Press Alt + R to read the document text or Alt + P to download or print.

No preview available

The URL can be used to link to this page

Home My WebLink AboutR-2009-137 Franklin Pool Water Slide Safety Evaluation Agreement with Sargent Engineers, Inc.RESOLUTION NO. R-2009-137 A RESOLUTION authorizing the City Manager of the City of Yakima to execute an agreement between the City of Yakima and Sargent Engineers, Inc. to evaluate the condition of the water slide and its support structure at Franklin Pool. WHEREAS, the City of Yakima operates and maintains Franklin Pool located in Yakima, Washington; and WHEREAS, the existing pool slide at Franklin Pool was constructed in 1991 and its condition needs to be evaluated to maintain its safety; and WHEREAS, Sargent Engineers, Inc. has the experience and expertise necessary to provide said services, and Sargent Engineers, Inc. is willing to perform said services in accordance with the terms and conditions of the attached agreement; and WHEREAS, the City Council deems it to be in the best interest of the City of Yakima to authorize execution of the attached agreement with Sargent Engineers, Inc. to observe the condition, determine the safe loading for the slide, and prepare a detailed report documenting the condition and strength of the slide, and suggest any maintenance that needs to be performed on the slide, now, therefore, BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF YAKIMA: The City Manager is hereby authorized and directed to execute the attached and incorporated "Consulting Agreement' between the City of Yakima and Sargent Engineers, Inc. for the purpose of evaluating the safety of the water slide at Franklin Pool. ADOPTED BY THE CITY COUNCIL this eh day of Oct• % r 2009 1/ ATTEST: David Edler, Mayor 4-46tnaLL City Cle J RFS NO. R-2009-137 Franklin pool water slide.rtf 2009- ''7 AGREEMENT BETWEEN THE CITY OF YAKIMA, WASHINGTON AND SARGENT ENGINEERS, INC. FOR PROFESSIONAL SERVICES TA,day of (V THIS AGREEMENT, made - and entered into on this (;(17. o , 2009, by and between the City of Yakima, Washington, with principal offices at 129 North Second Street, Yakima, WA 98901, hereinafter referred to as "CITY," and SARGENT ENGINEERS, INC.,. 320 Ronlee Lane NW, Olympia, WA 98502 and which corporation and its principal engineers performing this Agreement are licensed and registered to do business in the State of Washington, hereinafter referred. to as "ENGINEER," for the FRANKLIN POOL SLIDE EVALUATION, herein called the "PROJECT." WITNESSETH: RECITALS WHEREAS, CITY desires to retain the ENGINEER to provide engineering services for the FRANKLIN POOL SLIDE EVALUATION, as described in this Agreement and subsequent Amendments thereto; and WHEREAS, ENGINEER represents that it has available and offers to provide personnel with expertise and experience necessary to satisfactorily accomplish the workwithin the required time and that it has no conflicts of interest prohibited by law from entering into this Agreement; NOW, THEREFORE, CITY and ENGINEER agree as follows: SECTION 1 INCORPORATION OF RECITALS 1.1 The above recitals are incorporated into these operative provisions of the Agreement. SECTION 2 SCOPE OF SERVICES 2.0.1 ENGINEER agrees to perform those services described hereafter. Unless modified in wilting by both parties, duties of ENGINEER shall not be construed to exceed those services specifically set forth herein. 2.1 Basic Services: ENGINEER agrees to perform those tasks described in Exhibit A, entitled "City of Yakima — FRANKLIN POOL SLIDE EVALUATION" (WORK) which is part of this Agreement as if fully set forth herein. 2.2 Additional Services: CITY and ENGINEER agree that not all WORK to be performed by ENGINEER can be defined in detail at the time this Agreement is executed, and that additional WORK related to Project and not covered in Exhibit 'A may be needed during performance of this Agreement. CITY may, at any time, by written order, direct the ENGINEER to revise portions of the PROJECT WORK previously completed in a satisfactory manner, delete portions of the PROJECT, or request that the ENGINEER perform additional WORK beyond the scope of the PROJECT WORK Such changes hereinafter shall be referred to as "Additional Services." 2.2.1 If such Additional Services cause an increase or decrease in the ENGINEER'S cost of, or time required for, performance of any services under this Agreement, a contract Page - 1 - Professional Services Agreement between the City of Yakima and Sargent Engineers price and/or completion time adjustment pursuant to this Agreement shall be made and this Agreement shall be modified in writing accordingly. 2.2.2 Compensation for each such request for Additional Services will be negotiated by the CITY and the ENGINEER according to the provisions set forth in Exhibit C and, if so authorized, shall be considered part of the PROJECT WORK. The ENGINEER shall not perform any Additional Services until so authorized by CITY and agreed to by the ENGINEER in writing. 2.3 The ENGINEER must assert any claim for adjustment in writing within thirty (30) days from the date of receipt by the ENGINEER of the written notification of change or of providing services related to an asserted change, whichever is earliest. SECTION 3 CITY'S RESPONSIBILITIES 3.1 CITY -FURNISHED DATA: The CITY will provide to the ENGINEER all technical data in the CITY'S possession relating to the ENGINEER'S services on the PROJECT including information on any pre-existing conditions known to the CITY that constitute hazardous waste contamination on the PROJECT site as determined by an authorized regulatory agency. 3.2 ACCESS TO FACILITIES AND PROPERTY: The CITY will make its facilities reasonably accessible to ENGINEER as required for ENGINEER'S performance of its services and will provide labor and safety equipment as reasonably required by ENGINEER for such access. 3.3 TIMELY REVIEW: The CITY will examine the ENGINEER'S studies, reports, sketches, drawings, specifications, proposals,' and other documents; obtain advice of an attomey, insurance counselor, accountant, auditor, bond and financial advisors, and other consultants as CITY deems appropriate; and render in writing decisions required of CITY in a timely manner. Such examinations and decisions, however, shall not relieve the ENGINEER of any contractual obligations nor of its duty to render professional services meeting the standards of care for its profession. 3.4 CITY shall appoint a City's Representative with respect to WORK to be performed under this Agreement. City's Representative shall have complete authority to transmit instructions and receive information. ENGINEER shall be entitled to reasonably rely on such instructions made by the CITY'S Representative unless otherwise directed in writing by the CITY, but ENGINEER shall be responsible for bringing to the attention of the CITY'S Representative any instructions which the ENGINEER believes are inadequate, incomplete, or inaccurate based upon the ENGINEER'S knowledge. 3.5 Any documents, services, and reports provided by the CITY to the ENGINEER are available solely as additional information to the ENGINEER and will not relieve the ENGINEER of its duties and obligations under this Agreement or at law. The ENGINEER shall be entitled to reasonably rely upon the accuracy and the completeness of such documents, services and reports, but shall be responsible for exercising customary professional care in using and reviewing such documents, services, and reports and drawing conclusions therefrom. Page - 2 - Professional Services Agreement between the City of Yakima and Sargent Engineers SECTION 4 AUTHORIZATION, PROGRESS, AND COMPLETION 4.1 In signing this Agreement, CITY grants ENGINEER specific authorization to proceed with WORK described in Exhibit A. The time for completion is defined in Exhibit A, or as amended. ' SECTION 5 COMPENSATION 5.1 COMPENSATION ON A TIME SPENT BASIS AT SPECIFIC HOURLY RATES: For the services described in Exhibit A, compensation shall be according to Exhibit C - Schedule of Specific Hourly Rates on a time spent basis plus reimbursement for direct non -salary expenses. , 5.1.1 DIRECT NON -SALARY EXPENSES: Direct Non -Salary Expenses are, those costs incurred on or directly for the PROJECT including, but not limited to, necessary transportation costs, including current rates for ENGINEER'S vehicles; meals and lodging; laboratory tests and analyses; printing, binding and reproduction charges; all costs associated with other outside nonprofessional services and facilities; special CITY -requested and PROJECT -related insurance and performance warranty costs; and other similar costs. Reimbursement for Direct Non -Salary Expenses will be on the basis of actual charges when fumished by commercial sources and on the basis of current rates when furnished by ENGINEER. Estimated Direct Non -Salary Expenses are shown in Exhibit B. 5.1.1.2 Travel costs, including transportation, lodging, subsistence, and incidental expenses incurred by employees of the ENGINEER and each of the Subconsultants in connection with PROJECT WORK; provided, as follows: O That a maximum of U.S. INTERNAL REVENUE SERVICE allowed cents per mile will be paid for the operation, maintenance, and depreciation costs of company or individually owned vehicles for that portion of time they are used for PROJECT WORK. ENGINEER, whenever possible, will use the least expensive form of ground transportation. ❑ That reimbursement for meals inclusive of tips shall not exceed a maximum of $40 per day per person. This rate may be adjusted on a yearly basis. 0. That accommodation shall be at a reasonably priced hotel/motel. ❑ That air travel shall be by coach class, and shall be used only when absolutely necessary. 5.1.2 Telephone charges, computer charges, in-house reproduction charges, first class postage, and FAX charges are not included in the direct expense costs, but are considered included in the Schedule of Specific Hourly Billing Rates. 5.1.3 Professional Subconsultants. Professional Subconsultants are those costs for engineering, architecture, geotechnical services and similar professional services approved by the CITY. Reimbursement for Professional Subconsultants will be on the basis of 1.10 times the actual costs billed by the Professional Subconsultant for services provided to the CITY through this Agreement. Estimated Subconsuttant costs are shown in Exhibit B. Page - 3 - Professional Services Agreement between the City of Yakima and Sargent Engineers 5.2 Unless specifically authorized in writing by the CITY, the total budgetary amount for this PROJECT shall not exceed that amount set forth in Exhibit B. The ENGINEER will make reasonable efforts to complete the WORK within the budget and will keep CITY informed of progress toward that end so that the budget or WORK effort can be adjusted if found necessary. The ENGINEER is not obligated to incur costs beyond the indicated budget, as may be adjusted, nor is the CITY obligated to pay the ENGINEER beyond these limits. When any budget has been increased, the ENGINEER'S excess costs expended prior to such increase will be allowable to the same extent as if such costs had been incurred after the approved increase, and provided that the City was informed in writing at the time such costs were incurred. 5.3 The ENGINEER will use its best efforts to submit to the City's Representative by the 10th day of each calendar month an invoice for payment for PROJECT services completed through the accounting cut-off day of the previous month. Such invoices shall be for PROJECT services and WORK performed and costs incurred prior to the date of the invoice and not covered by previously submitted invoices. The ENGINEER shall submit with each invoice a summary of time expended on the PROJECT for the current billing period, copies of subconsultant invoices, and any other supporting materials determined by the City necessary to substantiate the costs incurred. CITY will use its best efforts to pay such invoices within thirty (30) days of receipt and upon approval of the WORK done and amount billed. CITY will notify the ENGINEER promptly if any problems are noted with the invoice. CITY may question any item in an invoice, noting to ENGINEER the questionable item(s) and withholding payment for such item(s). The ENGINEER may resubmit such item(s) in a subsequent invoice together with additional supporting information required. 5.4 If payment is not made within sixty (60) days following receipt of approved invoices, interest on the unpaid balance shall accrue beginning with the sixty-first (61) day at the rate of 1.0% per month or the maximum interest rate permitted by law, whichever is Tess; provided, however, that no interest 'shall accrue pursuant to Chapter 39.76 RCW when before the date of timely payment a notice of dispute is issued in good faith by the CITY to the ENGINEER pursuant to the terms of RCW 39.76.020(4). 5.5 Final payment of any balance due the ENGINEER for PROJECT services will be made within forty-five (45) days after satisfactory completion of the services required by this Agreement as evidenced by written acceptance by CITY and after such audit or verification as CITY may deem necessary and execution and delivery by the ENGINEER of a release of all known claims against CITY arising under or by virtue of this Agreement, other than such claims, if any, as may be specifically exempted by the ENGINEER from the operation of the release in stated amounts to be set forth therein. 5.6 Payment for any PROJECT services and WORK shall not constitute a waiver or release by CITY of any claims, right, or remedy it may have against the ENGINEER under this Agreement or by law, nor shall such payment constitute a waiver, remission, or discharge by CITY of any failure or fault of the ENGINEER to satisfactorily perform the PROJECT WORK as required under this Agreement. SECTION 6 RESPONSIBILITY OF ENGINEER 6.1 The ENGINEER shall be responsible for the professional quality, technical adequacy and accuracy, timely completion, and the coordination of all plans, design, drawings, specifications, reports, and other services furnished by the ENGINEER under this Page 4 Professional Services Agreement between the City of Yakima and Sargent Engineers Agreement. The ENGINEER shall, without additional compensation, correct or review any errors, omissions, or other deficiencies in its plans, designs, drawings, specifications, reports, and other services. The ENGINEER shall perform its WORK according to generally accepted civil engineering standards of care and consistent with achieving the PROJECT WORK within budget, on time, and in compliance with applicable laws, regulations, and permits. 6.2 CITY'S review or approval of, or payment for, any plans, drawings, designs, specifications, reports, and incidental WORK or services fumished hereunder shall not in any way relieve the ENGINEER of responsibility for the technical adequacy, completeness, or accuracy of its WORK and the PROJECT WORK. CITY'S review, approval, or payment for any of the services shall not be construed to operate as a waiver of any rights under this Agreement or at law or any cause of action arising out of the performance of this Agreement. 6.3 In performing WORK and services hereunder, the ENGINEER and its subcontractors, subconsultants, employees, agents, and representatives shall be acting as independent contractors and shall not be deemed or construed to be employees or agents of CITY in any manner whatsoever. The ENGINEER shall not hold itself out as, nor claim to be, an officer or employee of CITY by reason hereof and will not make any claim, demand, or application to or for any right or privilege applicable to an officer or employee of CITY. The ENGINEER shall be solely responsible for any claims for wages or compensation by ENGINEER employees, agents, and representatives, including subconsultants and subcontractors, and shall save and hold CITY harmless therefrom. 6.4 INDEMNIFICATION: (a) ENGINEER agrees to indemnify, defend, and hold the CITY harmless from loss, cost, or expense, including legal fees, of any kind claimed by third parties, including without limitation such loss, cost, or expense resulting from injuries to persons or damages to property, caused solely by the negligence or willful misconduct of the ENGINEER, its employees, officers, and subconsultants in connection with the PROJECT. In the event that any lien is placed upon the property of the CITY or any of the CITY'S officers, employees, or agents as a result of the negligence or willful misconduct of the ENGINEER, the ENGINEER shall at once cause the same to be dissolved and discharged by giving bond or otherwise. (b) CITY agrees to indemnify, defend, and hold the ENGINEER harmless from Toss, cost, or expense, including legal fees, of any kind claimed by third parties, including without limitation such loss, cost, or expense resulting from injuries to persons or damages to property, caused solely by the negligence or willful misconduct of the CITY, its employees, or agents in connection with the PROJECT. (c) If the negligence or willful misconduct of both the ENGINEER and the CITY (or a person identified above for whom each is liable) is a cause of such third party claim, the Toss, cost, or expense shall be shared between the ENGINEER and the CITY in proportion to their relative degrees of negligence or willful misconduct and the right of indemnity will apply for such proportion. Page -5 - Professional Services Agreement between the City of Yakima and Sargent Engineers 6.5 In any and, all claims by an employee of the ENGINEER, any subcontractor, anyone directly or indirectly employed by any of them or anyone for whose acts any of them may be liable, the indemnification obligations under this Agreement shall not be limited, in any way by any limitation on the amount or types of damages, compensation, or benefits payable by or for the ENGINEER or a subcontractor under workers' or workmens' compensation acts, disability benefit acts, or other employee benefit acts. The ENGINEER waives its immunity under the Industrial Insurance Act, Title 51, RCW. Such waiver has been mutually negotiated by the ENGINEER and the CITY as evidenced by their specific and express initialing of this paragraph. ENGINEER'S INITIALS 1445 CITY'S INITIALS 6.6 It is understood that any resident engineering or Construction Observation provided by ENGINEER is for the purpose of determining compliance with the technical provisions of PROJECT specifications and does not constitute any form of guarantee or insurance with respect to the performance of a contractor. ENGINEER does not assume responsibility for methods or appliances used by a contractor, for the safety of construction work, or for compliance by contractors with laws and regulations. CITY shall use its best efforts to ensure that the construction contract requires that the contractor(s) indemnify and name CITY, the CITY'S and the ENGINEER'S officers, principals, employees, agents, representatives, and engineers as additional insureds on contractor's insurance policies covering PROJECT, exclusive of insurance for ENGINEER professional liability. 6.7 SUBSURFACE INVESTIGATIONS: In soils, foundation, groundwater, and other subsurface investigations, the actual characteristics may vary significantly between successivetest points and sample intervals and at locations other than where observation, exploration, and investigations have been made. Because of the inherent uncertainties in subsurface evaluations, changed or unanticipated underground conditions may occur that could affect total PROJECT cost and/or execution. These conditions and cost/execution effects are not the responsibility of the ENGINEER, to the extent that ENGINEER has exercised the applicable standard of professional care and judgment in such investigations. SECTION 7 PROJECT SCHEDULE AND BUDGET 7.1 The general PROJECT schedule and the budget for both the entire PROJECT and its component tasks shall be as set forth in this Agreement and Attachment D, Project Schedule. The project schedule and performance dates for the individual tasks shall be mutually agreed to by the CITY and the ENGINEER within fifteen days after execution of this Agreement. The performance dates and budgets for tasks may be modified only upon written agreement of the parties hereto. The performance date for tasks and the completion date for the entire PROJECT shall not be extended nor the budget increased because of any unwarranted delays attributable to the ENGINEER, but may be extended or increased by the CITY in the event of a delay caused by special services requested by the CITY, or because of unavoidable delay caused by any govemmental action, or other conditions beyond the control of the ENGINEER which could not be reasonably anticipated. 7.2 Not later than the tenth day of each calendar month during the performance of the PROJECT, the ENGINEER shall submit to the CITY'S Representative a copy of the current schedule and a written narrative description of the WORK accomplished by the ENGINEER and subconsultants on each task, indicating a good faith estimate of the Page -6 - Professional Services Agreement between the City of Yakima and Sargent Engineers percentage completion thereof on the last day of the previous month. Additional oral or written reports shall be prepared at the request of the CITY for presentation to other govemmental agencies and/or to the public. SECTION 8 REUSE OF DOCUMENTS 8.1 All intemal WORK products of the ENGINEER are instruments or service of this PROJECT. There shall be no reuse, change, or alteration by the CITY or others acting through or in behalf of the CITY without written permission of the ENGINEER, which shall not be reasonably withheld will be at the CITY's sole risk. The CITY agrees to indemnify the ENGINEER and its officers, employees, subcontractors, and affiliated corporations from all claims, damages, losses, and costs, including, but not limited to, litigation expenses and attomey's fees,•arising out of or related to such unauthorized reuse, change, or alteration; provided, however, that the ENGINEER will not be indemnified for such claims, damages, losses, and costs including without limitations litigation expenses and attomey fees where caused by the ENGINEER's own acts or omissions. 8.2 The ENGINEER agrees that ownership of any plans, drawings, designs, specifications, computer programs, technical reports, operating manuals, calculations, notes, and other WORK submitted or which are specified to be delivered under this Agreement or which are developed or produced and paid for under this Agreement, whether or not complete, shall be vested in the CITY. SECTION 9 AUDIT AND ACCESS TO RECORDS 9.1 The ENGINEER, including its subconsultants, shall maintain books, records, docu- ments and other evidence directly pertinent to performance of the WORK under this Agreement in accordance with generally accepted accounting principles and practices consistently applied. The CITY or the CITY'S duly authorized representative, shall have access to such books, records, documents, and other evidence for inspection, audit, and copying for a period of three years after completion of the PROJECT. The CITY shall also have access to such books, records, and documents during the performance of the PROJECT WORK if deemed necessary by the CITY to verify the ENGINEER'S WORK and invoices. 9.2 Audits conducted pursuant to this section shall be in accordance with generally accepted auditing standards and established procedures and guidelines of the reviewing or auditing agency. 9.3 The ENGINEER agrees to the disclosure of all information and reports resulting from access to records pursuant to this section provided that the ENGINEER is afforded the opportunity for an audit exit conference and an opportunity to comment and submit any supporting documentation on the pertinent portions of the draft audit report and that the final audit report will include written comments, if any, of the ENGINEER. 9.4 The ENGINEER shall ensure that substantially the foregoing paragraphs are included in each subcontract for WORK on the Project. 9.5 Any charges of the ENGINEER paid by the CITY found by an audit to be inadequately substantiated shall be reimbursed to the CITY. SECTION 10 INSURANCE Page -7 - Professional Services Agreement between the City of Yakima and Sargent Engineers 10.1 Prior to beginning WORK under this Agreement, the ENGINEER shall provide Certificates of Insurance satisfactory to the CITY as evidence that policies providing the following coverage and limits of insurance are in full force and effect. The CITY and the CITY'S directors, officers, principals, employees, representatives, and agents shall be designated as additional insured on all such policies except for professional liability and Worker's Compensation. Such insurance shall be primary to the extent covered as additional insureds and other insurance maintained or carried by the CITY shall be separate and distinct and shall not be contributing with the insurance listed hereunder. 10.1.1 Commercial general liability insurance with a combined single limit for bodily injury and property damage of at least $1,000,000 per occurrence and $2,000,000 aggregate. 10.1.2. Automobile bodily injury and property damage liability insurance covering owned, non -owned, rented, and hired cars. The combined single limit for bodily injury and property damage shall be not less than $1,000,000 per occurrence. 10.1.3. Statutory workers' compensation and employer's liability insurance as required by state law. 10.1.4. Professional liability insurance. The limit of liability shall be not less than $2,000,000. The policy should have a retroactive date prior to the date of this contract or provide full prior acts. The coverage will continue for one year following the completion of the contract. Failure of either or all of the additional insureds to report a claim under such insurance shall not prejudice the rights of the CITY, its officers, employees, agents, and representatives thereunder. The CITY and the CITY'S officers, principals, employees, representatives, and agents shall have no obligation for payment of premiums because of being named as additional insureds under such insurance. None of the policies issued pursuant to the requirements contained herein shall be canceled, allowed to expire, or changed in any manner so as to affect the rights of the City thereunder until thirty (30) days after written notice to the CITY of such intended cancellation, expiration, or change_ Page -8 - Professional Services Agreement between the City of Yakima and Sargent Engineers SECTION 11 SUBCONTRACTS 11.1 ENGINEER shall be entitled, to the extent determined appropriate by ENGINEER, to subcontract any portion of the WORK to be performed under this Agreement. 11.2 Any subconsultants or subcontractors to the ENGINEER utilized on this PROJECT, including any substitutions thereof, will be subject to prior approval by CITY, which approval shall not be unreasonably withheld. Each subcontract shall be subject to review by the CITY'S Representative, if requested, prior to the subconsultant or subcontractor proceeding with the WORK. Such review shall not constitute an approval as to the legal form or content of such subcontract. The ENGINEER shall be responsible for the architectural and engineering performance, acts, and omissions of all persons and firms performing subcontract WORK. 11.3 CITY hereby authorizes the ENGINEER to subcontract with the persons and firms listed below: None anticipated. 11.4 The ENGINEER shall submit, along with its monthly invoices, a description of all WORK completed by subconsultants and subcontractors during the preceding month and copies of all invoices thereto. SECTION 12 ASSIGNMENT 12.1 This Agreement is binding on the heirs, successors, and assigns of the parties hereto. This Agreement may not be assigned by CITY or ENGINEER without prior, written consent of the other, which consent will not be unreasonably withheld. SECTION 13 INTEGRATION 13.1 This Agreement, represents the entire understanding of CITY and ENGINEER as to those matters contained herein. No prior oral or written understanding shall be of any force or effect with respect to those matters covered herein. This Agreement may not be modified or altered except in writing signed by both parties. SECTION 14 JURISDICTION AND VENUE 14.1 This Agreement shall be administered and interpreted under the laws of the State of Washington. Jurisdiction of litigation arising from this Agreement shall be in that state. If any part of this, Agreement is found to conflict with applicable laws, such part shall be inoperative, null, and void insofar as it conflicts with said laws, but the remainder of this Agreement shall be in full force and effect. Venue of all disputes shall be Yakima County, State of Washington. SECTION 15 EQUAL EMPLOYMENT and NONDISCRIMINATION 15.1 In connection with the Services under this Agreement, ENGINEER agrees to comply with the applicable provisions of State and Federal Equal Employment Opportunity and Nondiscrimination statutes and regulations. Page -9 - Professional Services Agreement between the City of Yakima and Sargent Engineers 15.2 During the performance of this Agreement, ENGINEER shall not discriminate in violation of any applicable federal, state and/or local law or regulation on the basis of age, sex, race, creed, religion, color, national origin, marital status, disability, honorably discharged veteran or military status, pregnancy, sexual orientation, and any other classification protected under federal, state, or local law. This provision shall include but not be limited to the following: employment, upgrading, demotion, transfer, recruitment, advertising, layoff or termination, rates of pay or other forms of compensation, selection for training, and the provision of services under this Agreement. SECTION 16 SUSPENSION OF WORK 16.1 CITY may suspend, in writing by certified mail, all or a portion of the WORK under this Agreement if unforeseen circumstances beyond CITY'S control are interfering with normal progress of the WORK ENGINEER may suspend, in writing by certified mail, all or a portion of the WORK under this Agreement if unforeseen circumstances beyond ENGINEER's control are interfering with normal progress of the WORK. ENGINEER may suspend WORK on PROJECT in the event CITY does not pay invoices when due, except where otherwise provided by this Agreement. The time for completion of the WORK shall be extended by the number of days WORK is suspended. If the period of suspension exceeds 90 days, the terms of this Agreement are subject to renegotiation, and both parties are granted the option to terminate WORK on the suspended portion of Project in accordance with SECTION 17. SECTION 17 TERMINATION OF WORK 17.1 Either party may terminate this Agreement, in whole or in part, if the other party materially breaches its obligations under this Agreement and is in default through no fault of the terminating party. However, no such termination may be effected unless the other party is given: (1) not less than fifteen (15) calendar days written notice delivered by certified mail, retum receipt requested, of intent to terminate; and (2) an opportunity for consultation and for cure with the terminating party before termination. Notice shall be considered issued within seventy-two (72) hours of mailing by certified mail to the place of business of either party as set forth in this Agreement. 17.2 In addition to termination under subparagraph A of this Section, CITY may terminate this Agreement for its convenience, in whole or in part, provided the ENGINEER is given: (1) not less than fifteen (15) calendar days written notice delivered by certified mail, retum receipt requested, of intent to terminate; and (2) an opportunity for consultation with CITY before termination. 17.3 If CITY terminates for default on the part of the ENGINEER, an adjustment in the contract price pursuant to the Agreement shall be made, but (1) no amount shall be allowed for anticipated profit on unperformed services or other WORK, and (2) any payment due to the ENGINEER at the time of termination may be adjusted to the extent of any additional costs or damages CITY has incurred, or is likely to incur, because of the ENGINEER'S breach. In such event, CITY shall consider the amount of WORK originally required which was satisfactorily completed to date of termination, whether that WORK is in a form or of a type which is usable and suitable to CITY at the date of termination and the cost to CITY of completing the WORK itself or of employing another firm to complete it. Under no circumstances shall payments made under this provision exceed the contract price. In the event of default, the ENGINEER agrees to pay CITY for any and all damages, costs, and expenses whether directly, Page - 10 - Professional Services Agreement between the City of Yakima and Sargent Engineers indirectly, or consequentially caused by said default. This provision shall not preclude CITY from filing claims and/or commencing litigation to secure compensation for damages incurred beyond that covered by contract retainage or other withheld payments. 17.4 If the ENGINEER terminates for default on the part of CITY or if CITY terminates for convenience, the adjustment pursuant to the Agreement shall include payment for services satisfactorily performed to the date of termination, in addition to termination settlement costs the ENGINEER reasonably incurs relating to commitments which had become firm before the termination, unless CITY determines to assume said commitments. 17.5 Upon receipt of a termination notice under subsections 17.1 or 17.2 above, the ENGINEER shall (1) promptly discontinue all services affected (unless the notice directs otherwise), and (2) deliver or otherwise make available to CITY all originals of data, drawings, specifications, calculations, reports, estimates, summaries, and such other information, documents, and materials as the ENGINEER or its subconsultants may have accumulated or prepared in performing this Agreement, whether completed or in progress, with the ENGINEER retaining copies of the same. 17.6 Upon termination under any subparagraph above, CITY reserves the right to prosecute the WORK to completion utilizing other qualified firms or individuals; provided, the ENGINEER shall have no responsibility to prosecute further WORK thereon. 17.7 If, after termination for failure of the ENGINEER to fulfill contractual obligations, it is determined that the ENGINEER has not so failed, the termination shall be deemed to have been effected for the convenience of CITY. In such event, the adjustment pursuant to the Agreement shall be determined as set forth in subparagraph 17.4 of this Section. 17.8 If, because of death, unavailability or any other occurrence, it becomes impossible for any key personnel employed by the ENGINEER in PROJECT WORK or for any corporate officer of the ENGINEER to render his services to the PROJECT, the ENGINEER shall not be relieved of its obligations to complete performance under this Agreement without the concurrence and written approval of CITY. If CITY agrees to termination of this Agreement under this provision, payment shall be made as set forth in subparagraph 17.3 of this Section. SECTION 18 ARBITRATION 18.1 All claims, counterclaims, disputes, and other matters in question arising out of, or relating to, this AGREEMENT or the breach thereof may be decided by arbitration in accordance with the Construction Industry Arbitration Rules of the American Arbitration Association then obtaining. Either CITY or ENGINEER may initiate a request for such arbitration, but consent of the other party to such arbitration shall be a necessary precondition to arbitration. SECTION 19 NOTICE 19.1 Any notice required to be given under the terms of this Agreement shall be directed to the party at the address set forth below. Notice shall be considered issued and effective upon receipt thereof by the addressee -party, or seventy-two hours after mailing by certified mail to the place of business set forth below, whichever is earlier. Page 11 Professional Services Agreement between the City of Yakima and Sargent Engineers CITY: City of Yakima 2301 Fruitvale Boulevard Yakima, WA 98902 Attn: Mr. David Brown, Water and Irrigation Manager ENGINEER: SARGENT ENGINEERS, INC. 320 Ronlee Lane NW Olympia, WA 98502 Attn: Monte Smith, Principal IN WITNESS WHEREOF, the parties hereto have caused this agreement to be executed by their respective authorized officers or representatives as of the day and year first above written. CITY OF YAKIMA SARGENT ENGINEERS, INC. Signature Printed Name: R. A. Zais, Jr. A / Signaty(re Printed Name: Monte Smith Title: Title: City Manager Date: /0/q/0 Attest Principal Date: /i7/2 7 IO Deborah Kloster, City Clerk CITY CONTRAC f NO. RESOLUTION NO' Page - 12 - Professional Services Agreement between the City of Yakima and Sargent Engineers STATE OF WASHINGTON ) ) ss. COUNTY OF YAKIMA ) I certify that I know or have satisfactory evidence that R.A. Zais, Jr., is the person who appeared before me, and said person acknowledged that he signed this instrument, on oath stated that he was authorized to execute the instrument, and acknowledged it as the City Manager of CITY OF YAKIMA to be the free and voluntary act of such party for the uses and purposes mentioned in the instrument. Dated: H1/1/0 9 Seal or Stamp Printed Name .4/Neff Al - tei6LTKIN p My commission expires: Page - 13 - Professional Services Agreement between the City of Yakima and Sargent Engineers EXHIBIT A CITY OF YAKIMA — FRANKLIN POOL SLIDE EVALUATION SCOPE OF WORK During the term of this AGREEMENT, the ENGINEER shall perform professional services in connection with the following project: City of Yakima — FRANKLIN POOL SLIDE EVALUATION This scope of work shall include the furnishing of all services, labor, materials, equipment, supplies, and incidentals necessary to conduct and complete the work as indicated hereinafter. The work to be performed involves project management, and project formulation, investigation, and preliminary engineering. 1. Observe the condition of the slide. Perform a visual observation of all areas of the slide and its support structure. For areas that are deteriorated, the extent of the deterioration will be quantified. 2. Determine the safe loading for the slide. The results of the observation will be used to determine the strength of the various elements according to the International Building Code. The fixed loads (weight of the structure and water) that are being applied to the various members will be determined. The live load (weight of the people) that can be supported by the slide will be determined by subtracting the fixed loads from the strength. 3. Prepare a report that will document the condition and strength of the slide and suggest any maintenance that should be performed on the slide. Page - 14 - Professional Services Agreement between the City of Yakima and Sargent Engineers EXHIBIT B FRANKLIN POOL SLIDE EVALUATION Professional Fees Compensation for professional services will be on a time spent basis at the specific hourly rates shown on Exhibit C, plus reimbursement for direct non -salary expenses. The following spreadsheet, EXHIBIT B ATTACHMENT, shows the estimated time and expenses to perform the Scope of Services outlined in EXHIBIT A for this FRANKLIN POOL SLIDE EVALUATION work. The maximum amount of compensation to the ENGINEER for this work will be $5,172.00. This maximum amount will not be exceeded without the written agreement of the CITY and the ENGINEER. Page - 15 - Professional Services Agreement between the City of Yakima and Sargent Engineers 1 EXHIBIT C SCHEDULE OF RATES FOR SARGENT ENGINEERS, INC. Principal Engineer $144.00 per hour Senior Engineer $116.00 per hour Senior Project Engineer $107 00 per hour Project Engineer $98.00 per hour Design Engineer $76.00 per hour Drafter II $80.00 per hour Clerical $49.00 per hour Page - 16 - Professional Services Agreement between the City of Yakima and Sargent Engineers SARGENT Sargent knee Inc. 320 Ronlee lane NW Olympia, Washington 98502-9241 Tel 360 867-9284 Fax 380 867-9318 www.saintenginears.00m August 19, 2009 Mr. Brett Sheffield Chief Engineer City of Yakima 129 North Second Street Yakima, WA 98901 RE: Franklin Pool Slide Evaluation Project No.: A09100.00 Dear Mr. Sheffield: At the Franklin Pool you have a slide that was constructed in 1991. The slide is supported by steel columns and beams. The Parks Department has concerns about the safety of the slide. You have asked us to evaluate the slide. Scope of Work We propose to perform the following tasks: • Observe the condition of the slide. We will perform a visual observation of all areas of the slide and its support structure. For areas that are deteriorated, we will quantify the extent of deterioration. • Determine the safe loading for the slide. We will take the results of our observation and determine the strength of the various elements according to the International Building Code. We will then determine the fixed loads (weight of the structure and water) that are being applied to the various members. By subtracting the fixed loads from the strength, we can determine the amount of live load each member can carry. The live load is the weight of people that can be carried by the slide. • Prepare a report documenting the condition and strength of the slide. We will also suggest any maintenance that needs to be performed on the slide. SARGENT Engineering Fees Our fee for performing the above tasks will not exceed: Rate: Mr. Brett Sheffield Page 2 August 19, 2009 Senior Senior Project Project Design Principal Engineer Engineer Engineer Engineer Drafter 11 Clerical Task Cost $144.00 $116.00 $107.00 $98.00 $76.00 $80.00 $49.00 Observe slide 10 $980 Calculate capacities 8 $784 Calculate live loads 16 $1,568 Prepare report 6 $588 Review report and loads 8 $1,152 Total Direct Salary Cost 8 0 0 40 0 0 0 $5,072 Direct Costs Mileage Total Direct Costs $100.00 $100 Total $5,172 Schedule We anticipate that we can complete this work by the end of September if we are given a notice to proceed by the fust of September. We look forward to assisting you with this project; please call if you have any questions. Sincerely, Sargent Engineers, Inc. yw/ Monte Smith Principal MJS 1\Serverl \files\MonteS\My Documents\Yakima\Franklin.docx • • ITEM TITLE: BUSINESS OF THE CITY COUNCIL YAKIMA, WASHINGTON AGENDA STATEMENT Item No. 12 For Meeting of October 6, 2009 Consideration of a Resolution authorizing a consulting agreement with Sargent Engineers Inc. to evaluate the safety of the water slide at Franklin Pool SUBMITTED BY: Chris Waarvick, Director of Public Works Ken Wilkinson, Parks and Recreation Manager CONTACT PERSON/TELEPHONE: Ken Wilkinson, 575-6020 SUMMARY EXPLANATION: Due to the age and condition of the water slide at Franklin Pool, staff requests Council consideration and approval of a consultant agreement with Sargent Engineers, Inc. to evaluate the condition of the water slide and its support structure. The water slide is highly used during the summer swimming season and appears to be showing signs of deterioration. If Council approves this item, Sargent Engineers, Inc. will observe the condition of the slide and prepare a detailed report. The results of this evaluation will quantify the extent of deterioration and determine how much weight the water slide can carry, in other words, what the safe Toad limit is for the water slide at Franklin Pool. The engineering fee to evaluate the pool slide is estimated to be approximately $5,200. Resolution X Ordinance Other (Specify Scope of Work Agreement Funding Source: Parks and Recreation Capital Fund—$5,200 APPROVED FOR SUBMITTAL: City Manager STAFF RECOMMENDATION: Staff respectfully requests City Council adoption of the attached Resolution authorizing execution of a consulting agreement between the City of Yakima and Sargent Engineers, Inc. BOARD/COMMISSION/COMMITTEE RECOMMENDATION: COUNCIL ACTION: ' 4C9Rb CERTIFICATE OF LIABILITY INSURANCE OPID CUSARDATE GMAT (MM/DD/YY 09 INFORMATIOh EXTEND OR BELOW PRODUCER Western States - The Dalles 101 E. Third St., PO Box 1940 The Dalies OR 97058 Phone: 541-296-2268 Fax: 541-296-9427 THIS CERTIFICATE 1S ISSUED AS A OF ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, ALTER THE COVERAGE AFFORDED BY THE POLICIES INSURERS AFFORDING COVERAGE NAIC # INSURED Sargent Engineers 320 Ronlee Lane NW Olympia WA 98502 I Inc INSURER A' U. S Specialty Insurance Co 52SBAVW7185 INSURER & The Hartford Insurance EACH OCCURRENCE INSURER C: PREMISEs(Eaoccurence) $ 1,000,000 INSURER D: CLAIMS MADE X OCCUR MED EXP (Any one person) INSURER E COVERAGES THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR ADD'L. INSRC TYPE OF INSURANCE POLICY NUMBER POLICY EFFECTIVE DATE (MM/DD/YYYY) POLICY EXPIRATION DATE (MM/DD/YYYY) LIMITS B X GENERAL X LIABILITY COMMERCIAL GENERAL LIABILITY 52SBAVW7185 02/21/09 02/21/10 EACH OCCURRENCE $1,000,000 PREMISEs(Eaoccurence) $ 1,000,000 CLAIMS MADE X OCCUR MED EXP (Any one person) $10,000 PERSONAL 8 ADV INJURY $1,000,000 GENERAL AGGREGATE $2,000,000 GEN'L AGGREGATE LIMIT APPLIES PER' 7 POLICY PRO LOC JECT PRODUCTS - COMP/OP AGG $ 2,000,000 B AUTOMOBILE X X LIABILITY ANY AUTO ALL OWNED AUTOS SCHEDULED AUTOS HIRED AUTOS' NON -OWNED AUTOS 52UECIV4082 02/21/09 02/21/10 COMBINED SINGLE LIMIT (Ea accident) $1,000,000 BODILY INJURY (Per person) _ $ BODILY INJURY (Per accident) PROPERTY DAMAGE (Per accident) $ GARAGE LIABILITY ANY AUTO --- AUTO ONLY - EA ACCIDENT $ OTHER THAN EA ACC $ AUTO ONLY' AGG $ EXCESS / UMBRELLA LIABILITY OCCUR CLAIMS MADE DEDUCTIBLE RETENTION $ EACH OCCURRENCE $ AGGREGATE $ $ $ $ WORKERS COMPENSATION ANDEMPLOYERS' LIABILITY Y / N ANY PROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? (Mandatory in NH) If yes, describe under SPECIAL PROVISIONS below WG SIM U- 01H /HAND TORY LIMITS ER E.L EACH ACCIDENT $ E.L. DISEASE - EA EMPLOYEE $ E.L DISEASE - POLICY LIMIT $ A OTHER PROF LIABILITY US081136704 08/16/09 08/16/10 EA CLAIM 2,000,000 ANN AGG 2,000,000 DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES / EXCLUSIONS ADDED BY ENDORSEMENT / SPECIAL PROVISIONS The certificate holder is an additional insured as per written agreement between the insured and their client on the general liability policy as respects to liability arising out of activities by or on behalf of the named insured. This insurance is primary and non-contributory. Project: Franklin Pool Slide Evaluation CERTIFICATE HOLDER CANCELLATION City of Yakima- City Clerk Attn: Linda Watkins 129 North Second Street (Yakima WA 98901 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TO MAIL 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, BUT FAILURE TO DO SO SHALL IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE INSURER, ITS AGENTS OR REPRESENTATIVES. AUTHORIZED REPRESENTATIVE NolaI" Qin ACORD 25 (2009/01) ©1988-20'SACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD IMPORTANT If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s) If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). DISCLAIMER This Certificate of Insurance does not constitute a contract between the issuing insurer(s), authorized representative or producer, and the certificate holder, nor does it affirmatively or negatively amend, extend or alter the coverage afforded by the policies listed thereon ACORD 25 (2009/01) e o�® _gr��s�'�j��../��/0//OJ�llOo CERTIFICATE OF LIABILITY INSURANCE OP ID CU SARGE-4 DATE (MM/DD/YYYY) 03/11/10 OF INFORIVIATIOts CERTIFICATE EXTEND OR POLICIES BELOW PRODUCER Western States - The Dailes 101 E. Third St., PO Box 1940 The Dalles OR 97058 Phone: 541-296-2268 Fax: 541-296-9427 THIS CERTIpICATE1S ISSUED AS A ONLY AND CONFERS NO RIGHTS UPON THE HOLDER. THIS CERTIFICATE DOES NOT AMEND, ALTER THE COVERAGE AFFORDED BY THE INSURERS AFFORDING COVERAGE , NAIC # INSURED Sargent Engineers Inc 320 Ronlee Lane Nov Olympia WA 98502 1 INSURER A. U S. Specialty Insurance Co B INSURER B: The Hartford Insurance GENERAL X INSURER C. 52SBAVW7185SC INSURER D: 02/21/11 INSURER E. $1,000,000 COVERAGES THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR ADD2. INSRC TYPE OF INSURANCE POLICY NUMBER POLICY EFFECTIVE DATE (MM/DD/YYYY) POLICY EXPIRATION DATE (MMIDD/YYYY) LIMITS B X GENERAL X LIABILITY COMMERCIAL GENERAL LIABILITY 52SBAVW7185SC 02/21/10 02/21/11 EACH OCCURRENCE $1,000,000 UAMAGt IV KtNItU PREMISES(Eaoccurence) $ 1,000,000 CLAIMS MADE 1X I OCCUR MED EXP (Any one person) $10,000 PERSONAL BADV INJURY $ 1,000,000 GENERAL AGGREGATE $2,000,000 GEN'L 7 AGGREGATE LIMIT APPLIES PER: PRODUCTS - COMP/OP AGG $ 2,000,000 POLICY PRO- JECT $ AUTOMOBILE X LIABILTY ANY AUTO ALL OWNED AUTOS SCHEDULED AUTOS HIRED AUTOS NON -OWNED AUTOS 52UECIV4082SC 02/21/10 02/21/11 COMBINED SINGLE LIMIT (Ea accident) $1,000,000 BODILY INJURY (Per person) BODILY INJURY (Per accident) PROPERTY DAMAGE (Per accident) $ GARAGE LIABILITY ANY AUTOOTHER AUTO ONLY - EA ACCIDENT $ THAN EA ACC $ AUTO ONLY- AGG $ $ EXCESS X / UMBRELLA LIABILITY OCCUR CLAIMS MADE 52SBAVW7185SC 02/21/10 02/21/11 EACH OCCURRENCE $2,000,000 AGGREGATE $2,000,000 DEDUCTIBLE RETENTION $ $ $ $ B WORKERS COMPENSATIONWCSIAIU- AND EMPLOYERS' LIABILITY ANY PROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? (Mandatory in NH) If yes, describe under SPECIAL PROVISIONS below 52WECZ08094 05/01/09 05/01/10 01 -H- 'TORY LIMITS ER E.L. EACH ACCIDENT $ 1,000,000 E.L. DISEASE - EA EMPLOYEE $ 1,000,000 E.L. DISEASE - POLICY LIMIT $ 1,000,000 A OTHER PROF LIABILITY US081136704 08/16/09 08/16/10 EA CLAIM 2,000,000 ANN AGG 2,000,000 DESCRIPTION OF OPERATIONS / LOCATIONS 1 VEHICLES / EXCLUSIONS ADDED BY ENDORSEMENT 1 SPECIAL PROVISIONS The certificate holder is an additional insured as per written agreement between the insured and their client on the general liability policy as respects to liability arising out of activities by or on behalf of the named insured. This insurance is primary and non-contributory. Project: Franklin Pool Slide Evaluation CERTIFICATE HOLDER CANCELLATION ACORD 25 (2009/01) -2009 ACORD CORPORATION. All rlgnts reserves. The ACORD name and logo are registered marks of ACORD SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TO MAIL 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, BUT FAILURE TO DO SO SHALL IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE INSURER, ITS AGENTS OR City of Yakima- City Clerk Attn: Linda Watkins REPRESENTATIVES. 129 North Second Street AUTHORIZED REPRESENTATIVE Yakima WA 98901 j/;�,, ➢7 t 00.('ft/i(tr- 4..51 /(IA ---- -- -----. ... . .. . ACORD 25 (2009/01) -2009 ACORD CORPORATION. All rlgnts reserves. The ACORD name and logo are registered marks of ACORD IMPORTANT If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). DISCLAIMER This Certificate of Insurance does not constitute a contract between the issuing insurer(s), authorized representative or producer, and the certificate holder, nor does it affirmatively or negatively amend, extend or alter the coverage afforded by the policies listed thereon. ACORD 25 (2009/01) N4-('vv7 —/f j' TR® CERTIFICATE OF LIABILITY INSURANCE OPID 4 DATE (MM/DD/YYYY) " 02/28/11 PRODUCER Western States - The Dalles 101 E. Third St., PO Box 1940 The Dalles OR 97058 Phone: 541-296-2268 Fax:541-296-9427 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. INSURERS AFFORDING COVERAGE NAIC # INSURED Sargent Engineers,_ Inc 320 Ronlee Lane NW Olympia WA 98502 .. - I . - - .- . - - INSURER A. U.S. Specialty Insurance Co B INSURER B: The Hartford Insurance GENERAL INSURER C: 52SBAVW7185SC INSURER D: 02/21/12 INSURER E: - - COVERAGES THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INR LTR ADD'L INSRC TYPE OF INSURANCE POLICY NUMBER POLICY EFFECTIVE DATE-(MM/DD/YYYY) POLICY EXPIRATION DATE (MMIDD/YYYY) LIMITS B X GENERAL LIABILITY COMMERCIAL GENERAL LIABILITY 52SBAVW7185SC 02/21/11 02/21/12 EACH OCCURRENCE $1,000,000 X PREMISES (Ea occurence) $1,000,000 CLAIMS MADE X OCCUR MED EXP (Any one person) $10,000 PERSONAL &ADV INJURY $ 1,000,000 GENERAL AGGREGATE $2,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS - COMP/OP AGG $ 2 , 000 , 00 0 PRO - POLICY ECT LOC WA STP GA 1,000,000 $ $ AUTOMOBILE LIABILITY ANY AUTO ALL OWNED AUTOS SCHEDULED AUTOS HIRED AUTOS NON -OWNED AUTOS 52UECIV4082SC 52UECIV4082SC 02/21/11 02/21/11 02/21/12 02/21/12 SINGLE LIMIT (Ea accident) $1,000,000 X BODILY INJURY (Per person) X BODILY INJURY (Per accident) $ X PROPERTY DAMAGE (Per accident) GARAGE LIABILITY ANY AUTOOTHER AUTO ONLY - EA ACCIDENT $ THAN EA ACC $ AUTO ONLY' AGG $ $ EXCESS / UMBRELLA LIABILITY 52SBAVW7185SC _ 02/21/11 02/21/12 EACH OCCURRENCE $2,000,000 X OCCUR CLAIMSMADE AGGREGATE $2,000,000 DEDUCTIBLE RETENTION, $ $ $ $ B WORKERS AND EMPLOYERS' ANY AFYIPROPRIETOR (Mandatory if yes, describe SPECIAL COMPENSATION' LIABILITY Y / N 52WECZ08094 05/01/10 -- 05/01/11 WC STAT U= Ol H- TORY LIMITS ER E.L. EACH ACCIDENT $1,000,000 EXCLNER/E ECUTIVE— E.L. DISEASE - EA EMPLOYEE $ 1 , 000 , 000 in NH) under PROVISIONS below E.L. DISEASE - POLICY LIMIT $ 1 , 000 , 000 A OTHER PROF LIABILITY US081136704 08/16/10 " 08/16/11 EA CLAIM 2,000,000 ANN AGG 2,000,000 DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES / EXCLUSIONS ADDED BY ENDORSEMENT / SPECIAL PROVISIONS CERTIFICATE HOLDER CANCELLATION ACORD 25 (2009/01) CAll rights reserved. The ACORD name and logo are registered marks of ACORD SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TO MAIL 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, BUT FAILURE TO DO SO SHALL IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE INSURER, ITS AGENTS OR City of Yakima- City Clerk Attn: Linda Watkins 129 North Second Street REPRESENTATIVES. AUTHORIZED REPRESENTATIVE iYakima WA 98901. . .IT ---Th Jf A i . I ACORD 25 (2009/01) CAll rights reserved. The ACORD name and logo are registered marks of ACORD IMPORTANT If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s) If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). DISCLAIMER This Certificate of Insurance does not constitute a contract between the issuing insurer(s), authorized representative or producer, and the certificate holder, nor does it affirmatively or negatively amend, extend or alter the coverage afforded by the policies listed thereon. ACORD 25 (2009101) NOTEPAD: HOLDER CODE INSURED'SNAME Sargent Engineers, Inc SARGE-4 OP ID SN PAGE 3 DATE 02/28/11 The certificate holder is an additional insured as per written agreement between the insured and their client (City of Yakima) on the general liability policy as respects to liability arising out of activities by or on behalf of the named insured. This insurance is primary and non-contributory. Per the attached policy form SS 00 08 04 05 Project: Franklin Pool Slide Evaluation • BUSINESS LIABILITY COVERAGE FORM Various provisions in this policy restrict coverage.: Read the entire policy carefully to determine rights, duties and what is and is not covered. Throughout this policy the words "you" and "your" refer to the Named Insured shown in the Declarations The words "we", "us" and "our" refer to the stock insurance company member of The Hartford providing this insurance. The word "insured" means any person or organization qualifying as such under Section C. - Who Is An Insured. Other words and phrases that appear in quotation marks have special meaning. Refer:to Section G. - Liability And tn Ln Medical Expenses Definitions. 0 *0500252z083870101 WIC MEM onk UMU MEM MEM EMM OEM MEM t MMWMUM A. COVERAGES 1. BUSINESS LIABILITY COVERAGIE (BODILY INJURY, PROPERTY DAMAGE, PERSONAL AND ADVERTISING INJURY) Insuring Agreement a. We will pay those sums that the insured becomes legally obligated to pay as damages because of "bodily injury", "property damage" or "personal and advertising injury" to which this insurance applies. We will have the right and duty 10 defend the insured against any "suit" seeking those damages. However, we will have no duty to defend the insured against any "suit" seeking damages for "bodily injury", "property damage" or "personal and advertising injury" to which this insurance does not apply. We may, at our discretion, investigate any "occurrence" or offense and settle any claim or "suit" that may result. But: (1) The amount we will pay for damages is limited as described in Section D. - Liability And Medical Expenses Limits Of Insurance; and (2) Our right and duty to defend ends when we have used up the applicable limit of insurance in the payment of judgments, settlements or medical expenses to which this insurance applies. No other obligation or liability to pay sums or perform acts or services is covered unless explicitly provided for under Coverage Extension- Supplementary Payments. b. This insurance applies: (1) To "bodily injury" and "property damage" only if: (a) The "bodily injury" or "property damage" is caused by an "occurrence" that takes place in the "coverage territory"; (b) The "bodily injury" or "property damage" occurs during the policy period; and (c) Prior to the policy period, no insured listed under Paragraph 1. of Section C. — Who Is An Insured and no "employee" authorized by you to give or receive notice of an "occurrence" or claim, knew that the "bodily injury" or "property damage" had occurred, in whole or in part. If such a listed insured or authorized "employee" knew, prior to the policy period, that the "bodily injury" or "property damage" occurred, then any continuation, change or resumption of such "bodily injury" or "property damage" during or after the policy period will be deemed to have been known prior to the policy period. (2) To "personal and advertising injury" caused by an offense arising out of your business, but only if the offense was committed in the "coverage territory" during the policy period. c. "Bodily injury" or "property damage" will be deemed to have been known to have occurred at the earliest time when any insured listed under Paragraph 1. of Section C. — Who Is An Insured or any "employee" authorized by you to give or receive notice of an "occurrence" or claim: (1) Reports all, or any part, of the "bodily injury" or "property damage" to us or any other insurer; Form SS 00 08 04 05 Page 1 of 24 © 2005, The Hartford BUSINESS LIABILITY COVERAGE FORM (2) Receives a written or verbal demand or claim for damages because of the "bodily injury" or "property damage"; or (3) Becomes aware by any other means that "bodily injury" or "property damage" has occurred or has begun to occur. d. Damages because of "bodily injury" include damages claimed by any person or organization for care, Toss of services or death resulting at any time from the "bodily injury". e. Incidental Medical Malpractice (1) "Bodily injury" -arising out of the rendering of or failure to render professional health care services as a physician, dentist, nurse, emergency medical technician or paramedic shall be deemed to be caused by an "occurrence", but only if: (a) The physician, dentist, nurse, emergency medical technician or paramedic is employed by you to provide such services; and (b) You are not engaged in the business or occupation of providing such services. (2) For the purpose of determining the limits of insurance for incidental medical malpractice, any act or omission together with all related acts or omissions in the fumishing of these services to any one person will be considered one "occurrence". 2. MEDICAL EXPENSES Insuring Agreement a. We will pay medical expenses as described below for "bodily injury" caused by an accident: (1) On premises you own or rent; (2) On ways next to premises you own or rent; or (3) Because of your operations; provided that: (1) The accident takes place in the "coverage territory" and during the policy period; (2) The expenses are incurred and reported to us within three years of the date of the accident; and (3) The injured person submits to examination, at our expense, by physicians of our choice as often as we reasonably require. Page 2 of 24 b. We will make these payments regardless of fault. These payments will not exceed the . _applicable limit of insurance We will pay reasonable expenses for: (1) First aid administered at the time of an accident; (2) Necessary medical, surgical, x-ray and dental services, including prosthetic devices; and (3) Necessary ambulance, hospital, professional nursing and funeral services. - 3. COVERAGE EXTENSION - SUPPLEMENTARY PAYMENTS a. We will pay, with respect to any claim or "suit" we investigate or settle, or any "suit" against an insured we defend. (1) All expenses we incur. (2) Up to $1,000 for the cost of bail bonds required because of accidents or traffic law violations arising out of the use of any vehicle to which Business Liability Coverage for "bodily injury" applies. VVe do not have to fumish these bonds. (3) The cost of appeal bonds or bonds to release attachments, but only for bond amounts within the applicable limit of insurance. VVe do not have to furnish these bonds. (4) All reasonable expenses incurred by the insured at our request to assist us in the investigation or defense of the claim or "suit", including actual loss of eamings up to $500 a day because of time off from work. (5) All costs taxed against the insured in the "suit". (6) Prejudgment interest awarded against the insured on that part of the judgment we pay. If we make an offer to pay the applicable limit of insurance, we will not pay any prejudgment interest based on that period of time atter the offer. (7) All interest on the full amount of any judgment that accrues after entry of the judgment and before we have paid, offered to pay, or deposited in court the part of the judgment that is within the applicable limit of insurance. Any amounts paid under (1) through (7) above will not reduce the limits of insurance. Form SS 00 08 04 05 N in 0 *05.00252ZQ83870101 MEM MGR b. If we defend an insured against a "suit" and an indemnitee of the insured is also named as a party to the "suit", we will defend that indemnitee if all of the following conditions are met: (1) The "suit" against the indemnitee seeks damages for which the insured has assumed the liability of the indemnitee in a contract or agreement that is an "insured contract"; (2) This insurance applies to such liability assumed by the insured; (3) The obligation to defend, or the cost of the defense of, that indemnitee, has also been assumed by the insured in the same "insured contract"; (4) The allegations in the "suit" and the information we know about the "occurrence" are such that no conflict appears 10 exist between the interests of the insured and the interest of the indemnitee; (5) The indemnitee and the insured ask us to conduct and control the defense of that indemnitee against such "suit" and agree that we can assign the same counsel to defend the insured and the indemnitee; and (6) The indemnitee: nwe (a) Agrees in writing to: GEC (i) Cooperate with us in the investigation, settlement or defense of the "suit"; (ii) Immediately send us copies of any demands, notices, summonses or legal papers MOM received in connection with MOM EMS the "suit"; (iii) Notify any other insurer whose coverage is available to the aina indemnitee; and (iv) Cooperatewith us with respect to coordinating other applicable insurance available to the indemnitee; and (b) Provides us with written authorization 1o: (i) Obtain records and other information related to the "suit"; and (ii) Conduct and control the defense of the indemnitee in such "suit". Form SS 00 08 04 05 BUSINESS LIABILITY COVERAGE FORM So long as the above conditions are met, attorneys' fees incurred by us in the defense of that indemnitee, necessary litigation expenses incurred by us and necessary litigation expenses incurred by the indemnitee at our request will be paid as Supplementary Payments. Notwithstanding the provisions of Paragraph 1.b.(b) of Section B. — Exclusions, such payments will not be deemed to be damages for "bodily injury" and "property damage" and will not reduce the Limits of Insurance. Our obligation to defend an insured's indemnitee and to pay for attorneys' fees and necessary litigation expenses as Supplementary Payments ends when: (1) We have used up the applicable limit of insurance in the payment of judgments or settlements; or (2) The conditions set forth above, or the temps of the agreement described in Paragraph (6) above, are no longer met., B. EXCLUSIONS 1. Applicable To Business Liability Coverage This insurance does not apply to: a. Expected Or Intended Injury (1) "Bodily injury" or "property damage" expected or intended from the standpoint of the insured. This exclusion does not apply to "bodily injury" or "property damage" resulting from the use of reasonable force to protect persons or property; or (2) "Personal and advertising injury" arising out of an offense committed by, at the direction of or with the consent or acquiescence of the insured with the expectation of inflicting "personal and advertising injury". b. Contractual Liability (1) "Bodily injury" or "property damage"; or (2) "Personal and advertising injury" for which the insured is obligated to pay damages by reason of the assumption of liability in a contract or agreement. This exclusion does not apply to liability for damages because of: (a) "Bodily injury", "property damage" or "personal and advertising injury" that the insured would have in the absence of the contract or agreement; or Page 3 of 24 BUSINESS LIABILITY COVERAGE FORM (b) "Bodily injury" or "property damage" assumed in a contract or agreement that is an "insured contract", provided the "bodily injury" or "property damage" occurs subsequent to the execution of the contract or agreement. Solely for the purpose of liability assumed in an "insured contract", reasonable attorneys' fees and necessary litigation expenses incurred by or for a party other than an insured are deemed to be damages because of "bodily injury" or "property damage" provided: (i) Liability to such party for, or for the cost of, that party's defense has also been assumed in the same "insured contract", and (ii) Such attorneys' fees and litigation expenses are for defense of that party against a civil or alternative dispute resolution proceeding in which damages to which this insurance applies are alleged. c. Liquor Liability "Bodily injury" or "property damage" for which any insured may be held liable by reason of: (1) Causing or contributing to the intoxication of any person; (2) The furnishing of alcoholic beverages to a person under the legal drinking age or under the influence of alcohol; or (3) Any statute, ordinance or regulation relating to the sale, gift, distribution or use of alcoholic beverages. This exclusion applies only if you are in the business of manufacturing, distributing, selling, serving or fumishing alcoholic beverages. d. Workers' Compensation And Similar Laws Any obligation of the insured under a workers' compensation, disability benefits or unemployment compensation law or any similar law. e. Employer's Liability "Bodily injury" to: (1) An "employee" of the insured arising out of and in the course of: (a) Employment by the insured; or (b) Performing duties related to the conduct of the insured's business, or . (2) The spouse, child, parent, brother or sister of that "employee" as a consequence of (1) above. This exclusion applies: (1) 1Nhether the insured may be liable as an employer or in any other capacity; and (2) To any obligation to share damages with or repay someone else who must pay damages because of the injury. This exclusion does not apply to liability assumed by the insured under an "insured contract". f. Pollution (1) "Bodily injury", "property damage" or "personal and ._ advertising injury" arising out of the actual, alleged or threatened discharge, dispersal, seepage, migration, release or escape of "pollutants": (a) At or from any premises, site or location which is or was at any time owned or occupied by, or rented or loaned to any insured. However, this subparagraph does not apply to: (i) "Bodily injury" if sustained within a building and caused by smoke, fumes, vapor or soot produced by or originating from equipment that is used to heat, cool or dehumidify the building, or equipment that is used to heat water for personal use, by the building's occupants or their guests; (ii) "Bodily injury" or "property damage" for which you may be held liable, if you are a contractor and the owner or lessee of such premises, site or location has been added to your policy as an additional insured with respect to your ongoing operations performed for that additional insured at that premises, site or location and such premises, site or location is not and never was owned or occupied by, or rented or loaned to, any insured, other than that additional insured; or Page 4 of 24 Form SS 00 08 04 05 0 *0500252ZQ83870101 MIM MEE EEM MIM CEM ECIE MOM MINS MEE s S MINIM (iii) "Bodily injury" or "property damage" arising out of heat, smoke or fumes from a ."hostile fire"; (b) At or from any premises, site or location which is or was at any time. used by or for any insured or others for the handling, storage, disposal, processing or treatment of waste; (c) Which are or were at any time transported, -handled, stored, treated, disposed of, or processed as waste by or for: (i) Any insured; or (ii) Any person or organization for whom you may be legally responsible; (d) At or from any premises, site or location on which any insured or any contractors or subcontractors working directly or indirectly on any insured's behalf are performing operations if the "pollutants" are brought on or to the premises, site or location in connection with such operations by such insured, contractor or subcontractor. However, this subparagraph does not apply to: (i) "Bodily injury" or "property damage" arising out of the escape of fuels, lubricants or other operating fluids which are needed to perform the normal electrical, hydraulic or mechanical functions necessary for the operation of "mobile equipment" or its parts, if such fuels, lubricants or other operating fluids escape from a vehicle part designed to hold, store or receive them. This exception does not apply if the "bodily injury" or "property damage" arises out of the intentional discharge, dispersal or release of the fuels, lubricants or other operating fluids, or if such fuels, lubricants or other operating fluids are brought on or to the premises, site or location with the intent that they be discharged, dispersed or BUSINESS LIABILITY COVERAGE FORM released as part of the operations being performed by such insured, contractor or subcontractor; (ii) "Bodily injury" or "property damage" sustained within a building and caused by the release of gases, fumes or vapors from materials brought into that building in connection with operations being performed by you or on your behalf by a contractor or subcontractor, or (iii) "Bodily injury" or "property - damage" arising out of heat, smoke or fumes from a "hostile fire"; or (e) At or from any premises, site or location on which any insured or any contractors or subcontractors working directly or indirectly on any insured's behalf are performing operations if the operations are to test for, monitor, clean up, remove, contain, treat, detoxify or neutralize, or in any way respond to, or assess the effects of, "pollutants". (2) Any loss, cost or expense arising out of any: (a) Request, demand, order or statutory or regulatory requirement that any insured or others test for, monitor, clean up, remove, contain, treat, detoxify or neutralize, or in any way respond to, or assess the effects of, "pollutants"; or (b) Claim or suit by or on behalf of a governmental authority for damages because of testing for, monitoring, cleaning up, removing, containing, treating, detoxifying or neutralizing, or in any way responding to, or assessing the effects of, "pollutants". However, this paragraph does not apply 10 liability for damages because of "property damage" that the insured would have in the absence of such request, demand, order or statutory or regulatory requirement, or such claim or "suit" by or on behalf of a govemmental authority. Form SS 00 08 04 05 Page 5 of 24 BUSINESS LIABILITY COVERAGE FORM g• Aircraft, Auto Or Watercraft "Bodily injury" or "property damage" arising out of the ownership, maintenance, use or entrustment to others of any aircraft, "auto" or watercraft owned or operated by or rented or loaned to any insured. Use includes operation and "loading or unloading". This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by that insured, if the "occurrence"- which caused the "bodily injury" or "property damage" involved the ownership, maintenance, use or entrustment to others of any aircraft, "auto" or watercraft that is owned or operated by or rented or loaned to any insured. This exclusion does not apply to: (1) A watercraft while ashore on premises you own or rent; (2) A watercraft you do not own that is: (a) Less than 51 feet long; and (b) Not being used to carry persons for a charge; (3) Parking an "auto" on, or on the ways next to, premises you own or rent, provided the "auto" is not owned by or rented or loaned to you or the insured; (4) Liability assumed under any "insured contract" for the ownership, maintenance or use of aircraft or watercraft; (5) "Bodily injury" or "property damage" arising out of the operation of any of the equipment listed in Paragraph f.(2) or f.(3) of the definition of "mobile equipment"; or (6) An aircraft that is not owned by any insured and is hired, chartered or loaned with a paid crew. However, this exception does not apply if the insured has any other insurance for such "bodily injury" or "property damage", whether the other insurance is primary, excess, contingent or on any other basis. h. Mobile Equipment "Bodily injury" or "property damage" arising out of: (1) The transportation of "mobile equipment" by an "auto" owned or operated by or rented or loaned to any insured; or Page 6 of 24 (2) The use of "mobile equipment" in, or while in practice or preparation for, a . prearranged racing, speed or demolition contest or in any stunting activity. i. War "Bodily injury", "property damage" or "personal and advertising injury": - however caused, arising, directly or indirectly, out of: (1) War, including undeclared or civil war; (2) Warlike action by a military force, including action in hindering or defending against an actual or expected attack, by any government, sovereign or other authority using military personnel or other agents; or (3) Insurrection, rebellion, revolution, usurped power, or action taken by govemmental authority in hindering or defending against any of these. j. Professional Services "Bodily injury", "property damage" or "personal and advertising injury" arising out of the rendering of or failure to render any professional service. This includes but is not limited to: (1) Legal, accounting or advertising services; (2) Preparing, approving, or failing to prepare or approve maps, shop drawings, opinions, reports, surveys, field orders, change orders, designs or drawings and specifications; (3) Supervisory, inspection, architectural or engineering activities; (4) Medical, surgical, dental, x-ray or nursing services treatment, advice or instruction; (5) Any health or therapeutic service treatment, advice or instruction; (6) Any service, treatment, advice or instruction for the purpose of appearance or skin enhancement, hair removal or replacement or personal grooming; (7) Optical or hearing aid services including the prescribing, preparation, fitting, demonstration or distribution of ophthalmic lenses and similar products or hearing aid devices; Form SS 00 08 04 05 *0500252Z03870101 MOM MM ONW MEM aiMM MEE ZCS (8) Optometry or optometric services including but not limited to examination of the eyes and the prescribing, preparation, fitting,demonstration or distribution of ophthalmic lenses and similar products; (9) Any: (a) Body piercing (not includingear piercing); (b) Tattooing, including but not limited to the insertion of pigments into or under the skin; and (c) Similar services; (10) Services in the practice of pharmacy; and (11) Computer consulting, design or programming services, including web site design. Paragraphs (4) and (5) of this exclusion do not apply to the Incidental Medical Malpractice coverage afforded under Paragraph 1.e. in Section A. - Coverages. k. Damage To Property "Property damage" to: (1) Property you own, rent or occupy, including any costs or expenses incurred by you, or any other person, organization or entity, for repair, replacement, enhancement, restoration or maintenance of such property for any reason, including prevention of injury to a person or damage to another's property; (2) Premises you sell, give away or abandon, if the "property damage" arises out of any part of those premises; (3) Property loaned to you; (4) Personal property in the care, custody or control of the insured; That particular part of real property on which you or any contractors or subcontractors working directly or indirectly on your behalf are performing operations, if the "property damage" arises out of those operations; or (6) That particular part of any property that must be restored, repaired or replaced because "your work" was incorrectly performed on it. (5) BUSINESS LIABILITY COVERAGE FORM Paragraphs (1), (3) and (4) of this exclusion do not apply to "property damage" (other than damage by fire) to premises, including the contents of such premises, rented to you for a period of 7 or fewer consecutive days. A separate Limit of Insurance applies to Damage To Premises Rented To You as described in Section D. - Limits Of Insurance. Paragraph (2) of this exclusion does not apply if the premises are "your work" and were never occupied, rented or held for rental by you. Paragraphs (3) and (4) of this exclusion do not apply to the use of elevators. Paragraphs (3), (4), (5) and (6) of this exclusion do not apply to liability assumed under a sidetrack agreement. Paragraphs (3) and (4) of this exclusion do not apply to "property damage" to borrowed equipment while not being used to perform operations at a job site. Paragraph (6) of this exclusion does not apply to "property damage" included in the "products -completed operations hazard". I. Damage To Your Product "Property damage" to "your product" arising out of it or any part of it. m. Damage To Your Work "Property damage" to "your work" arising out of it or any part of it and included in the "products -completed operations hazard". This exclusion does not apply if the damaged work or the work out of which the damage arises was performed on your behalf by a subcontractor. n. Damage To Impaired Property Or Property Not Physically Injured "Property damage" to "impaired property" or property that has not been physically injured, arising out of: (1) A defect, deficiency, inadequacy or dangerous condition in "your product" or "your work"; or (2) A delay or failure by you or anyone acting on your behalf to perform a contract or agreement in accordance with its terms. This exclusion does not apply to the loss of use of other property arising out of sudden and accidental physical injury to "your product" or "your work" after it has been put to its intended use. Form SS 00 08 04 05 Page 7 of 24 BUSINESS LIABILITY COVERAGE FORM o. Recall Of Products, Work Or Impaired Property Damages claimed for any loss, cost or expense incurred by you or others for the Toss of use, withdrawal, recall, inspection, repair, replacement, adjustment, removal or disposal of: - (1) "Your product"; (2) "Your work"; or (3) "Impaired property"; if such produd, work or property is withdrawn or -recalled from the market or from use by any person or organization because of a known or suspected defect, deficiency, inadequacy or dangerous condition in it. p. Personal And Advertising Injury "Personal and advertising injury": (1) Arising out of oral, written or electronic publication of material, if done by or at the direction of the insured with knowledge of its falsity; (2) Arising out of oral, written or electronic publication of material whose first publication took place before the beginning of the policy period; (3) Arising out of a criminal act committed by or at the direction o1 the insured; (4) Arising out of any breach of contract, except an implied contract to use another's "advertising idea" in your "advertisement"; (5) Arising out of the failure of goods, products or services to conform with any statement of quality or performance made in your "advertisement"; (6) Arising out of the wrong description of the price of goods, products or services; (7) Arising out of any violation of any intellectual properly rights such as copyright, patent, trademark, trade name, trade secret, service mark or other designation of origin or authenticity. However, this exclusion does not apply to infringement, in your "advertisement", of (a) Copyright; (b) Slogan, unless the slogan is also a trademark, trade name, service mark or other designation of origin or authenticity; or (c) Title of any literary or artistic work; (8) Arising out of an offense committed by - an insured whose business is: (a) Advertising, broadcasting, publishing or telecasting; (b) Designing or determining content of web sites for others; or (c) An Internet search, access, content or service provider. However, this exclusion does not apply to Paragraphs a., b. and c. under the definition of "personal and _ advertising injury" in Section G. — Liability And Medical Expenses Definitions. For the purposes of this exclusion, placing an "advertisement" for or linking to others on your web site, by itself, is not considered the business of advertising, broadcasting, publishing or telecasting; (9) Arising out of an electronic chat room or bulletin board the insured hosts, owns, or over which the insured exercises control; (10) Arising out of the unauthorized use of another's name or product in your e-mail address, domain name or metatags, or any other similar tactics to mislead another's potential customers; (11) Arising out of the violation of a person's right of privacy created by any state or federal act. However, this exclusion does not apply to liability for damages that the insured would have in the absence of such state or federal act; (12) Arising out of: (a) An "advertisement" for others on your web site; (b) Placing a link to a web site of others on your web site; (c) Content from a web site of others displayed within a frame or border on your web site. Content includes information, code, sounds, text, graphics or images; or (d) Computer code, software or programming used to enable: (i) Your web site; or (ii) The presentation or functionality of an "advertisement" or other content on your web site; Page 8 of 24 Form SS 00 08 04 05 Ln 0 *0500252ZQ83870101 OBEN MEM MMEI Mani sear= Mae MEMSRI q• (13) Arising out of a violation of any anti- trust law; (14) Arising out of the fluctuation in price or value of any stocks, bonds or other securities; or (15) Arising out of discrimination or humiliation, committed by or at the direction of any "executive officer", director, stockholder, partner or member of the insured. Electronic Data Damages arising out of the loss of, loss of use of, damage to, corruption of, inability to access, or inability to manipulate "electronic data". r. Employment -Related Practices "Bodily injury" or "personal and advertising injury" to: (1) A person arising out of any: (a) Refusal to employ that person; (b) Termination of that person's employment; or (c) Employment-related practices, policies, acts or omissions, such as coercion, demotion, evaluation, reassignment, discipline, defamation, harassment, humiliation or discrimination directed at that person; or (2) The spouse, child, parent, brother or sister of that person as a consequence of "bodily injury" or "personal and advertising injury" to the person at whom any of the employment-related practices described in Paragraphs (a), (b), or (c) above is directed. This exclusion applies: (1) Whether the insured may be liable as an employer or in any other capacity; and (2) To any obligation to share damages with or repay someone else who must pay damages because of the injury. s. Asbestos (1) "Bodily injury", "property damage" or "personal and advertising injury" arising out of the "asbestos hazard". (2) Any damages, judgments, settlements, loss, costs or expenses that: BUSINESS UABILITY COVERAGE FORM (a) May be awarded or incurred by reason of any claim or suit alleging actual or threatened injury or damage of any nature or kind to persons or property which would not have occurred in whole or in pari but for the "asbestos hazard"; (b) Arise out of any request, demand, order or statutory or regulatory requirement that any insured or others test for, monitor, clean up, remove, encapsulate, contain, treat, detoxify or neutralize or in any way respond to or assess the effects of an "asbestos hazard"; or (c) Arise out of any claim or suit for damages because of testing for, monitoring, cleaning up, removing, encapsulating, containing, treating, detoxifying or neutralizing or in any way responding to or assessing the effects of an "asbestos hazard". t. Violation Of Statutes That Govern E - Mails, Fax, Phone Calls Or Other Methods Of Sending Material Or Information "Bodily injury", "property damage", or "personal and advertising injury" arising directly or indirectly out of any action or omission that violates or is alleged to violate: (1) The Telephone Consumer Protection Act (TCPA), including any amendment of or addition 10 such law; (2) The CAN -SPAM Act of 2003, including any amendment of or addition to such law; or (3) Any statute, ordinance or regulation, other than the TCPA or CAN -SPAM Act of 2003, that prohibits or limits the sending, transmitting, communicating or distribution of material or information. Damage To Premises Rented To You — Exception For Damage By Fire, Lightning or Explosion Exclusions c. through h. and k. through o. do not apply to damage by fire, lightning or explosion to premises rented to you or temporarily occupied by you with permission of the owner. A separate Limit of Insurance applies to this coverage as described in Section D. - Liability And Medical Expenses Limits Of Insurance. Fomi SS 00 08 04 05 Page 9 of 24 BUSINESS LIABILITY COVERAGE FORM 2. Applicable To Medical Expenses Coverage We will not pay expenses for "bodily injury": a. Any Insured To any insured, except "volunteer workers". b. Hired Person To a person hired to dowork for or on behalf of any insured or a tenant of any insured. c. Injury On Normally Occupied Premises To a person injured on That part of premises you own or rent that the person normally occupies. d. Workers' Compensation And Similar Laws To a person, whether or not an "employee" of any insured, if benefits for the "bodily injury" are payable or must be provided under a workers' compensation or disability benefits law or a similar law. e. Athletics Activities To a person injured while practicing, instructing or participating in any physical exercises or games, sports or athletic contests. f. Products -Completed Operations Hazard Included with the "products -completed operations hazard". Business Liability Exclusions Excluded under Business Liability Coverage. C. WHO IS AN INSURED 1. If you are designated in the Declarations as: a. An individual, you and your spouse are insureds, but only with respect to the conduct of a business of which you are the sole owner. b. A partnership or joint venture, you are an insured. Your members, your partners, and their spouses are also insureds, but only with respect to the conduct of your business. c. A limited liability company, you are an insured. Your members are also insureds, but only with respect to the conduct of your business. Your managers are insureds, but only with respect to their duties as your managers. d. An organization other than a partnership, joint venture or limited liability company, you are an insured. Your "executive officers" and directors are insureds, but only with respect to their duties as your officers or directors. Your stockholders are also insureds, but only with respect to their liability as stockholders. 9. e. A trust, you are an insured. Your trustees are also insureds, but only with respect to their duties as trustees. 2. Each of the following is also an insured: a. Employees And Volunteer Workers Your "volunteer workers" only while performing duties related to the conduct of your business, or your "employees", other than either your "executive officers" (if you are an organization other than a partnership, joint venture or limited liability company) or your managers (if you are a limited liability company), but only for acts within the scope of their employment by you or while performing duties related to the conduct of your business. However, none of these "employees" or "volunteer workers" are insureds for: (1) "Bodily injury" or "personal and advertising injury": (a) To you, to your partners or members (if you are a partnership or joint venture), to your members (if you are a limited liability company), or to a co -"employee" while in the course of his or her employment or performing duties related to the conduct of your business, or to your other "volunteer workers" while performing duties related to the conduct of your business; (b) To the spouse, child, parent, brother or sister of that co - "employee" or that "volunteer worker" as a consequence of Paragraph (1)(a) above; (c) For which there is any obligation to share damages with or repay someone else who must pay damages because of- the injury described in Paragraphs (1)(a) or (b) above; or (d) Arising out of his or her providing or failing to provide professional health care services. If you are not in the business of providing professional health care services, Paragraph (d) does not apply to any nurse, emergency medical technician or paramedic employed by you to provide such services. (2) "Property damage" 10 property: (a) Owned, occupied or used by, Page 10 of 24 Form SS 00 08 04 05 '.o 0 *0500252ZQ83870101 (b) Rented to, in the care, custody or control of, or over which physical control is being exercised for any purpose by you, any of your "employees", "volunteer workers", any partner or member (if you are a partnership or joint venture), or 'any member (if you are a limited liability company). b. Real Estate Manager Any person (other than your "employee" or "volunteer worker"), or any organization while acting as your real estate manager. c. Temporary Custodians Of Your Property Any person or organization having proper temporary custody of your property if you die, but only: (1) Wth respect to liability arising out of the maintenance or use of that property; and (2) Until your legal representative has been appointed. d. Legal Representative If You Die Your legal representative if you die, but only with respect to duties as such. That representative will have all your rights and duties under this insurance. e. Unnamed Subsidiary Any subsidiary and subsidiary thereof, of yours which is a legally incorporated entity of which you own a financial interest of more than 50% of the voting stock on the effective date of this Coverage Part. The insurance afforded herein for any subsidiary not shown in the Declarations as a named insured does not apply to injury or damage with respect to which an insured under this insurance is also an insured under another policy or would be an insured under such policy but for its termination or upon the exhaustion of its limits of insurance. 3. Newly Acquired Or Formed Organization Any organization you newly acquire or form, other than a partnership, joint venture or limited liability company, and over which you maintain financial interest of more than 50% of the voting stock, will qualify as a Named Insured if there is no other similar insurance available to that organization. However: a. Coverage under this provision is afforded only until the 180th day after you acquire or form the organization or the end of the policy period, whichever is earlier, and Form SS 00 08 04 05 BUSINESS LIABILITY COVERAGE FORM b. Coverage under this provision does not apply to: (1) "Bodily injury" or "property damage" that occurred; or (2) "Personal and advertising injury" arising out,of an offense committed before you acquired or formed the organization. 4. Operator Of Mobile Equipment With respect to "mobile equipment" registered in your name under any motor vehicle registration law, any person is an insured while driving such equipment along a public highway with your permission. Any other person or organization responsible for the conduct of such person is also an insured, but only with respect to liability arising out of the operation of the equipment, and only if no other insurance of any kind is available to that person or organization for this liability. However, no person or organization is an insured with respect to: a. "Bodily injury" to a co -"employee" of the person driving the equipment; or b. "Property damage" to property owned by, rented to, in the charge of or occupied by you or the employer of any person who is an insured under this provision. 5. Operator of Nonowned Watercraft With respect to watercraft you do not own that is less than 51 feet long and is not being used to carry persons for a charge, any person is an insured while operating such watercraft with your permission. Any other person or organization responsible for the conduct of such person is also an insured, but only with respect to liability arising out of the operation of the watercraft, and only if no other insurance of any kind is available to that person or organization for this liability. However, no person or organization is an insured with respect to: a. "Bodily injury" to a co -"employee" of the person operating the watercraft; or b. "Property damage" to property owned by, rented to, in the charge of or occupied by you or the employer of any person who is an insured under this provision. 6. Additional Insureds When Required By Written Contract, Written Agreement Or Permit The person(s) or organization(s) identified in Paragraphs a. through f. below are additional insureds when you have agreed, in a written Page 11 of 24 BUSINESS LIABILITY COVERAGE FORM contract, written agreement or because of a permit issued by a state or political subdivision, that such person or organization be added as an additional insured on your policy, provided the injury or damage occurs subsequent to the execution of the contract or agreement, or the issuance of the permit. A person or organization is an additional insured under this provision only for that period of time required by the contract, agreement or permit. However, no such person or organization is an additional insured under this -provision if such person or organization is included as an additional insured by an endorsement issued by us and made a part of this Coverage Part, including all persons or organizations added as additional insureds under the specific additional insured coverage grants in Section F. — Optional Additional Insured Coverages. a. Vendors Any person(s) or organization(s) (referred to below as vendor), but only with respect to "bodily injury" or "property damage" arising out of "your products" which are distributed or sold in the regular course of the vendor's business and only if this Coverage Part provides coverage for "bodily injury" or "property damage" included within the "products -completed operations hazard". (1) The insurance afforded to the vendor is subject to the following additional exclusions: This insurance does not apply to: (a) "Bodily injury" or "property damage" for which the vendor is obligated to pay damages by reason of the assumption of liability in a contract or agreement. This exclusion does not apply to liability for damages that the vendor would have in the absence of the contract or agreement; (b) Any express warranty unauthorized by you; (c) Any physical or chemical change in the product made intentionally by the vendor, (d) Repackaging, except when unpacked solely for the purpose of inspection, demonstration, testing, or the substitution of parts under instructions from the manufacturer, and then repackaged in the original container; (e) Any failure to make such inspections, adjustments, tests or servicing as the vendor has agreed to make or normally undertakes to make in the usual course of business, in connection with the distribution or sale of the products; (f) Demonstration, installation, servicing or repair operations, except such operations performed at the vendor's premises in connection with the sale of the product; (g) Products which, after distribution or sale by you, have been labeled or relabeled or used as a container, part or ingredient of any other thing or substance by or for the vendor; or (h) "Bodily injury" or "property damage" arising out of the sole negligence of the vendor for its own acts or omissions or those of its employees or anyone else acting on its behalf. However, this exclusion does not apply to: (i) The exceptions contained in Subparagraphs (d) or (f); or (ii) Such inspections, adjustments, tests or servicing as the vendor has agreed to make or normally undertakes to make in the usual course of business, in connection with the distribution or sale of the products. (2) This insurance does not apply to any insured person or organization from whom you have acquired such products, or any ingredient, part or container, entering into, accompanying or containing such products. b. Lessors Of Equipment (1) Any person or organization from whom you lease equipment; but only with respect to their liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by your maintenance, operation or use of equipment leased to you by such person or organization. Page 12 of 24 Form SS 00 08 04 05 *0500252ZQ83870101 MCWIRZ EMI MIRM c 121BEIM HERM tf tmc (2) With respect to the insurance afforded to these additional insureds, this insurance does not apply to any "occurrence" which takes place after you cease to lease that equipment. c. Lessors Of Land Or Premises (1) Any person 'or organization from whom you lease land or premises, but only with respect to liability arising out of the ownership, maintenance or use of that part of the land or premises leased toyouu. (2) With respect 10 the insurance afforded to these additional insureds, this insurance does not apply to: (a) Any "occurrence" which takes place after you cease to lease that land or be a tenant in that premises; or (b) Structural alterations, new construction or demolition operations performed by or on behalf of such person or organization. d. Architects, Engineers Or Surveyors (1) Any architect, engineer, or surveyor, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by your acts or omissions or the acts or omissions of those acting on your behalf: (a) In connection with your premises; or (b) In the performance of your ongoing operations performed by you or on your behalf. (2) With respect to the insurance afforded to these additional insureds, the following additional exclusion applies: This insurance does not apply to "bodily injury", "property damage" or "personal and advertising injury" arising out of the rendering of or the failure to render any professional services by or for you, including: (a) The preparing, approving, or failure to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders, designs or drawings and specifications; or (b) Supervisory, inspection, architectural or engineering activities. Form SS 00 08 04 05 BUSINESS LIABILITY COVERAGE FORM e. Permits Issued By State Or Political Subdivisions (1) Any state or -political subdivision, but only with respect to operations performed by you or on your behalf for which the state or political subdivision has issued a permit. (2) Wth respect to the insurance afforded to these additional insureds, this insurance does not apply to: (a) "Bodily injury", "property damage" or "personal and advertising injury" arising out of operations performed for the state or municipality; or (b) "Bodily injury" or "property damage" included within the "products - completed operations hazard". f. Any Other Party (1) Any other person or organization who is not an insured under Paragraphs a. through e. above, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by your acts or omissions or the acts or omissions of those acting on your behalf: (a) In the performance of your ongoing operations; (b) In connection with your premises owned by or rented to you; or (c) In connection with "your work" and included within the "products - completed operations hazard", but only if (i) The written contract or written agreement requires you to provide such coverage to such additional insured; and (ii) This Coverage Part provides coverage for "bodily injury" or "property damage" included within the "products - completed operations hazard". (2) Wth respect to the insurance afforded to these additional insureds, this insurance does not apply to: "Bodily injury", "property damage" or "personal and advertising injury" arising out of the rendering of, or the failure to render, any professional architectural, engineering or surveying services, including: Page 13 of 24 BUSINESS UABILITY COVERAGE FORM (a) The preparing, approving, or failure to prepare or approve, maps, shop drawings, opinions, reports, surveys,field orders, change orders, designs or drawings and specifications; or (b) Supervisory, architectural activities. The limits of insurance that apply to additional insureds are described in Section D. — Limits Of Insurance. How this insurance applies when other insurance is available to an additional insured is described in the Other Insurance Condition in Section E. - Liability And Medical Expenses General Conditions. No person or organization is an insured with respect to the conduct of any current or past partnership, joint venture or limited liability company that is not shown as a Named Insured in the Declarations. D. UABILITY AND MEDICAL EXPENSES LIMITS OF INSURANCE 1. The Most We Will Pay The Limits of Insurance shown in the Declarations and the rules below fix the most we will pay regardless of the number of: a. Insureds; b. Claims made or "suits" brought; or c. Persons or organizations making claims or bringing "suits". 2. Aggregate Limits The most we will pay for: a. Damages because of "bodily injury" and "property damage" included in the "products -completed operations hazard" is the Products -Completed Operations Aggregate Limit shown in the Declarations. b. Damages because of all other "bodily injury", "property damage" or "personal and advertising injury", including medical expenses, is the General Aggregate Limit shown in the Declarations. This General Aggregate Limit applies separately to each of your "locations" owned by or rented to you. "Location" means premises involving the same or connecting lots, or premises whose connection is interrupted only by a street, roadway or right-of-way of a railroad. inspection, or engineering This General Aggregate limit does not apply to "property •damage" to premises . while rented to you or temporarily occupied by you with permission of the owner, arising out of fire, lightning or explosion. 3. Each Occurrence Limit Subject to 2.a. or 2.b above, whichever applies, the most we will pay for the sum of all damages because of all "bodily injury", "property damage" and medical expenses arising out of any one "occurrence" is the Liability and Medical Expenses Limit shown in the Declarations. The most we will pay for all medical expenses because of "bodily injury" sustained by any one person is the Medical Expenses Limit shown in the Declarations. 4. Personal And Advertising Injury Limit Subject to 2.b. above, the most we will pay for the sum of all damages because of all "personal and advertising injury" sustained by any one person or organization is the Personal and Advertising Injury Limit shown in the Declarations. 5. Damage To Premises Rented To You Limit The Damage To Premises Rented To You Limit is the most we will pay under Business Liability Coverage for damages because of "property damage" to any one premises, while rented to you, or in the case of damage by fire, lightning or explosion, while rented to you or temporarily occupied by you with permission of the owner. In the case of damage by fire, lightning or explosion, the Damage to Premises Rented To You Limit applies to all damage proximately caused by the same event, whether such damage results from fire, lightning or explosion or any combination of these. 6. How Limits Apply To Additional Insureds The most we will pay on behalf of a person or organization who is an additional insured under this Coverage Part is the lesser of: a. The limits of insurance specified in a written contract, written agreement or permit issued by a state or political subdivision; or b. The Limits of Insurance shown in the Declarations. Such amount shall be a part of and not in addition to the Limits of Insurance shown in the Declarations and described in this Section. Page 14 of 24 Form SS 00 08 04 05 *0500252ZO83870101 ISM SSG1 MEER If more than one limit of insurance under this policy and any endorsements attached thereto applies to any claim or "suit", the most we will pay under this policy and the endorsements is the single highest limit of liability of all coverages applicable to such claim or "suit". However, this paragraph does not apply to the Medical Expenses limit set forth in Paragraph 3. above. The Limits of Insurance of this Coverage Part apply separately to each consecutive annual period and to any remaining period of less than 12 months, starting with the beginning of the policy period shown in the Declarations, unless the policy period is extended after issuance for an additional period of less than 12 months. In that case, the additional period will be deemed part of the last preceding period for purposes of determining the Limits of Insurance. E. LIABILITY AND MEDICAL EXPENSES GENERAL CONDITIONS 1. Bankruptcy Bankruptcy or insolvency of the insured or of the insured's estate will not relieve us of our obligations under this Coverage Part. 2. Duties In The Event Of Occurrence, Offense, Claim Or Suit a. Notice Of Occurrence Or Offense You or any additional insured must see to it that we are notified as soon as practicable of an "occurrence" or an offense which may result in a claim. To the extent possible, notice should include: (1) How, when and where the "occurrence" or offense took place; (2) The names and addresses of any injured persons and witnesses; and (3) The nature and location of any injury or damage arising out of the "occurrence or offense. b. Notice Of Claim If a claim is made or "suit" is brought against any insured, you or any additional insured must: (1) Immediately record the specifics of the claim or "suit" and the date received; and (2) Notify us as soon as practicable. You or any additional insured must see to it that we receive a written notice of the claim or "suit" as soon as practicable. c. Assistance And Cooperation Of The Insured You and any other involved insured must: BUSINESS LIABILITY COVERAGE FORM (1) Immediately send us copies of any demands, notices, summonses or legal papers received in connection with the claim or "suit"; (2) Authorize us to obtain records and other information; (3) Cooperate, with us in the investigation, settlement. of the claim or defense against the "suit"; and (4) Assist us, upon our request, in the enforcement of any right against any person or organization that may be liable to the insured because of injury or damage to which this insurance may also apply. d. Obligations At The Insured's Own Cost No insured will, except at that insured's own cost, voluntarily make a payment, assume any obligation, or incur any expense, other than for first aid, without our consent. e. Additional Insured's Other Insurance If we cover a claim or "suit" under this Coverage Part that may also be covered by other insurance available to an additional insured, such additional insured must submit such claim or "suit" to the other insurer for defense and indemnity. However, this provision does not apply to the extent that you have agreed in a written contract, written agreement or permit that this insurance is primary and non-contributory with the additional insured's own insurance. f. Knowledge Of An Occurrence, Offense, Claim Or Suit Paragraphs a. and b. apply to you or to any additional insured only when such "occurrence", offense, claim or "suit" is known to: (1) You or any additional insured that is an individual; (2) Any partner, if you or an additional insured is a partnership; (3) Any manager, if you or an additional insured is a limited liability company; (4) Any "executive officer" or insurance manager, if you or an additional insured is a corporation; (5) Any trustee, if you or an additional insured is a trust; or (6) Any elected or appointed official, if you or an additional insured is a political subdivision or public entity. Form SS 00 08 04 05 Page 15 of 24 BUSINESS LIABILITY COVERAGE FORM This Paragraph f. applies separately to you and any additional insured. 3. Financial Responsibility Laws a. When this policy is certified as proof of financial responsibility for the future under the provisions of any motor vehicle financial responsibility law, the insurance - provided by the policy for "bodily injury" liability and "property damage" liability will comply with the provisions of the law to the extent of the coverage and limits of insurance required by that law. b. With respect to _ "mobile equipment" to which this insurance applies, we will provide any liability, uninsured motorists, underinsured motorists, no-fault or other coverage required by any motor vehicle law. We will provide the required limits for those coverages. 4. Legal Action Against Us No person or organization has a right under this Coverage Form: a. To join us as a party or otherwise bring us into a "suit" asking for damages from an insured; or b. To sue us on this Coverage Form unless all of its terms have been fully complied with. A person or organization may sue us to recover on an agreed settlement or on a final judgment against an insured; but we will not be liable for damages that are not payable under the terms of this insurance or that are in excess of the applicable limit of insurance. An agreed settlement means a settlement and release of liability signed by us, the insured and the claimant or the claimant's legal representative. 5. Separation Of Insureds Except with respect to the Limits of Insurance, and any rights or duties specifically assigned in this policy to the first Named Insured, this insurance applies: a. As if each Named Insured were the only Named Insured; and b. Separately to each insured against whom a claim is made or "suit" is brought. 6. Representations a. When You Accept This Policy By accepting this policy, you agree. (1) The statements in the Declarations are accurate and complete; (2) Those statements are based upon representations you made 10 us; and Page 16 of 24 (3) We have issued this policy in reliance upon your representations. b. Unintentional Failure To Disclose Hazards If unintentionally you should fail to disclose all hazards relating to the conduct of your business at the inception date of this - -Coverage Part, we shall not deny any coverage under this Coverage Part because of such failure. 7. Other Insurance If other valid and collectible insurance is available for a loss we cover under this Coverage Part, our obligations are limited as follows: a. Primary Insurance This insurance is primary except when b. below applies. If other insurance is also primary, we will share with all that other insurance by the method described in c. below. b. Excess Insurance This insurance is excess over any of the other insurance, whether primary, excess, contingent or on any other basis: (1) Your Work That is Fire, Extended Coverage, Builder's Risk, Installation Risk or similar coverage for "your work"; (2) Premises Rented To You That is fire, lightning or explosion insurance for premises rented to you or temporarily occupied by you with percussion of the owner, (3) Tenant Liability That is insurance purchased by you to cover your liability as a tenant for "property damage" to premises rented to you or temporarily occupied by you with permission of the owner; (4) Aircraft, Auto Or Watercraft If the loss arises out of the maintenance or use of aircraft, "autos" or watercraft to the extent not subject to Exclusion g. of Section A. — Coverages. (5) Property Damage To Borrowed Equipment Or Use Of Elevators If the loss arises out of "property damage" to borrowed equipment or the use of elevators to the extent not subject to Exclusion k. of Section A. — Coverages. Form SS 00 08 04 05 0 U1 Ln0 *0500252ZQ83870101 MGM MEM MEG E NOINCS B▪ EM N ES ESSE ELME MM N TS MGM smom O SEMSf (6) When You Are Added As An Additional Insured To Other Insurance That is other insurance available to you covering liability for damages arising out of the premises or operations, or products and completed operations, for which you have- been added as an additional insured by that insurance; or (7) When You Add Others As An Additional Insured To This Insurance That is other insurance available to an additional insured. However, the following provisions apply to other insurance available to any person or organization who is an additional insured under this Coverage Part: (a) Primary Insurance When Required By Contract This insurance is primary if you have agreed in a written contract, written agreement or permit that this insurance be primary. If other insurance is also primary, we will share with all that other insurance by the method described in c. below. (b) Primary And Non -Contributory To Other Insurance When Required By Contract If you have agreed in a written contract, written agreement or permit that this insurance is primary and non-contributory with the additional insured's own insurance, this insurance is primary and we will not seek contribution from that other insurance. Paragraphs (a) and (b) do not apply to other insurance 10 which the additional insured has been added as an additional insured When this insurance is excess, we will have no duty under this Coverage Part to defend the insured against any "suit" if any other insurer has a duty to defend the insured against that "suit". If no other insurer defends, we will undertake to do so, but we will be entitled to the insured's rights against all those other insurers. BUSINESS LIABILITY COVERAGE FORM When this insurance is excess over other insurance, we will pay only our share of the amount of the loss, if any, that exceeds the sum of: (1) The total amount that all such other insurance would pay for the loss in the absence of this insurance; and (2) The total of all deductible and self- insured amounts under all that other insurance. We will share the remaining loss, if any, with any other insurance that is not described in this Excess Insurance provision and was not bought specifically to apply in excess of the Limits of Insurance shown in the Declarations of this Coverage Part. c. Method Of Sharing If all the other insurance permits contribution by equal shares, we will follow this method also. Under this approach, each insurer contributes equal amounts until it has paid its applicable limit of insurance or none of the loss remains, whichever comes first. If any of the other insurance does not permit contribution by equal shares, we will contribute by limits. Under this method, each insurer's share is based on the ratio of its applicable limit of insurance to the total applicable limits of insurance of all insurers. 8. Transfer Of Rights Of Recovery Against Others To Us a. Transfer Of Rights Of Recovery If the insured has rights to recover all or part of any payment, including Supplementary Payments, we have made under this Coverage Part, those rights are transferred to us. The insured must do nothing after loss to impair them. At our request, the insured will bring "suit" or transfer those rights to us and help us enforce them. This condition does not apply to Medical Expenses Coverage. b. Waiver Of Rights Of Recovery (Waiver Of Subrogation) If the insured has waived any rights of recovery against any person or organization for all or part of any payment, including Supplementary Payments, we have made under this Coverage Part, we also waive that right, provided the insured waived their rights of recovery against such person or organization in a contract, agreement or permit that was executed prior to the injury or damage. Form SS 00 08 04 05 Page 17 of 24 BUSINESS LIABILITY COVERAGE FORM F. OPTIONAL ADDITIONAL INSURED_ COVERAGES If listed or shown as applicable in the Declarations, one 'or more of the following Optional Additional Insured Coverages also apply. When any of these Optional Additional Insured Coverages apply, Paragraph 6. (Additional Insureds When Required by Written Contract, Written Agreement or Permit) of Section C., Who Is An Insured, does not apply to the person or organization shown in the Declarations. These coverages are subject to the terms and conditionsapplicable to Business Liability Coverage in this policy, except as provided below: 1. Additional Insured - Designated Person Or Organization WHO IS AN INSURED under Section C. is amended to include as an additional insured the person(s) or organization(s) shown in the Declarations, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by your acts or omissions or the acts or omissions of those acting on your behalf: a. In the performance of your ongoing operations; or b. In connection with your premises owned by or rented to you. 2. Additional Insured - Managers Or Lessors Of Premises a. WHO IS AN INSURED under Section C. is amended to include as an additional insured the person(s) or organization(s) shown in the Declarations as an Additional Insured - Designated Person Or Organization; but only with respect to liability arising out of the ownership, maintenance or use of that part of the premises leased to you and shown in the Declarations. b. Wth respect to the insurance afforded to these additional insureds, the following additional exclusions apply: This insurance does not apply to: (1) (2) Any "occurrence" which takes place after you cease to be a tenant in that premises; or Structural alterations, new construction or demolition operations performed by or on behalf of such person or organization. 3. Additional Insured - Grantor Of Franchise WHO IS AN INSURED under Section C. is amended to include as an additional insured the person(s) or organization(s) shown in the Declarations as an Additional Insured - Grantor Of Franchise, but only with respect to their liability as grantor of franchise to you. 4. Additional Insured - Lessor Of Leased Equipment a. WHO IS AN INSURED under Section C. is amended to include as an additional insured the person(s) or organization(s) shown in the Declarations as an Additional Insured — Lessor of Leased Equipment, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by your maintenance, operation or use of equipment leased to you by such person(s) or organization(s). b. Wth respect to the insurance afforded to these additional insureds, this insurance does not apply to any "occurrence" which takes place after you cease to lease that equipment. 5. Additional Insured - Owners Or Other Interests From Whom Land Has Been Leased a. WHO IS AN INSURED under Section C. is amended to include as an additional insured the person(s) or organization(s) shown in the Declarations as an Additional Insured — Owners Or Other Interests From Whom Land Has Been Leased, but only with respect to liability arising out of the ownership, maintenance or use of that part of the land leased to you and shown in the Declarations. b. With respect to the insurance afforded 10 these additional insureds, the following additional exclusions apply: This insurance does not apply to: (1) Any "occurrence" that takes place after you cease to lease that land; or (2) Structural alterations, new construction or demolition operations performed by or on behalf of such person or organization. 6. Additional Insured - State Or Political Subdivision — Permits a. WHO IS AN INSURED under Section C. is amended to include as an additional insured the state or political subdivision shown in the Declarations as an Additional Page 18 of 24 Form SS 00 08 04 05 0 01-1 *0500252Z03870101 11111111113 IMMO SISICOM MMIStEliMC Insured — State Or Political Subdivision - Permits, but only with respect to operations performed by you or on your behalf for which the state or political subdivision has issued.a permit. b. With respect to the insurance afforded to these additional insureds, the following additional exclusions apply: This insurance does not apply to: (1) "Bodily injury", "property damage" or "personal and advertising injury" arising out of operations performed for the state or municipality; or _ (2) "Bodily injury" or "property damage" included in the "product -completed operations" hazard. 7. Additional Insured - Vendors a. WHO IS AN INSURED under Section C. is amended to include as an additional insured the person(s) or organization(s) (referred to below as vendor) shown in the Declarations as an Additional Insured - Vendor, but only with respect to "bodily injury" or "property damage" arising out of "your products" which are distributed or sold in the regular course of the vendor's business and only if this Coverage Part provides coverage for "bodily injury" or "property damage" included within the "products -completed operations hazard". b. The insurance afforded to the vendor is subject to the following additional exclusions: (1) This insurance does not apply to: (a) "Bodily injury" or "property damage" for which the vendor is obligated to pay damages by reason of the assumption of liability in a contract or agreement. This exclusion does not apply to liability for damages that the vendor would have in the absence of the contract or agreement; (b) Any express warranty unauthorized by you; (c) Any physical or chemical change in the product made intentionally by the vendor, (d) Repackaging, unless unpacked solely for the purpose of inspection, demonstration, testing, or the substitution of parts under instructions from the manufacturer, and then repackaged in the original container, Form SS 00 08 04 05 BUSINESS LIABILITY COVERAGE FORM (e) Any failure to make such inspections, adjustments, tests or servicing as the vendor has agreed to make or normally undertakes to make in the usual course of business, in connection with the distribution or sale of the products; (f) Demonstration, installation, servicing or repair operations, except such operations performed at the vendor's premises in connection with the sale of the product; (g) Products which, after distribution or sale by you, have been labeled or relabeled or used as a container, part or ingredient of any other thing or substance by or for the vendor; or (h) "Bodily injury" or "property damage" arising out of the sole negligence of the vendor for its own acts or omissions or those of its employees or anyone else acting on its behalf. However, this exclusion does not apply to: (i) The exceptions contained in Subparagraphs (d) or (f); or (ii) Such inspections, adjustments, tests or servicing as the vendor has agreed to make or normally undertakes 10 make in the usual course of business, in connection with the distribution or sale of the products. (2) This insurance does not apply to any insured person or organization from whom you have acquired such products, or any ingredient, part or container, entering into, accompanying or containing such products. 8. Additional Insured — Controlling Interest WHO IS AN INSURED under Section C. is amended to include as an additional insured the person(s) or organization(s) shown in the Declarations as an Additional Insured — Controlling Interest, but only with respect to their liability arising out of: a. Their financial control of you; or b. Premises they own, maintain or control while you lease or occupy these premises. Page 19 of 24 BUSINESS LIABILITY COVERAGE FORM This insurance does not apply to structural alterations, new construction and demolition operations performed by or for that person or organization. 9. Additional Insured — Owners, Lessees Or Contractors — Scheduled Person Or • Organization • a. WHO IS AN INSURED under Section C. is amended to include as an additional insured the person(s) or organization(s) shown in the Declarations as an Additional Insured - Owner, Lessees Or Contractors, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by your acts or omissions or the acts or omissions of those acting on your behalf: (1) In the performance of your ongoing operations for the additional insured(s); or (2) In connection with "your work" performed for that additional insured and included within the "products - completed operations hazard", but only if this Coverage Part provides coverage for "bodily injury" or "property damage" included within the "products -completed operations hazard". b. With respect to the insurance afforded to these additional insureds, this insurance does not apply to "bodily injury", "property damage" or "personal an advertising injury" arising out of the rendering of, or the failure to render, any professional architectural, engineering or surveying services, including: (1) The preparing, approving, or failure to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders, designs or drawings and specifications; or (2) Supervisory, inspection, architectural or engineering activities. 10. Additional Insured — Co -Owner Of Insured Premises WHO IS AN INSURED under Section C. is amended to include as an additional insured the person(s) or Organization(s) shown in the Declarations as an Additional Insured — Co - Owner Of Insured Premises, but only with respect to their liability as co-owner of the premises shown in the Declarations. The limits of insurance that apply to additional insureds are described in Section D. — Limits Of Insurance. How this insurance applies when other insurance is available to an additional insured is described in the Other Insurance Condition in Section E. — Liability And Medical Expenses General Conditions. G. LIABILITY AND MEDICAL EXPENSES DEFINITIONS 1. "Advertisement" means the widespread public dissemination of information or images that has the purpose of inducing the sale of goods, products or services through: Radio; Television; Billboard; Magazine; Newspaper; b. The Internet, but only that part of a web site that is about goods, products or services for the purposes of inducing the sale of goods, products or services; or c. Any other publication that is given widespread public distribution. However, "advertisement" does not include: a. The design, printed material, information or images contained in, on or upon the packaging or labeling of any goods or products; or b. An interactive conversation between or among persons through a computer network. 2. "Advertising idea" means any idea for an "advertisement". 3. "Asbestos hazard" means an exposure or threat of exposure to the actual or alleged properties of asbestos and includes the mere presence of asbestos in any form. 4. "Auto" means a land motor vehicle, trailer or semi -trailer designed for travel on public roads, including any attached machinery or equipment. But "auto" does not include "mobile equipment". 5. "Bodily injury" means physical: a. Injury; b. Sickness; or c. Disease sustained by a person and, if arising out of the above, mental anguish or death at any time. 6. "Coverage territory" means: Page 20 of 24 Form SS 00 08 04 05 *05002522Q83870101 a. The United States of America (including its territories and possessions), Puerto Rico and Canada; b. International waters or airspace, but only if the injury or damage occurs in the course of travel or transportation between any places included in a. above; c. All other parts of the world if the injury or damage arises out of: (1) Goods or products made or sold by you in the territory described in a. above; (2) The activities of a personwhose home is in the territory described in a. above, but is away for a short time on your business; or (3) "Personal and advertising injury" offenses that take place through the Internet or similar electronic means of communication provided the insured's responsibility to pay damages is determined in the United States of America (including its territories and possessions), Puerto Rico or Canada, in a "suit" on the merits according to the substantive law in such territory, or in a settlement we agree to. 7. "Electronic data" means information, facts or programs: a. Stored as or on; b. Created or used on; or c. Transmitted to or from computer software, including systems and applications software, hard or floppy disks, CD-ROMS, tapes, drives, cells, data processing devices or any other media which are used with electronically controlled equipment. 8. "Employee" includes a "leased worker". "Employee" does not include a "temporary worker". 9. "Executive officer" means a person holding any of the officer positions created by your charter, constitution, by-laws or any other similar goveming document. 10. "Hostile fire" means one which becomes uncontrollable or breaks out from where it was intended to be. 11. "Impaired property" means tangible property, other than "your product" or "your work", that cannot be used or is less useful because: a. It incorporates "your product" or "your work" that is known or thought to be defective, deficient, inadequate or dangerous; or BUSINESS LIABILITY COVERAGE FORM b. You have failed to fulfill the terms of a contract or agreement; if such property can be restored to use by: a. The repair, replacement, adjustment or removal of "your product" or "your work"; or b. Your fulfilling the terms of the contract or agreement 12. "Insured contract" means: a. A contract for a lease of premises. However, that portion of the contract for a lease of premises that indemnifies any person or organization for damage by fire, lightning or explosion to premises while rented to you or temporarily occupied by you with permission of the owner is subject to the Damage To Premises Rented To You limit described in Section D. — Liability and Medical Expenses Limits of Insurance. b. A sidetrack agreement; c. Any easement or license agreement, including an easement or license agreement in connection with construction or demolition operations on or within 50 feet of a railroad; d. Any obligation, as required by ordinance, to indemnify a municipality, except in connection with work for a municipality; e. An elevator maintenance agreement; or f. That part of any other contract or agreement pertaining to your business (including an indemnification of a municipality in connection with work performed for a municipality) under which you assume the tort liability of another party to pay for "bodily injury" or "property damage" to a third person or organization, provided the "bodily injury" or "property damage" is caused, in whole or in part, by you or by those acting on your behalf. Tort liability means a liability that would be imposed by law in the absence of any contract or agreement. Paragraph f. includes that part of any contract or agreement that indemnifies a railroad for "bodily injury" or "property damage" arising out of construction or demolition operations within 50 feet of any railroad property and affecting any railroad bridge or tressle, tracks, road -beds, tunnel, underpass or crossing. However, Paragraph f. does not include that part of any contract or agreement: Form SS 00 08 04 05 Page 21 of 24 BUSINESS UABILITY COVERAGE FORM (1) That indemnifies an architect, engineer or surveyor for injury or damage arising out of: (a) Preparing, approving or failing to prepare or approve maps, shop drawings, opinions, reports, surveys, field orders, change orders, designs or drawings and specifications; or (b) Giving directions or instructions or failing to give them, if that is the primary cause of the injury o damage; or (2) Under which the insured, if an architect, engineer or surveyor, assumes liability for an injury or damage arising out of the insured's rendering or failure to render professional services, including those listed in (1) above and supervisory, inspection, architectural or engineering activities. 13. "Leased worker" means a person leased to you by a labor leasing firm under an agreement between you and the labor leasing firm, to perform duties related to the conduct of your business. "Leased worker" does not include a "temporary worker". 14. "Loading or unloading" means the handling of property: a. After it is moved from the place where it is accepted for movement into or onto an aircraft, watercraft or 'auto"; b. While it is in or on an aircraft, watercraft or "auto"; or c. While it is being moved from an aircraft, watercraft or "auto" to the place where it is finally delivered; but "loading or unloading" does not include the movement of property by means of a mechanical device, other than a hand truck, that is not attached to the aircraft, watercraft or "auto". 15. "Mobile equipment" means any of the following types of land vehicles, including any attached machinery or equipment: a. Bulldozers, farm machinery, forklifts and other vehicles designed for use principally off public roads; b. Vehicles maintained for use solely on or next to premises you own or rent; c. Vehicles that travel on crawler treads; d. Vehicles, whether self-propelled or not, on which are permanently mounted: r (1) Power cranes, shovels, loaders, diggers or drills; or (2) Road construction or resurfacing equipment such as graders, scrapers or rollers, e. Vehicles not described in a., b., c., or d. above that are not self-propelled and are maintained primarily to provide mobility to permanently attached equipment of the following types: (1) Air compressors, pumps and generators, including spraying, welding, building cleaning, geophysical exploration, lighting and well servicing equipment; or (2) Cherry pickers and similar devices used to raise or lower workers; f. Vehicles not described in a., b., c., or d. above maintained primarily for purposes other than the transportation of persons or cargo. However, self-propelled vehicles with the following types of permanently attached equipment are not "mobile equipment" but will be considered "autos": (1) Equipment, of at least 1,000 pounds gross vehicle weight, designed primarily for: (a) Snow removal; (b) Road maintenance, but not construction or resurfacing; or (c) Street cleaning; (2) Cherry pickers and similar devices mounted on automobile or truck chassis and used to raise or lower workers; and (3) Air compressors, pumps and generators, including spraying, welding, building cleaning, geophysical exploration, lighting and well servicing equipment. 16. "Occurrence" means an accident, including continuous or repeated exposure to substantially the same general harmful conditions. 17. "Personal and advertising injury" means injury, including consequential "bodily injury", arising out of one or more of the following offenses: a. False arrest, detention or imprisonment; b. Malicious prosecution; Page 22 of 24 Form SS 00 08 04 05 '.o 0 *0500252ZQ83870101 MiW Waal rs RIBE c. The wrongful eviction from, wrongful entry into, or invasion of the right of private occupancy of a room, dwelling or premises that the person occupies, committed by or on behalf of its owner, landlord or lessor; d. Oral, written or electronic publication- of------ material that slanders or libels a person or organization or disparages a person's or organization's goods, products or services; e. Oral, written or electronic publication of material that violates a person's right of privacy; f. Copying, in your "advertisement", a person's or organization's "advertising idea" or style of "advertisement"; Infringement of copyright, slogan, or title of any literary or artistic work, in your "advertisement"; or h. Discrimination or humiliation that results in injury to the feelings or reputation of a natural person. 18. "Pollutants" means any solid, liquid, gaseous or thermal irritant or contaminant, including smoke, vapor, soot, fumes, acids, alkalis, chemicals and waste. Waste includes materials to be recycled, reconditioned or reclaimed. 19. "Products -completed operations hazard"; a. Includes all "bodily injury" and "property damage" occurring away from premises you own or rent and arising out of "your product" or "your work" except: (1) Products that are still in your physical possession; or (2) Work that has not yet been completed or abandoned. However, "your work" will be deemed to be completed at the earliest of the following times: (a) When all of the work called for in your contract has been completed. (b) When all of the work to be done at the job site has been completed if your contract calls for work at more than one job site. (c) When that part of the work done at a job site has been put to its intended use by any person or organization other than another contractor or subcontractor working on the same project. g. BUSINESS UABILITY COVERAGE FORM Work that may need service, maintenance, correction, repair or replacement, but which is otherwise complete, will be treated as completed. The "bodily injury" or "property damage" must occur away from premises you own or rent, unless your business includes the selling, handling or distribution of "your product" for consumption on premises you own or rent. b. Does not include "bodily injury" or "property damage" arising out of: (1) The transportation of property, unless the injury or damage arises out of a condition in or on a vehicle not owned or operated by you, and that condition was created by the "loading or unloading" of that vehicle by any insured; or (2) The existence of tools, uninstalled equipment or abandoned or unused materials. 20. "Property damage" means: a. Physical injury to tangible property, including all resulting loss of use of that property. All such loss of use shall be deemed to occur at the time of the physical injury that caused it; or b. Loss of use of tangible property that is not physically injured. All such loss of use shall be deemed to occur at the time of "occurrence" that caused it. As used in this definition, "electronic data" is not tangible property. 21. "Suit" means a civil proceeding in which damages because of "bodily injury", "property damage" or "personal and advertising injury" to which this insurance applies are alleged. "Suit" includes: a. An arbitration proceeding in which such damages are claimed and to which the insured must submit or does submit with our consent; or b. Any other alternative dispute resolution proceeding in which such damages are claimed and to which the insured submits with our consent. 22. "Temporary worker" means a person who is furnished to you to substitute for a permanent "employee" on leave or to meet seasonal or short-term workload conditions. 23. "Volunteer worker" means a person who: a. Is not your "employee"; Form SS 00 08 04 05 Page 23 of 24 BUSINESS LIABILITY COVERAGE FORM b. Donates his or her work; c. Acts at the direction of and within the scope of duties determined by you; and d. Is not paid a fee, salary or other compensation by you or anyone else for their work performed for you. 24. "Your,product": a. Means: _. (1) Any goods or products, other than real property, manufactured, sold, handled, distributed or disposed of by: (a) You; (b) Others trading under your name; or (c) A person or organization whose business or assets you have acquired; and (2) Containers (other than vehicles), materials, parts or equipment furnished in connection with such goods or products. b. Includes: (1) Warranties or representations made at any time with respect to the fitness, quality, durability, performance or use of "your product"; and (2) The providing of or failure to provide wamings or instructions. c. Does not include vending machines or other property rented to or located for the use of others but not sold 25. "Your work": a. Means: (1) Work or operations performed by you or on your behalf; and (2) Materials, parts or equipment furnished in connection with such work or operations. b. Includes: (1) Warranties or representations made at any time with respect to the fitness, quality, durability, performance or use of "your work"; and (2) The providing of or failure to provide warnings or instructions. Page 24 of 24 Form SS 00 08 04 05