will be approximately $98,060."
Except as specifically modified herein, the Professional Services, Agreement
between R. W. Beck and Associates and the City of Yakima shall remain in full force
and effect.
Approved for Client
Approved for Consulting Engineer
By.
Richard A. Zas, Jr., City Mgr.
Date: -7//1/6, > Date.
ATTEST:
Ctty Clerk
CITY COMTaa:'1 - J� '5`ge `7�'
WVB\049
WV-1405-AA1-AA October 26, 1990
AMENDMENT NO. 1
To Professional Services Agreement
with City of Yakima
Dated May 19, 1989
The Professional Services Agreement between R. W. Beck and Associ-
ates and the City of Yakima for the Chesterly Park Well and Pump Station is
hereby amended as follows:
PROJECT: Change name to "Domestic Water Well Project"
PART I - SCOPE OF SERVICES
Change Parts I and II to the following:
I. General
The project consists of developing a domestic water well to replace
the capacity lost when the City closed its Raney wells. The work will
proceed in three phases. First, a hydrogeologic survey of selected sites
shall be performed and a report prepared for the City. Second, after a
site has been selected, specifications will be prepared and issued for
drilling the well. Third, a pump station and water main connecting the
well to the City's existing system will be designed and contract docu-
ments prepared.
II. Well Survey and Construction
1. Hydrogeologic Survey and Report
The Consultant will conduct a hydrogeologic survey of the Yakima area
to evaluate the feasibility of developing a well with a capacity be-
tween 2,000 and 3,000 gallons per minute (gpm) at one or more of sev-
eral selected sites. The Consultant will provide a report summariz-
ing hydrogeologic and engineering considerations and making recommen-
dations resulting from the study. The City will determine the pre-
ferred site for development.
2. Well Specifications
The Consultant will prepare specifications for drilling a well at the
proposed well site so that the City can advertise a contract to pros-
pective well drillers. The Consultant shall prepare and deliver a
camera-ready master of the specifications to the City for advertising
and bidding the project.
Amendment No. 1 -2- October 26, 1990
3. Services During Well Construction
The Consultant shall attend pre -construction conference, monitor the
well construction including full time (8 hours per day) on-site in-
spection during drilling of the lower section, document well con-
struction, prepare geologic log of the well, witness pump test and
geophysical logging, and make recommendations for the design of the
well and pump. Based on a water quality sample, the consultant shall
identify any treatment requirements for the well.
PART II - PAYMENT
Change the first sentence in the third paragraph to the following:
"On the basis of the Scope of Services outlined in this Agree-
ment, the estimated total amount to be paid by the Client for
services furnished and expenses reimbursed will be approximately
$84,320.
Except as specifically modified herein, the Professional Services
Agreement between R. W. Beck and Associates and the City of Yakima shall re-
main in full force and effect.
Approved for Client
By:
Date:
S /
ATTEST.
City Cterk
cm (main tifiU 90 " 8/A.
(3042E)
64 -Cat-') C v►n c
Approved for Consulting Engineer
By:
Date:
RESOLUTION NO. I) 5 " 3 8
A RESOLUTION authorizing the City Manager and City Clerk of
the City of Yakima to execute Amendment No. 1 to
the agreement with R. W. Beck & Associates for
professional engineering services.
WHEREAS, in connection with the water well and pumphouse
replacement of the Ranney Collector, it is necessary for the
City to engage professional engineering services to provide
technical assistance during construction; and
WHEREAS, R. W. Beck & Associates has offered to perform
those professional services; and the City Council deems it to
be an the b-_'st ir:rerest of the City that Amendment No. 1 to
tl,c d• lreement document be executed by the City; now, there-
fore,
BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF YAKIMA:
The City Manager and City Clerk of the City of Yakima are
hereby authorized and directed to execute "Amendment No. 1 To
Professional Services Agreement with City of Yakima Dated May
19, 199," which Amendment is attached hereto and by reference
made a part hereof.
ADOP1 D BY THE CITY COUNCIL this /3 day of
1990.
Q,GUt
Mayor
ATTEST:
City Clerk
fres beck.jy)
RWB-203Q
R. W. BECK AND ASSOCIATES
Engineers and Consultants
PROFESSIONAL SERVICES AGREEMENT
June 2, 1989 WV-1405-BAl-AZ
Date P S. A. No
CLIENT City of Yakima
ADDRESS 129 North Second Street
Yakima, Washington 98901
PROJECT Sewer Design Projects
Part I—Scope of Services
See Exhibit A attached
Part II—Payment
For services furnished, the Client shall pay R.W. Beck and Associates, Consulting Engineer, upon submission of monthly invoices,
an amount equal to the actual hours of services furnished multiplied by the product of the Consulting Engineer's established hourly salary
costs, which include allowance for personnel benefits, and a factor of 2.4
In addition, the Client shall reimburse the Consulting Engineer each month: at cost for all out-of-pocket expenses directly chargeable
to the work; at cost plus 10% for services of Special Consultants and Subcontractors; and at the Consulting Engineer's then current rates for
computer and reproduction services.
On the basis of the Scope of Services outlined in this Agreement, the estimated total amount to be paid by the Client for services
furnished and expenses reimbursed will be approximately $64,700.00 The maximum amount
to be paid by the Client under this Agreement shall not exceed the amount estimated above kX;l'0fIX9 1NRXXXXXXXXXXXXXXXXXA
without prior written authorization of the Client, and the Consulting Engineer shall not be required to furnish services or incur expenses
for which the total charges to the Client exceed such maximum amount.
Part III—Standard Provisions (see following pages)
Part IV—Special Provisions ( )
Approved for CLIENT
Approved for CONSULTING ENGINEER
By. C:127 -S.4 By.
Title: Title:
Richard A. Zais, Jr.
City Manager
Title: Karen S. Roberts
City Clerk
MM
By-
Title:
yTitle:
-fa.efliz-
A,„,71/7,4„ 17
City Contract No.
-3
oiution No. _mss
Q
R. W. Beck and Associates '
PART III — STANDARD PROVISIONS
IIIA. Consulting Engineer's Organizations
R. W. Beck and Associates is a partnership
and R. W. Beck and Associates, Inc. is a corpora-
tion owned and controlled by the partnership. Both
entities are organized and operated under the laws
of the State of Washington. It is expressly agreed
that the partnership may be changed by addition or
reduction in the number of the partners or redis-
tribution of the partnership interests and this
Agreement may be assigned to the partnership or to
the corporation. The Consulting Engineer may as-
sign the compensation from this Agreement to any
other entity.
III.B. Professional Services
1. The Consulting Engineer shall be consul-
tant and advisor to the Client as an independent
contractor and shall not be an employee of the Cli-
ent. The Consulting Engineer shall not be an agent
or representative of the Client except that the
Consulting Engineer may act as the Client's agent
in providing construction management services to
the degree specifically authorized in Part IV -
Special Provisions of this Professional Services
Agreement.
2. The Consulting Engineer represents that
the services furnished under this Agreement will be
in accordance with generally accepted professional
practices. Any estimate of cost of equipment, con-
struction, ownership or operation furnished by the
Consulting Engineer shall' be the Consulting Engi-
neer's opinion based upon its professional judgment
and experience. The Consulting Engineer makes no
other representation or warranty, express or im-
plied.
III.C. Change in Scope and Delays
1. If the provisions for payment in this
Agreement provide for a fixed fee or a maximum
payment for services, such fee" or maximum is for
the Scope of Services described in the Agreement.
If the Scope of Services is modified so that more
or less work or time is required, and such
modification is accepted by the Client and the
Consulting Engineer, the fee or maximum and the
time shall be equitably adjusted.
2. In the event of delays in or failures of
performance of the Consulting Engineer caused by
circumstances_ beyond its control, the Consulting
Engineer's fee or maximum and the time allowed
shall be equitably adjusted, and such delays or
failures shall not constitute a default or give
rise to any claim against the'Consulting Engineer.
III.D. Relating to Payment
1. The Consulting Engineer's "Salary Costs"
allow for basic salary and personnel benefits,
including: life, accident, disability and medical
insurance; sick leave, holiday and vacation pay;
social security, workers' compensation, unemploy-
ment compensation and pension retirement contribu-
tions; and similar employment-related costs. Basic
salary per hour shall be twelve times current
monthly salary for employees or current monthly
drawings in lieu of salary for partners, exclusive
of overtime, bonus or other profit participation
payments, divided by 2,080.
2. The Consulting Engineer's "Out -of -Pocket
Expenses" are those expenditures made by the
Consulting Engineer, other than Salary Costs, costs
of reproduction and computer services and costs of
Special Consultants and Subcontractors, which are
directly chargeable to the project and which would
not otherwise have been incurred. Such expendi-
tures include, but are not limited to, transporta-
tion, lodging, subsistence, communications,
liability and other insurance premiums when
required by the Client in addition to the types and
amounts currently carried by the Consulting
Engineer, taxes other than those levied on the
profits or net income of the Consulting Engineer,
equipment rentals and repair, and special mailing,
forms, materials and supplies required during the
progress of the work. Reimbursement for out-of-
pocket expenses shall be an amount equal to the
cost thereof.
3. "Computer services" as used herein shall
mean the use of electronic computing and informa-
tion processing equipment, word processing equip-
ment, data communications equipment, computer
software, and related facilities and services of
personnel necessary to operate and maintain such
equipment and facilities. "Reproduction services"
as used herein shall mean the use of printing and
copying equipment, photographic equipment, and
similar facilities and services of personnel to
operate and maintain such equipment and facil-
ities. Charges for computer and reproduction
services shall be at the Consulting Engineer's
established-- rates therefor which are in effect at
the time.,of such usage.
4. -In event of the "inability or failure of
the Client to pay' -'as --agreed, interest commencing
sixty days after the date of invoice shall be paid
by the Client to the_,Consultinp Engineer on the
last day of each month on4)all,_'unpaid amounts due
the Consulting- Engineer- at -the- interest rate for
borrowed funds then- currently available to the
Consulting Engineer at the Rainier National Bank of
Seattle.
Q
R. W. Beck and Associates
PART III — STANDARD PROVISIONS
III.E. Insurance
The Consulting Engineer shall maintain in
effect, to the extent that such insurance is avail-
able at reasonable cost, employer's liability, pro-
fessional liability, comprehensive general liabil-
ity (bodily injury and property damage) and compre-
hensive automobile liability (bodily injury and
property damage) insurance with respect to employ-
ees and vehicles of the Consulting Engineer
assigned to the prosecution of work under this
Agreement, with each policy having maximum limits
of not less than $5,000,000, and statutory workers'
compensation protection. Upon written request, the
Consulting Engineer will supply to the Client a
description of each such insurance policy currently
in effect, specifying the amount thereof. The Con-
sulting Engineer will obtain and thereafter main-
tain in effect, if reasonably available, such addi-
tional insurance as may be requested by the Client,
the cost of which shall be reimbursed by the Client.
III.F. Liability
In partial but specific consideration of
the execution of this Agreement, the Client and
Consulting Engineer agree as follows:
1. The Consulting Engineer shall indemnify
and hold harmless the Client and its governing
board, officers and employees from all claims,
expenses and liability, following operation of
applicable rights of contribution, arising out of
negligent acts, errors or omissions of the
Consulting Engineer and its employees, including
claims made by employees of the Consulting
Engineer; provided, however, such indemnification
and hold harmless shall not exceed (a) the proceeds
of any applicable insurance required to be
maintained by the Consulting Engineer under the
provisions of this Agreement or (b) $250,000,
whichever is greater.
2. The Client shall indemnify and hold harm-
less the Consulting Engineer, its partners, offi-
cers,"employees and subcontractors from all claims,
expenses and liability, following operation of
applicable rights of contribution, arising out of
negligent acts, errors or omissions of the Client
and its employees, including claims made by
employees of the Client and claims related to
construction, use, occupancy, ownership, operation,
maintenance or control of facilities related to
services to be performed under this Agreement.
3. The Client shall limit any and all claims
of the Client against the Consulting Engineer, its
partners, officers, employees or subcontractors
arising out of the performance of this Agreement,
to an amount not to exceed (a) the proceeds of any
III -2
applicable insurance required to be maintained
the Consulting Engineer under the provisions
this Agreement or (b) $250,000, whichever
greater.
by
of
is
4. For amounts in excess of any proceeds of
the insurance required to be maintained by the Con-
sulting Engineer under the provisions of this
Agreement, the Client shall indemnify the Consult-
ing Engineer, its partners, officers, employees and
subcontractors against all expense or liability of
any kind arising out of any claim for loss of life,
bodily or personal injury, property damage or other
loss from any cause related to the furnishing of
the services covered by this Agreement; provided,
however, this indemnity shall not apply to the sole
negligence of the Consulting Engineer.
5. The Client and the Consulting Engineer
shall not be liable to each other in any event for
interest (except as otherwise provided); loss of
anticipated revenues, earnings or profits; in-
creased expense of operations; loss by reason of
shutdown or non -operation due to late completion or
otherwise; and consequential damages.
6. In any and all claims involving an
employee of the Consulting Engineer or the Client,
the indemnification obligation under this paragraph
entitled "Liability" shall not be limited in any
way by any limitation on the amount or type of
damages, compensation or benefits payable under
workers' or workmen's compensation acts, disability
benefit acts or other employee benefit acts.
III.G. Suspension or Termination of Services
The Client or the Consulting Engineer may
suspend or terminate any or all services covered in
this Agreement at any time upon written notice in
which event the Client shall pay the Consulting
Engineer upon submission of invoices for all
services rendered and expenses incurred to the
effective date of such suspension or termination.
III.H. Construction Contractor's
Performance and Safety
The Consulting Engineer shall not be
responsible: for safety on the Client's premises
or project site, except for the safety. of personnel
of the Consulting Engineer, its Special Consultants
and Subcontractors; for providing or assuring a
safe place for the performance of the construction
contractor's work; for safety precautions; programs
or equipment; for construction means, methods,
techniques, sequences or procedures; or for the
construction contractor'sfailure to perform the
work in accordance with the Contract Documents.
Q
W. is eck and Associates
PART III — STANDARD PROVISIONS
III.I. Disposition of Documents
1. Upon completion of the services provided
under this Agreement, the Consulting Engineer shall
deliver to the Client one copy of all Reports,
Specifications and Contract Documents and one
transparency of each of the Drawings. The orig-
inals of all Reports, Specifications, Drawings and
Contract Documents shall be retained by the Con-
sulting Engineer and upon request by the Client,
the Consulting Engineer will furnish copies to the
Client at actual cost of duplication and mailing.
If such Reports, Specifications, Drawings or Con-
tract Documents or reproductions thereof, or any
other items relating to the services of the Con-
sulting Engineer are changed in any way or used by
the Client for any other project or purposes, the
Client shall indemnify, defend and hold harmless
the Consulting Engineer from all loss, damage, lia-
bility or expense arising out of such change or use.
2. Except as specifically provided to the
contrary in this Agreement, all computer programs,
computer code and documents related thereto
("computer software") developed by or used by the
Consulting Engineer in conjunction with the Con-
sulting Engineer's work hereunder shall remain the
sole and exclusive property of the Consulting Engi-
neer, and the Client shall have no right or title
to or interest in such computer software. In the
event the Consulting Engineer releases any such
computer software to the Client, the Client shall
protect the confidentiality of such computer soft-
ware and shall not release or divulge such computer
software to any other person or organization or let
any other persons or organization use such computer
software. In the event Client uses any such com-
puter software or allows such computer software to
be used by others, the Client shall indemnify and
hold harmless the Consulting Engineer from all
loss, damage, liability or expense arising out of
such use.
III.J. Equal Opportunity
The Consulting Engineer will not knowingly
discriminate against any employee or applicant for
employment because of age, race, color, religion,
sex, national origin, marital or veteran status or
physical handicap. The Consulting Engineer will
take affirmative action to the end that applicants
are employed, and that employees are treated during
employment, without such discrimination.
III.K. Severability and Headings
1. If any part of tl:iis Agreement, including,
but not limited to, any provision, paragraph,
clause, phrase or words, :is found to be in conflict
I1I-3
with applicable laws, such part shall be inopera-
tive, null and void insofar as it is in conflict
with said laws, but the remainder shall be given
full force and effect.
2. The descriptive headings used in this
Agreement have been
reference only and
restrict any of the
Agreement.
III.L. Notice
inserted for convenience of
shall in no way modify or
terms and provisions of this
All notices relating to this Agreement
shall be in written form delivered in person or by
Express Mail, Registered or Certified United States
Mail, postage prepaid, to the Consulting Engineer
or to the Client to the attention of its chief
executive officer at the last business address of
the principal office of the addressee known to the
sender.
- END OF PART III -
WV -0000 -BD -AA June 2, 1989
R. W. Beck and Associates
EXHIBIT A -- SCOPE OF SERVICES
SEWER DESIGN PROJECTS
I. General
The project consists of the design of three separate sewer system
extensions to the City of Yakima System identified as the 1) Scenic Drive Sew-
er Extension (approximately 5,000 if), 2) the Appleview L.I.D. (aproximately
5,200 lf), and 3) the Westview L.I.D. (approximately 4,800 lf). The design
shall be completed according to preliminary layouts prepared by the City of
Yakima. The length of the Scenic Drive Sewer will be determined by the area
along Scenic Drive that can be physically served by a gravity sewer. The
scope will also include investigating the feasibility of extending the exist-
ing sewer which runs north from Mari Lane to Scenic Drive and directing sewage
from areas to the west along Scenic Drive to this sewer. The sewer will be
designed with stubs to connect side sewers from existing homes, but the design
and construction of the side sewers are not part of the project.
II. Work To Be Performed By The Consulting Engineer During the Design Phase
1. Field Investigations
The City has aerial mapping with 5 -foot contour intervals prepared in
1982 which will be used as the base map for the project. The Consultant
shall establish the centerline of the road right-of-way survey spot ele-
vations along the route of the interceptor in order to verify the eleva-
tions for design purposes and as an aid in determining which houses and
service area can be directed to the new sewer. The consultant shall also
survey the basement elevations of houses along the route.
2. Design Report
The Consultant shall prepare a design report, establishing the final
route, pipeline size and materials, identifying service to existing and
future development, and discussing alternatives considered. The report
shall include a preliminary plan and profile for the pipeline. This re-
port shall be reviewed and approved by the City before proceeding with
final design.
3. Contract Drawings
Contract Drawings for bidding the project will consist of plan/profile
drawings at a scale of 1:40 prepared from City mapping and survey data
discussed under Paragraph No. II, 1, and drawings showing construction
details necessary for the construction of the project, including man-
holes, connections, pipeline crossings, road restoration, etc.
Exhibit A (Continued) Page 2
4. Contract Specifications
Technical specifications shall be prepared in the CSI format with the
WSDOT/APWA specifications used where appropriate. The general and spe-
cial conditions shall be prepared using the City's format.
5. Engineer's Estimate
The Consultant shall prepare a detailed Engineer's Estimate of the proba-
ble construction cost as of the date that the design is completed.
6. City Review and Final Contract Documents
The Contract Documents including the drawings, technical specifications,
general and special conditions, and bidding instructions shall be submit-
ted in draft form to the City for review. The Consultant shall meet with
the City to review the design and will incorporate any comments into a
final set of Contract Documents. The Consultant will deliver a camera-
ready set of the Contract Specifications and reproducible master of the
Contract Drawings to the City for its use in advertising the construction.
III. Additional Services
The City may request additional services from the Consulting Engi-
neer which may include consulting services during construction, the design of
additional sewers, or other services as may become necessary or desirable dur-
ing the course of the project.
Payment for additional services shall be the subject of a supple-
mental agreement acceptable to both parties.
IV. Services To Be Provided By The City
The City shall provide the following assistance and services:
1. Obtain any easements required for the project.
2. Satisfying envi ronmental requirements for the project.
3. "As -built" drawings with invert elevations for the existing sewers.
4. Any other information, reports, or other documents as may be neces-
sary to facilitate the design.
5. Reproducible copies of the aerial base maps with 5 -foot contour
intervals prepared for the area.
6. Printing the Contract Documents and advertising the project for
construction.
- End of EXHIBIT A -
(A6924e)
RWB-272C
R. W. Beck and Associates
PART III - STANDARD PROVISIONS
(Subconsultant Agreements)
The Subconsultant and Beck agree that the following Standard Provisions shall
supersede any conflicting provisions of this Agreement.
III A. Insurance
1. The Subconsultant shall provide and shall pay the premiums for workmen's
compensation insurance and unemployment insurance on behalf of its employees to the insuring
limits set by law. The Subconsultant shall pay when due all social security, federal income
tax deductions and any other taxes or payroll deductions required by law for or on behalf of
its employees. The Subconsultant shall maintain in effect comprehensive general liability
(bodily injury and property damage), comprehensive automobile liability (bodily injury and
property damage) and employer's liability insurance with respect to employees and vehicles of
the Subconsultant assigned to the prosecution of work under this Agreement in an amount not
less than $1,500,000 combined single limit. In addition, the Subconsultant shall maintain in
effect professional liability insurance in the amount of not less than $500,000 per
occurrence and in the aggregate during each annual policy period for not less than three
years following completion of all services under this Agreement.
2. The Subconsultant agrees to furnish certificates of insurance to Beck within 15 days
from the date of this Agreement which certify the amount of such insurance and that its
insurance companies will notify Beck 15 days prior to the effective date of any termination,
cancellation, material change or reduction of said insurance coverages.
3. The Subconsultant shall indemnify, defend and hold Beck harmless from any and all
claims, demands and actions based upon or arising out of errors, omissions or negligent acts
of Subconsultant or its partners, officers, employees, subcontractors or agents related to
this Agreement.
III.B. Assignment
The services to be provided under this Agreement shall not be assigned by the
Subconsultant without the prior written approval of Beck.
III.C. Suspension or Termination of Services
Beck may suspend or terminate any or all of the services covered by this Agreement
upon written notice in which event equitable payment will be made for all services rendered
and expenses incurred to the effective date of such suspension or termination.
III.D. Limitation of Liability Prohibited
No limitation of liability of any kind is provided to the Subconsultant by Beck
under this Agreement.
III.E. Complete Agreement
This Agreement combines all understandings relative to the services to be provided
into a single agreement superseding all previous correspondence, discussions and proposals.
- End PART III -
R.W. BECK
AN ASSOCIATES
maiseataishismisommusso
(C
Fourth and Blanchard Building, Suite 600 ■ 2121 Fourth Avenue ■ Seattle, Washington 98121-2317
Telephone (206) 441-7500 ■ Fax (206) 441-4962/441-4972
WV -0000 -BD -AA (0261) June 2, 1989
Mr. Dennis Covell
City Engineer
City of Yakima
129 North Second Street
Yakima, Washington 98901
Dear Dennis:
Subject: Professional Services Agreement
for Engineering Services
This will confirm that we FAX'd a revised agreement for the design of
the sewer extensions to you this afternoon. The revised project includes the
Appleview and the Westview Local Improvement District as well as the Scenic Drive
Sewer which was previously included in the scope. The scope of work is essential-
ly the same for each of the three areas. There is some economy in combining the
three projects and the new total price is $64,700.
We have made several assumptions in our estimate:
1. We have not included any geotechnical investigations, assuming that
these should not be necessary.
2. We have included surveying by Huibregtse, Louman Associates, Inc. for
each of the project areas to establish spot elevations along the sewer
route, to establish a baseline for construction, and to determine base-
ment elevations for houses that will be connected to the sewer system.
3. We are assuming that the topographic mapping that was prepared by
Olympus Associates, Inc. is available for the Appleview and Westview
areas.
We look forward to working with you on this project and hope that you
find the enclosed contracts in order.
RAB/ato
Enclosures
(A6924e)
Very truly yours,
R. W. BECK AND ASSOCIATES
L24) 23L,,
R.
Alan Bushley
Partner and Manage
Au,n.1X•IL„t,m.NlAW...luml•tn \I •I:.mrt,(010 li.utq,k,Il'•Nlim,HI, MN
1N•117I r I ,11 ■ I'Ix•n n. 1/1 ii runrnn, t \ • . ile \\'•\
RESOLUTION NO. D® 5 5 8 3
A RESOLUTION authorizing the City Manager and City Clerk of the City
of Yakima to execute an agreement with R. W. Beck &
Associates for professional engineering services.
WHEREAS, in connection with the Scenic Drive/53rd Avenue area;
potential Westview area LID; and proposed Brenda Terrace, Taylor and
Century Additions area LID, it is necessary for the City to engage
professional engineeing services to provide plans, specifications, and
construction cost estimates, and
WHEREAS, R. W. Beck & Associates has offered to perform those
professional services; and the City Council deems it to be in the best
interest of the City that an agreement document be executed by the
City, now, therefore,
BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF YAKIMA:
The City Manager and City Clerk of the City of Yakima are hereby
authorized and directed to execute an agreement with R. W. Beck &
Associates for the purpose mentioned above, the estimated costs and
description of tasks which are to be incorporated 'in the agreement
attached hereto and by reference, made a part hereof.
ADOPTED BY THE CITY COUNCIL this V day of,L �v_... , 1989.
Al'1'k;ST :
CITY CLERK
MAYOR