HomeMy WebLinkAbout04/02/2019 06E Construction Management Services Contract with KBA, Inc.ITEM TITLE:
SUBMITTED BY:
BUSINESS OF THE CITY COUNCIL
YAKIMA, WASHINGTON
AGENDA STATEM ENT
1
Item No. 6.E.
For Meeting of: April 2, 2019
Resolution ratifying a Professional Services Contract with KBA,
Inc. for Construction Management Services
Scott Schafer, Public Works Director
Bob Desgrosellier, Acting Chief Engineer, 575-6228
SUMMARY EXPLANATION:
With the North 1st Street Revitalization Phase 1 Project scheduled to begin on March 18th, an
agreement was required to be in place prior to the start of the project with a consulting
engineering firm to provide the dedicated construction management and inspection duties
required of this important project. The City does not have the capacity to provide this vital
supervision. As a result of the project start date, and the fact that the agreement was not finalized
in time to get it in front of the City Council before the start date of the project, it became
necessary for the City Manager to execute this agreement prior to the next available City Council
meeting to avoid any delays.
With Phase 1 primarily funded by a Surface Transportation Program (STP) federal grant, the City
is required to adhere to all federal guidelines and regulations. The City followed the federal
consultant selection procedure and utilized the Municipal Research and Service Center's
(MRSC) roster in selecting qualified engineering firms that had the required experience. The City
interviewed three qualified engineering firms; selecting KBA, Inc. The agreement with KBA, Inc.
outlines the obligations in providing the construction management and inspection services for
Phase 1 of the North 1st Street Revitalization Project in the amount not to exceed $600,000.
Funding for Phase 1 of the N. 1st St. Project was secured with a $2.718 million STP grant and a
$1 million Transportation Improvement Board (TIB) grant. Additional funding is to be provided by
the City's utilities for their respective projects and the use of Gas Tax Funds. The City Manager's
executed agreement is attached and is now submitted for City Council ratification.
ITEM BUDGETED: Yes
STRATEGIC PRIORITY: Economic Development
2
STAFF RECOMMENDATION:
Adopt Resolution
BOARD/COMMITTEE RECOMMENDATION:
ATTACHMENTS:
Description Upload Date Type
Resolution KBA Agreement 32(12019 Resolution
cm-1[1'dd 3:77/21119 Cevc Memo
A RESOLUTION
RESOLUTION NO. R-2019 -
ratifying the City Manager's execution of a Professional Services
Contract with KBA, Inc. for Construction Management Services for
Phase 1 of the N. 1st Street Revitalization Project.
3
WHEREAS, Phase 1 of the North 1st Street Revitalization Project was scheduled to
begin on March 18, 2019, and it was required that an agreement be in place prior to the start
of the project with a consulting engineering firm to provide the dedicated construction
management and inspection duties required of this important project since the City does not
have the capacity to provide this vital supervision; and
WHEREAS, since Phase 1 is primarily funded with a Surface Transportation
Program (STP) federal grant, the City was required to adhere to all federal guidelines and
regulations; and
WHEREAS, the City followed the federal consultant selection procedure and utilized
the Municipal Research and Service Center's (MRSC) roster in selecting qualified
engineering firms that had the required experience; and
WHEREAS, the City interviewed three qualified engineering firms; selecting KBA,
Inc.; and
WHEREAS, the agreement with KBA, Inc. outlines the obligations in providing the
construction management and inspection services for Phase 1 of the North 1st Street
Revitalization Project in the amount not to exceed $600,000; and
WHEREAS, due to the project start date, and the fact that the agreement was not
finalized in time to get it in front of the City Council before the start date of the project, it
became necessary for the City Manager to execute this agreement prior to the next
available City Council meeting to avoid any delays; and
WHEREAS, the Yakima City Council has determined that revitalization of the North
First Street Corridor is a Strategic Priority; and
WHEREAS, the City Council of the City of Yakima finds it was in the best interest of
the residents and the City to start the project on time, which required execution of the
agreement with KBA, Inc. prior to a City Council meeting, and that ratification of this
agreement is in the best interest of the City; now, therefore
BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF YAKIMA:
The City Manager's execution of the Professional Services Agreement with KBA, Inc.
attached hereto and incorporated herein by this reference not to exceed Six Hundred
Thousand dollars ($600,000) to provide Construction Management Services for Phase 1 of
the North 1st Street Revitalization Project is ratified by City Council.
ADOPTED BY THE CITY COUNCIL this 2nd day of April, 2019.
Kathy Coffey, Mayor
ATTEST:
Sonya Claar Tee, City Clerk
4
For City of Yakima Use Only:
Contract No, 34ici -01
Project No, >A
Resolution No.
SOQ No.�_���__�
AGREEMENT
BETWEEN
CITY OF YAN3MA,WASH|NGTON
AND
KBA, Inc.
FOR PROFESSIONAL SERVICES
5
THIS AGREEMENT, made and entered into on this day of , 2019, by and
between the City of Yakima, Washington, a municipal corporation with its principal office at 129 North
Second Street, Yakima, WA 98908, (hereinafter referred to as "CITY"), and KBA, Inc. with its principal
office at 11201 SE 8th Street, Suite 160, Bellevue, WA 98004 (hereinafter referred to as
"CONSULTANT"); ; said corporation being licensed and registered to do business in the State of
Washington, and will provide Construction Management services under this Agreement for the North 1st
Street Revitalization — SR 12 to "N" Street project on behalf of the City of Yakima. Project No.
2~310 . herein referred to as the "PROJECT."
WITNESSETH:
RECITALS
WHEREAS, CITY desires to retain the CONSULTANT to provide Construction Management
services for construction of the PROJECT, as described in this Agreement and subsequent Amendments
thereto; and
VVHEREAG. CONSULTANT represents that it has available and oflers to provide personnel with
knowledge and experience necessary to satisfactorily accomplish the work within the required time and
that it has no conflicts of interest prohibited by law from entering into this Agreement;
NOW, THEREFORE, CITY and CONSULTANT agree as foliows:
SECTION 1 INCORPORATION OF RECITALS
1.1 The above recitals are incorporated into these operative provisions of the Agreement.
SECTION 2 SCOPE OF SERVICES
2.0i1 CONSULTANT agrees to perform those services described hereafter. Unless modified in
writing by both oadem, duties of CONSULTANT shall not be construed to exceed those
services specifically set forth herein.
2.0.2 CONSULTANT shall use its best efforts to maintain continuity in personnel and shall
assign, 1<. Wondell Adams as Principal -in -Charge throughout the term of this Agreement
unless other personnel are approved by the CITY.
2.1 Basic Gervices: CONSULTANT agrees to perform those tasks described in Exhibit A, entitled
"Scope of Sanicea^ (WORK) which is attached hereto and made a part of this Agreement as if
fully set forth herein.
2.2 CITY and CONSULTANT agree that not all WORK to be performed by
CONSULTANT can be defined in detail at the time this Agreement is exeou1ed, and that
additional WORK related to the Project and not covered in Exhibit A may be needed during
performance of this Agreement. CITY may, at any time, by written onjer, direct the
CONSULTANT to revise portions of the PROJECT WORK previously completed in a satisfactory
monner, delete portions of the PROJECT, or request that the CONSULTANT perform additional
WORK beyond the scope of the PROJECT WORK. Such changes hereinafter shall be referred
to as "Additional Services."
Page 1
6
2.2.1 If such Additional Services cause an increase or decrease in the CONSULTANT'S cost
of, or time required for, performance of any services under this Aomnment, a contract
price and/or completion time adjustment pursuant to this Agreement shall be negotiated,
and this Agreement shall be modified in writing and accepted by the parties hereto.
2.2.2 Compensation for each such request for Additional Services shall be negotiated by the
CITY and the CONSULTANT according to the provisions set forth in Exhibit B. attached
hereto and incorporated herein by this roforenoe, and if so authohzed, shall be
considered part of the PROJECT WORK. The CONSULTANT shall not perform any
Additional Services until so authorized by CITY and agreed to by the CONSULTANT in
writing.
SECTION 3 CITY'S RESPONSIBILITIES
3.1 CITY -FURNISHED DATA: The CITY will provide to the CONSULTANT all technical data in the
CITY'S possession relating to the CONSULTANT'S services on the PROJECT including
information on any pre-existing conditions known to the CITY that constitute hazardous waste
contamination on the PROJECT site as determined by an authorized regulatory agency.
3.2 ACCESS TO FACILITIES AND PROPERTY: The CITY will make its facilities reasonably
accessible to CONSULTANT as required for CONSULTANTS performance of its services and
will provide labor and safety equipment as reasonably required by CONSULTANT for such
access.
3.3 TIMELY REVIEW: The CITY will examine the CONSULTANTS utudiea, vepodo, oke1chea,
drawings, specifications, proposals, and other documents; obtain advice of an attorney, insurance
oounam|nr, anoounhant, auditor, bond and financial advioom, and other consultants as CITY
deems appropriate; and render in writing decisions required of CITY in a timely manner. Such
examinations and deoiniona, howaver, shall not relieve the CONSULTANT of any contractual
obligations nor of its duty to render professional services meeting the standards of care
applicable to its profession.
3.4 CITY shall appoint aCITY'S Representative with respect to WORK to be performed under this
Agreement. CITY'S Representative shall have complete authority to transmit instructions and
receive information. CONSULTANT shall be entitled to reasonably rely on such instructions
made by the CITY'S Representative unless otherwise directed in writing by the CITY, but
CONSULTANT shall be responsible for bringing to the attention of the CITY'S Representative any
instructions which the CONSULTANT believes are inadequado, inonmp|eto, or inaccurate based
upon the CONSULTANTS knowledge.
3.5 Any documents, services, and reports provided by the CITY to the CONSULTANT are available
solely as additional information to the CONSULTANT and will not relieve the CONSULTANT of its
professional duties and obligations under this Agreement or at Iaw. The CONSULTANT shall be
entitled to reasonably rely upon the accuracy and the completeness of such documents, services
and noporte, but shall be responsible for exercising customary professional care in using and
reviewing such documents, services, and reports and drawing conclusions from them.
SECTION 4 AUTHORIZATION, PROGRESS, AND COMPLETION
4.1 In signing this Aoraemart. CITY grants CONSULTANT specific authorization to proceed with
WORK described in Exhibit A. The time for completion is defined in Exhibit A, or as amended.
SECTION 5 COMPENSATION
5.1 COMPENSATION ON A TIME SPENT BASIS AT SPECIFIC HOURLY RATES: For the services
described in Exhibit A. compensation shall be according to the Exhibit B - Cost Estimate,
attached hereto and incorporated herein by this refan*nue, on a time spent basis plus
Page 2
7
5.1.1 DIRECT NON -SALARY EXPENSES: Direct Non -Salary Expenses are those costs
incurred on or directly for the PROJECT inn|uding, but not limited to, necessary
transportation 000ts, including current rates for CONSULTANT'S vehicles; meals and
lodging; laboratory tests and analyses; phnUng, binding and reproduction charges; all
coatsanaoniabedvvithotharnutaidanonprofasaiona|nen/inoaandfaoi|idea;apaoio|C|TY'
requested and PROJECT -related insurance and performance warranty costs; and other
similar costs. Reimbursement for Direct Non -Salary Expenses will be on the basis of
actual charges, and on the basis of current rates when furnished by CONSULTANT.
Estimated Direct Non -Salary Expenses are shown in Exhibit B.
5.1.1.1 Travel couts, including tranapodaUon, lodong, subaistenoe, and incidental
expenses incurred by employees of the CONSULTANT and each of the
Subconsultants in connection with PROJECT WORK; provided, as foliows:
• That a maximum of U.S. INTERNAL REVENUE SERVICE allowed cents
per mile will be paid for the openodnn, maintenanoe, and depreciation
costs of company or individually owned vehicles for that portion of time
they are used for PROJECT WORK. C(]NSULTANT, whenever
possible, will use the Ieast expensive form of ground transportation.
• That reimbursement for meals inclusive of tips shall not exceed the
maximum amount allowed for Yakima County by the General Services
Administration (GSA). This rate may be adjusted on a yearly basis.
• That accommodation for hotel/motel shall not exceed the maximum
amount allowed for Yakima County by the GSA. This rate may be
adjusted on a year!y basis.
+
That air travel shall be by coach o|ana, and shall be used only when
absolutely necessary.
5.1.2 Telephone charges, computer charges, in-house reproduction chergem, first class
postage, and FAX charges are not included in the direct expense nosts, but are
considered included in the Schedule of Specific Hourly Billing Rates.
5.1.3 Professional Subconsultants. Professional Subconsultants are those costs for
engineehng, ouchheotuna, geotechnical services and similar professional services
approved by the CITY. Reimbursement for Professional Subconsultants will be on the
basis of actual costs billed for services provided to the CITY through this Agreement.
Estimated Subconsultant costs are shown in Exhibit B.
5.2 Unless ly authorized in writing by the CITY, the total budgetary amount for this
PROJECT shall not exceed Six Hundred Thousand Dollars ($600,000.00). The CONSULTANT
shall make all reasonable efforts to complete the WORK within the budget and will keep CITY
informed of progress toward that end so that the budget or WORK effort can be adjusted if found
necessary. The CONSULTANT is not obligated to incur costs beyond the indicated budget, as
may be adjusted, nor is the CITY obligated to pay the CONSULTANT beyond these limits. When
any budget has been increased, the CONSULTANT'S excess costs expended prior to such
increase will be allowable to the same extent as if such costs had been incurred after the
approved increase, and provided that the City was informed in writing at the time such costs were
incurred.
5.3 The CONSULTANT shall submit to the City's Representative an invoice eacmonth for payment
for PROJECT services completed through the accounting nut -off day of the previous month.
Such invoices shall be for PROJECT services and WORK performed and costs incurred prior to
the date of the invoice and not covered by previously submitted invoices. The CONSULTANT
shall submit with each invoice a summary of time expended on the PROJECT for the current
billing period, copies of subconsultant invoioeo, and any other supporting materials and details
determined necessary by the City 10 substantiate the costs incurred. CITY will pay such invoices
within thirty (30) days of receipt and upon approval of the WORK done and amount bi||ed, or 30
days from the date the grant money is received for this proieot, whichever is later. CITY will notify
the CONSULTANT within 8 working days if any problems are noted with the invoice. CITY may
question any item in an invoice, noting to CONSULTANT the questionable item(s) and
Page 3
8
withholding payment for such item(s). The CONSULTANT may resubmit such item(s) in a
subsequent invoice together with additional supporting information requested.
5.4 If payment is not made within thirty (30) days following receipt of approved invoices (or receipt of
grant funding, whichever is later), interest on the unpaid balance shall accrue beginning with the
thirty-first (311 day at the rate of 1.0% per month or the maximum interest rate permitted by law,
whichever is less; provided, however, that no interest shall accrue pursuant to Chapter 39.76
RCW when before the date of timely payment a notice of dispute is issued in good faith by the
CITY to the CONSULTANT pursuant to the terms of RCW 39.76.020(4).
5.5 Final payment of any balance due the CONSULTANT for PROJECT services will be made within
forty-five (45) days after satisfactory completion of the services required by this Agreement as
evidenced by CITY's written acceptance and after such audit or verification as CITY may deem
necessary, together with CONSULTANT's execution and delivery of a release of all known
payment claims against CITY arising under or by virtue of this Agreement, other than such
payment claims, if any, as may be specifically exempted by the CONSULTANT from the
operation of the release in stated amounts to be set forth therein.
5.6 Payment for any PROJECT services and WORK shall not constitute a waiver or release by CITY
of any claims, right, or remedy it may have against the CONSULTANT under this Agreement or
by law, nor shall such payment constitute a waiver, remission, or discharge by CITY of any failure
or fault of the CONSULTANT to satisfactorily perform the PROJECT WORK as required under
this Agreement.
SECTION 6 RESPONSIBILITY OF CONSULTANT
6.1 The CONSULTANT shall be responsible for the professional quality, technical adequacy and
accuracy, timely completion, and the coordination of all plans, designs, drawings, specifications,
reports, and other services furnished by the CONSULTANT under this Agreement. The
CONSULTANT shall, without additional compensation, correct or review any errors, omissions, or
other deficiencies in its plans, designs, drawings, specifications, reports, and other services. The
CONSULTANT shall perform its WORK according to generally accepted standards of care by
members of the same profession currently practicing under similar circumstances, in the same
geographical area and time period, and consistent with achieving the PROJECT WORK within
budget, on time, and in compliance with applicable laws, regulations, and permits.
6.2 CITY'S review or approval of, or payment for, any plans, drawings, designs, specifications,
reports, and incidental WORK or services furnished hereunder shall not in any way relieve the
CONSULTANT of responsibility for the technical adequacy, completeness, or accuracy of its
WORK and the PROJECT WORK. CITY'S review, approval, or payment for any of the services
shall not be construed to operate as a waiver of any rights under this Agreement or at law or any
cause of action arising out of the performance of this Agreement.
6.3 In performing WORK and services hereunder, the CONSULTANT and its subcontractors,
subconsultants, employees, agents, and representatives shall be acting as independent
contractors and shall not be deemed or construed to be employees or agents of CITY in any
manner whatsoever. The CONSULTANT shall not hold itself out as, nor claim to be, an officer or
employee of CITY by reason hereof and shall not make any claim, demand, or application to or
for any right or privilege applicable to an officer or employee of CITY. The CONSULTANT shall
be solely responsible for any claims for wages or compensation by CONSULTANT's employees,
agents, and representatives, including subconsultants and subcontractors, and shall save and
hold CITY harmless therefrom.
6.4 INDEMNIFICATION:
(a) CONSULTANT agrees to defend, indemnify, and hold harmless the CITY, its elected
and appointed officials, agents, officers, employees and volunteers (hereinafter
"parties protected") from (1) claims, demands, liens, lawsuits, administrative and
other proceedings,(including reasonable costs and attorneys fees) and (2)
judgments, awards, losses, liabilities, damages, penalties, fines, costs and expenses
of any kind claimed by third parties arising out of, or related to any death, injury,
Page 4
9
damage or destruction to any person or any property to the extent caused by any
negligent act, anUon, dehuult, error, omission or willful misconduct arising out of the
CONSULTANT's performance under this Agreement. In the event that any lien is
placed upon the City's property or any of the City's ofcers, employees or agents as
a result of the negligence or willful misconduct of the CONSULTANT, the
CONSULTANT shall at once cause the same to be dissolved and discharged by
giving bond or other necessary satisfaction.
(b) CITY agrees to indemnify and hold the CONSULTANT harmless from Ioss, cost, or
expense of any kind claimed by third parties, including without limitation such |oss, cost,
or expense resulting from injuries to persons or damages to pnopedy, caused solely by
the negligence or willful misconduct of the CITY, its emnp|oyeea, or agents in connection
with the PROJECT.
(c) If the negligence or willful misconduct of both the CONSULTANT and the CITY (or a
person identified above for whom each is liable) is a cause of such third party claim, the
|oao, cost, or expense shall be shared between the CONSULTANT and the CITY in
proportion 10 their relative degrees of negligence or willful misconduct and the right of
indemnity will apply for such proportion.
(d) Nothing contained in this Section or this Agreement shall be construed to create a liability
or a right of indemnification in any third party.
6.5 In any and all claims by an employee of the CONSULTANT, any subcontractor, anyone directly or
indirectly employed by any of them, or anyone for whose acts any of them may be |iab|n, the
indemnification obligations under this Agreement shall not be limited in any way by any limitation
on the amount or types of damages, compensation, or benefits payable by or for the
CONSULTANT or a subcontractor under workers' or workmens' compensation acts, disability
benefit acts, or other employee benefit acts. The CONSULTANT specifically and expressly
waives its immunity under the Industrial Insurance Act, Title 51, RCW. Such waiver has been
mutually negotiated by the CONSULTANT and the CITY.
6.6 It is understood that any resident engineering or inspection provided by CONSULTANT is for the
purpose of determining compliance with the technical provisions of PROJECT specifications and
does not constitute any form of guarantee or insurance with respect to the performance of a
contractor. CONSULTANT does not assume responsibility for methods or appliances used by a
contractor, for a contractor's safety programs or methods, or for contractors' compliance with laws
and regulations. CITY shall use its best etforts to ensure that the construction contract requires
that the contractor(s) indemnify and name CITY, the CITY's and the CONGULTANT'a nffioero,
principa|o, amnp|oyeao, agenta, ropreoentetivao, and engineers as additional insureds on
contractor's insurance policies covering PRCQECT, exclusive of insurance for CONSULTANT
professional liability.
6.7 SUBSURFACE INVESTIGATIONS: In aui|a, foundadnn, groundwater, and other subsurface
invoaUgaUona, the actual characteristics may vary significantly between successive test points
and sample intervals and at locations other than where obaonoaion, exp|nration, and
investigations have been made. Because of the inherent uncertainties in subsurface evaluations,
changed or unanticipated underground conditions may occur that could affect total PROJECT
cost and/or execution. These conditions and cost/execution effects are not the responsibility of
the CONSULTANT.
SECTION 7 PROJECT SCHEDULE AND BUDGET
7.1 The general PROJECT schedule and the budget for both the entire PROJECT and its component
tasks shall be as set forth in this Agreement and attached Exhibits. The project schedule and
performance dates for the individual tasks shall be mutually agreed to by the CITY and the
CONSULTANT within fifteen (15) days after execution of this Agreement. The performance dates
and budgets for tasks may be modified only upon written agreement of the parties hereto. The
performance date for tasks and the completion date for the entire PROJECT shall not be
ex1anded, nor the budget increased because of any unwarranted delays attributable to the
CONSULTANT, but may be extended or increased by the CITY in the event of a delay caused by
Page 5
10
special services requested by the CITY or because of unavoidable delay caused by any
governmental action or other conditions beyond the control of the CONSULTANT which could not
be reasonably anticipated or avoided.
7.2 The CONSULTANT shall submit to the CITY'S Representative a Construction Progress Report
no later than the tenth (10'h) day of each calendar month during the performance of the
SECTION 8 REUSE OF DOCUMENTS
8.1 All internal WORK products of the CONSULTANT are instruments or services of this PROJECT.
There shall be no rouoe, change, or alteration by the CITY or others acting through or on behalf
of the CITY without written permission of the CONSULTANT, which shall not be unreasonably
withheld and will be at the C|TY'a sole risk. The CITY agrees to indemnify the CONSULTANT
and its officers, emp|oyeeo, ouboontroutorn, and affiliated corporations from all claims, damages,
|oaoea, and costs including, but not Iimited to, litigation expenses and attorney's fees arising out
of or related to such unauthorized reuse, change, or alteration; pnuvidod, hovvmvor, that the
CONSULTANT will not be indemnified for such claims, damages, |oeaee, and costs including,
without limitation, litigation expenses and attorney fees if they were caused by the
CONSULTANT'e own negligent acts or omissions.
8.2 The CONSULTANT agrees that any and all p|ana, drawings, designs, specifications, computer
pnognamo, technical repnrto, operating manuodo, calcu|aUono, noteo, and other WORK submitted
or which are specified to be delivered under this Agreement or which are developed or produced
and paid for under this Agreement, whether or not complete, shall be owned by and vested in the
CITY.
8.3 All rights to patento, trademarko, copyrights, and trade secrets owned by CONSULTANT
(hereinafter "Intellectual Property") as well as any mndifioeUono, updates or enhancements to said
Intellectual Property during the performance of the WORK remain the property of CONSULTANT,
and CONSULTANT does not grant CITY any right or license to such Intellectual Property.
SECTION 9 AUDIT AND ACCESS TO RECORDS
9.1 The CONSULTANT, including its subconsultants, shall maintain bnoho, renondo, documents and
other evidence directly pertinent to performance of the WORK under this Agreement in
accordance with generally accepted accounting principles and practices consistently applied.
The CITY, or the C|TY'a duly authorized vepnaoen1a1iwa, shall have access to such booko,
neoonda, dnoumento, and other evidence for inapeoUon, audit, and copying for a period of three
years after completion of the PROJECT. The CITY shall also have access to such booko,
oeoovdo, and documents during the performance of the PROJECT WORK, if deemed necessary
by the CITY, to verify the CONSULTANTs WORK and invoices and/or to comply with the Public
Records Act, RCW 42.56.
9.2 Audits conducted pursuant to this section shall be in accordance with generally accepted auditing
standards and established procedures and guidelines of the reviewing or auditing agency.
9.3 The CONSULTANT agrees to the disclosure of all information and reports resulting from access
to records pursuant to this section provided that the CONSULTANT is afforded the opportunity for
an audit exit conference and an opportunity to comment and submit any supporting
documentation on the pertinent portions of the drafaudit report and that the final audit report will
include CONSULTANT's written comments, if any.
9.4 The CONSULTANT shall ensure that the foregoingparagnaphoareindudedinnechsubcontrao
for WORK on the Project.
9.5 Any charges of the CONSULTANT paid by the CITY which are hound by an audit to be
Page 6
11
SECTION 10 INSURANCE
10.1 At all times during performance of the WORK, CONSULTANT shall secure and maintain in effect
insurance to protect the CITY and the CONSULTANT from and against all claims, damages,
|omoea, and expenses arising out of or resulting from the performance of this Agreement.
CONSULTANT shall provide and maintain in force insurance in limits no Iess than those stated
be|ow, as applicable. The CITY reserves the right to require higher limits should it deem it
necessary in the best interest of the public. If CONSULTANT carries higher coverage Iimits than
the limits stated be|ow, such higher Iimits shall be shown on the Certificate of Insurance and
Endorsements and CONSULTANT shall be named as an additional insured for such higher limits.
10.1.1 Commercial General Liability Insurance. Before this Agreement is fully executed by
the padiea. CONSULTANT shall provide the CITY with a certificate of insurance as
proof of commercial liability insurance and commercial umbrella liability insurance with
a total liability limit of the limits required in the po|icy, subject to minimum limits of Two
Million Dollars (G2.000.000.00) per occurrence combined single limit bodily injury and
property damage, and Two Million Dollars ($2.000.000.00) general aggregate. The
certificate shall clearly state who the provider is, the coverage amnurt, the policy
number, and when the poiicy and provisions provided are in effect. Said policy shall be
in etfect for the duration of this Agreement. The policy shall name the CITY, its elected
and appointed officia|o, officem, agento, emp|oyooa, and volunteers as additional
insureds. The insured shall not cancel the insurance coverage in this amount without
first giving the CITY five (5) calendar days prior written notice. The insurance shall be
with an insurance company or companies ratadA'V|| or higher in Best's Guide and
admitted in the State of Washington.
101.2. Commercial Automobile Liability Insurance.
a. If CONSULTANT owns any vehicles, before this Agreement is fully executed by
the partieo. CONSULTANT shall provide the CITY with a certificate of insurance as
proof of commercial automobile liability insurance and commercial umbrella liability
insurance with a total liability limit of the limits required in the po|ioy, subject to
minimum limits of Two Million Dollars ($2.000.000.00) per occurrence combined single
limit bodily injury and pnnpertydammga. Automobile liability will apply 10 "Any Auto"
and be shown on the cer(ificate.
b. If CONSULTANT does not own any vehicles, only "Non -owned and Hired
Automobile Liability" will be required and may be added to the commercial liability
coverage at the same limits as required in that section of this Aonnament, which is
Section 10.1.1 entitled "Commercial General Liability Insurance".
c. Under either situation described above in Section 10.1.2.a. and Section 10.1.2.b.,
the required certificate of insurance shall clearly state who the provider is, the
coverage amount, the policy number, and when the policy and provisions provided are
in effect. Said policy shall be in effect for the duration of this Agreement. The policy
shall name the CITY, its elected and appointed ufficia|a, offioero, agents, employees,
and volunteers as additional insureds. The insured shall not cancel the insurance
coverage in this amount without first giving the CITY five (5) calendar days prior written
notice. The insurance shall be with an insurance company or companies rated A -VII or
higher in Best's Guide and admitted in the State of Washington.
10.1.8. Statutory workers' compensation and employer's liability insurance as required by state
10J4. Professional Liability Coverage. Betore this Contract 15 fufly executed by the parties,
CONSULTANT shall provide the City with a certificate of insurance as proof of
professional liability coverage with a total liability limit of the limits required in the policy,
subject to minimum limits of Two Million Dollars ($2.000.000.00) per claim, and Two
Million Dollars ($2'000.000.00) aggregate. The certificate shall dearly state who the
provider is, the coverage amount, the policy number, and when the policy and
Page 7
12
Contract. The insured shall not cancel the insurance coverage in this amount without
first giving the CITY five (5) calendar days prior written notice. The insurance shall be
with an insurance company or companies rated A -VII or higher in Best's Guide. If the
policy is written on a claims made basis the coverage will continue in force for an
additional two years after the completion of this contract.
Failure of either or all of the additional insureds to report a claim under such insurance
shall not prejudice the rights of the CITY, its elected and appointed offinia|a, officers,
employees, agents, and representatives there under. The CITY and the CITYs elected
and appointed offioia|o, officers, principals, emp|oyeee, napneaentativaa, and agents
shall have no obligation for payment of premiums because of being named as
additional insureds under such insurance.
SECTION 11 SUBCONTRACTS
11.1 CONSULTANT shall be entitlad, to the extent determined appropriate by CONSULTANT, to
subcontract any portion of the WORK to be performed under this Agreement.
11.2 Any subconsultants or subcontractors to the CONSULTANT utilized on this PROJECT, including
any substitutions thereof, will be subject to prior approvaby CITY, which approval shall not be
unreasonably withheld. Each subcontract shall be subject to review by the C|TY'a
Repreaentadive, if naquneted, prior to the subconsultant or subcontractor proceeding with the
WORK. Such review shall not constitute an approval as to the legal form or content of such
subcontract. The CONSULTANT shall be responsible for the architectural and engineering
performance, acts, and omissions of all persons and firms performing subcontract WORK.
11.3 CITY does not anticipate CONSULTANT subcontracting with any additional persons or firms for
the purpose of completing this Agreement.
11.4 The CONSULTANT shall submit, along with its monthly invoicen, a description of all WORK
completed by subconsultants and subcontractors during the preceding month and copies of all
invoices thereto.
SECTION 12 ASSIGNMENT
12.1 This Agreement is binding on the heina, successors and assigns of the parties hereto. This
Agreement may not be assigned by CITY or CONSULTANT without prior written consent of the
other, which consent will not be unreasonably withheld. It is expressly intended and agreed that
no third party beneficiaries are created by this Aoreement, and that the rights and remedies
provided herein shall inure only to the benefit of the parties to this Agreement.
SECTION 13 INTEGRATION
13.1 This Agreement represents the entire understanding of GITY and CONSULTANT as to those
matters contained herein. No prior oral or written understanding shall be of any force or effect
with respect to those maUero covered herein. This Agreement may not be modified or altered
except in writing signed by both parties.
SECTION 14 JURISDICTION AND VENUE
14.1 This Agreement shall be administered and interpreted under the laws of the State of Washington.
Jurisdiction of litigation arising from this Agreement shall be in Washington State. If any part of
this Agreement is found to conflict with applicable laws, such part shall be inoperative, null, and
void insofar as it conflicts with said laws, but the remainder of this Agreement shall be in full force
and effect. Venue for all disputes arising under this Agreement shall lie in a court of competent
jurisdiction in Yakima County, Washington.
SECTION 15 EQUAL EMPLOYMENT and NONDISCRIMINATION
15.1 During the performance of this Agreement, CONSULTANT and CONSULTANT's subconsultants
Page 8
13
law or regulation on the basis of age, sex, race, creed, ndigion, color, national ohgin, marital
ntatuo, dieabi|hx, honorably discharged veteran or military status, pvegnancy, sexual uhentadon,
and any other classification protected under fedena|, state, or local law. This provision shall
include but not be limited to the following: emp|nymen1, upgruding, dmmctiun, tnunafer,
recruitment, advertising, layoff or tenninsdion, rates of pay or other forms of compenoatinn,
selection for training, and the provision of services under this Agreement. CONSULTANT
agrees to comply with the applicable provisions of State and Federal Equal Employment
Opportunity and Nondiscrimination statutes and reguiations.
SECTION 16 SUSPENSION OF WORK
16.1 CITY may suspend, suspend, in writing by certified mail, ali or a portion of the WORK under this Agreement
if unforeseen circumstances beyond CITY's control are interfering with normal progress of the
WORK. CONSULTANT may suspend, in writing by certified mai|, all or a portion of the WORK
under this Agreement if unforeseen circumstances beyond CC)NGULTANT'o control are
interfering with normal progress of the WORK. CONSULTANT may suspend WORK on the
PROJECT in the event CITY does not pay invoices when due, except where otherwise provided
by this Agreement. The time for completion of the WORK shall be extended by the number of
days WORK is suspended. If the period of suspension exceeds ninety (90) days, the terms of
this Agreement are subject to nanegoUatimn, and both parties are granted the option to terminate
WORK on the suspended portion of Pject in accordance with SECTION 17.
SECTION 17 TERMINATION OF WORK
17.1 Either party may terminate this Agreement, in whole or in part, if the other party materially
breaches its obligations under this Agreement and is in default through no fault of the terminating
party. However, no such termination may be effected unless the other party is given: (1)not less
than fifteen (15) calendar days written notice delivered by certified mai|, return receipt raquaoted,
of intent to terminate; and (2) an opportunity for consultation and for cure with the terminating
party before termination. Notice shall be considered issued within seventy-two (72) hours of
mailing by certified mail to the place of business of either party as set forth in this Agreement.
17.2 In addition to termination under subsection 17.1 of this SaoUon. CITY may terminate this
Agreement for its convenience, in whoie or in part, provided the CONSULTANT is given: (1) not
less than fifteen (15) calendar days written notice delivered by certified mail, return receipt
noquaaLad, of intent to terminate; and (2) an opportunity for consultation with CITY before the
effective termination date.
17.3 K CITY terminates for default on the part of the CONSULTANT, an adjustment in the contract
price pursuant to the Agreement shall be made, but (1) no amount shall be allowed for anticipated
profit on unperformed services or other WORK, and (2) any payment due to the CONSULTANT
at the time of termination may be adjusted to the extent of any additional costs or damages CITY
has inournad, or is likely to incur, because of the CONSULTANT'S breach. In such event. CITY
shall consider the amount of WORK originally required which was satisfactorily completed to date
of terminoUon, whether that WORK is in a form or of a type which is usable and suitable to CITY
at the date of termination and the cost to CITY of completing the WORK itself or of employing
another firm to complete it. Under no circumstances shall payments made under this provision
exceed the contract price. in the event of defauit, the CONSULTANT agrees to pay CITY for any
and all damugee, 000ta, and expenses whether directly, indine(t|y, or consequentiaiiy caused by
said default. This provision shall not preclude CITY from filing claims and/or commencing
litigation to secure compensation for damages incurred beyond that covered by contract
retainage or other withheid payments.
17.4 If the CONSULTANT terminates for defak on the part of CITY or if CITY terminates for
convenience, the adjustment pursuant to the Agreement shall include payment for services
satisfactorily performed to the date of termination, in addition to termination settiement costs the
CONSULTANT reasonably incurs reiating to commitments which had become firm before the
termination, uniess CITY determines to assume said commitments.
17.5 Upon receipt of a termination notice under subsections 17.1 or 17.2 above, the CONSULTANT
Page 9
14
deliver or otherwise make available to CITY all originals of data, drawings, specifications,
calculations, nepnrte, nohma1ae, nummmhan, and such other infnnnaUnn, doouments, and
materials as the CONSULTANT or its subconsultants may have accumulated or prepared in
performing this Agreem*nt, whether completed or in pnognaea, with the CONSULTANT retaining
copies of the same.
17.6 Upon terminatiounder any subparagraphabov.CITYreserves the right to prosecute the
WORK to completion utilizing other qualified firms or individuals; provided, the CONSULTANT
shall have no responsibility to prosecute further WORK thereon.
17.7 If, after termination for failure of the CONSULTANT to fulfill contractual ob|igadona, it is
determined that the CONSULTANT has not so failed, the termination shall be deemed to have
been effected for the convenience of CITY. In such avant, the adjustment pursuant to the
Agreement shall be determined as set forth in subparagraph 17.4 of this Section.
17.8 If, because of death, unavailability or any other occurrence, it becomes impossible for any key
personnel employed by the CONSULTANT in PROJECT WORK or for any corporate officer of
the CONSULTANT to render his services 10 the PROJECT, the CONSULTANT shall not be
relieved of its obligations to complete performance under this Agreement without the concurrence
and written approval of CITY. If CITY agrees to termination of this Agreement under this
provision, payment shall be made as set forth in subparagraph 17.3 of this Section.
SECTION 18 DISPUTE RESOLUTION
18.1 In the event that any dispute shall arise as to the ior performance of this Agreement,
or in the event of a notice of default as to whether such default does constitute a breach of the
contraot, and if the parties hereto cannot mutually settle such ddferencoe, then the parties shall
first pursue mediation as a means to resolve the dispute. If neither of the afore mentioned
methods are successful then any dispute relating to this Agreement shall be decided in the courts
of Yakima County, in accordance with SECTION 14. If both parties consent in wriUng, other
available means of dispute resolution may be implemented.
SECTION 19 NOTICE
19.1 Any notice required to be given under the terms of this Agreement shall be directed to the party at
the address set forth betow. Notice shall be considered issued and effective upon receipt thereof
by the addressee -party, or seventy-two (72) hours after mailing by certified mail to the place of
business set forth below, whichever is earlier.
CITY: City of Yakima
129 N. 2nd Street
Yakima, WA 9890
Attn: Bob Desgrosellier, Sr. Engineer
CONSULTANT: KBA, Inc.
112U1GE8th Street, Suite 180
Bellevue, WA 98004
Attn: Deborah Ottum, CPCM
[SIGNATURE PAGE BEGINS ON FOLLOWING PAGE]
Page 10
15
IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed by their
respective, authorized officers or representatives as of the day and year first above written.
CITY OF YAKIMA
CilcMoore
Printed Name:e
iff
Title: City Manager
Printed Name: erf-
Title; \'' res ct,on
CITY CONTRACT NO• 25 1 --(2/11
RESOLUTION NO; a
Page 11
STATE OF WASHINGTON
) ss.
COUNTY OF YAKIMA
16
I certify that I know or have satisfactory evidence that Cliff Moore is the person who appeared before me,
and said person acknowledged that he signed this instrument, on oath stated that he was authorized to
execute the instrument, and acknowledged it as the CITY MANAGER of the CITY OF YAKIMA, to be the
free and voluntary act of such party for the uses and purposes mentioned in the instrument.
Dated:
Seal or Stamp
i0" R
-gfr,
ye„
(Signatur
611
Printed Na
r-9
e,
My commission expires:
Page 12
STATE OF WASHINGTON
)ss.
COUNTY OF v‘3.1
J
I certify that I know or have satisfactory evidence that
appeared before me, and said person acknowledged
atlsh was authorized to execute the
., 4. of .:k M.iL•
for the uses and purposes mentioned in the instrument
17
KV\5 {, LU is the person who
that he/she signed this instrument, on oath stated
instrument, and acknowledged it as the
to be the free and voluntary act of such party
Dated:
Seal or Stamp
Printed Name
My commission expires:
Page 13
KBA, Inc.
EXHIBIT A
SCOPE OF SERVICES
Construction Management Services
for
North 1st Street Revitalization — SR 12Nm'N'Street
18
March 7, 2019
KBA, Inc.(Consultant) will provide Construction Management (CM) services to City of Yakima (Agency),
for the PjeotknmwnaaA&»rthlst Street Revitalization —SRt2bm'N'Street. These services will
include consultation, contract administration, field observation, documentation, and material testing, as
required during the construction ofthe Project, aadotai|edbe|ow.
Project Description: The project consists of reconstructing the existing roadway and the work includes
roadway excavation, HMA, curb, gutter and sidewalk, stormwater collection/treatment/conveyance,
grading, water and sanitary sewer mainline vep|aoement, aigning, athping, illumination, irrigation,
Iandscaping and other work. The Designer of Record on this projectject is PBS (Designer).
I. CONSTRUCTION MANAGEMENT SERVICES
A. Consultant Contract and Team Management. Provide overall day-to-day management of
the consultant contracand team, including:
1. Decide on best modes and frequency of communication with Agency and Designer. Liaison
and coordinate with Agency on a regular basis to discuss Pject issues and status.
2. Manage Consultant Team, comprised of Consultant's staff and subconsultant. Organize and
Iayout work for Consultant Team.
3. Review month!y expenditures and Consultant Team scope activities. Prepare and submit to
Agency monthly, an invoice and progress report describing Consultant Team services
provided that month. Prepare and submit reporting required by funding source(s), if any.
Deliverables
• Monthly invoices and progress reports
B. Preconstruction Services
1. Review Contract Documents to familiarize team with Project requirements.
2. Provide one set of preconstruction photographs and video.
Deliverables
• Preconstruction photos, digital files on electronic storage medium
C. Construction Phase Services — Contract Administration
1. Liaison with the Agency, construction contractor, Designer, appropriate agencies, property
owners, and utilities.
2. Provide the Agency with brief monthly construction progress reports, highlighting progress
and advising of issues which are likely to impact cost, schedule, or quality/scope.
3. Schedule Review:
a. Review construction contractor's schedules for compliance with Contract Documents.
b. Monitor the construction contractor's conformance to schedule and require revised
schedules when needed. Advise Agency of schedule changes.
1*23-01-Yakima'North-/m-Street maftsaNegotiationReco"ds \ I n-houseDrafts Exhiu+A-S=pe-v5-P5Ae*0307.docx 1 of 6
19
KBA, Inc. March 7, 2019
4. Progress Meetings. Lead regular (usually weekly) progress meetings with the construction
contractor, including Agency pre -briefing. Prepare weekly meeting agenda and meeting
notes, and distribute copies to attendees. Track outstanding issues on a weekly basis.
5. Manage Submittal Process. Track and review, or cause to be reviewed by other appropriate
party, work plans, shop drawings, samples, test reports, and other data submitted by the
construction contractor, for general conformance to the Contract Documents.
6. Record of Materials. Maintain provided Record of Materials indicating anticipated material
appnova|a, material compliance duuum*nta1iun, and materials testing requirements. Maintain
records of material compliance documentation received and advise of any known
deficiencies.
7. Prepare weekly statement of working days and distribute to the Agency and Contractor.
8. Manage RFI (Request for Information) process. Track and review/evaluate, or cause to be
reviewed/evaluated by other appropriate party, RFIs. Manage responses to RFIs.
R. Change Management. Evaluate entitlement, and prepare scope, impact, and independent
estimate for change orders. Facilitate resolution of change orders.
10. Monthly Pay Requests. Prepare monthly requests for payment and/or review payment
requests submitted by the construction contractor. Review with Agency and construction
contractor, and recommend approval, as appropriate.
11. Evaluate construction contractor's Schedule of Values for lump sum items. Review the
Contract Price allocations and verify that such allocations are made in accordance with the
requirements of the Contract Documents.
12. Notify construction contractor of noncompliance.
13. Prevailing Wage Monitoring:
a. Monitor Payroll Compliance. Review Statements of Intent to Pay Prevailing Wage
against the Contract Document requirements. Collect, record, and check weekly certified
payrolls and conduct on-site wage interviews, both at a frequency documented in
accordance with Agency guidelines.
14. Assist the Agency in the investigation of malfunctions or failures during construction.
15. Public Information. Provide information for Agency to prepare media communications and
public notices on Project status. Provide information for Agency's inclusion into a Project
website and/or newsletters, if requested.
16. Record Drawings. Review not Iess than monthly, the construction contractor's redline set of
contract plans. Maintain a CM Team set of conformed drawings tracking plan changes,
location of discovered anomalies and other items, as encountered by the CM team. Use
these markups to check the progress of the Contractor -prepared Record Drawings.
17. Document Control. Establish and maintain document filing and tracking systems, following
Agency guidelines and meeting funding agency requirements. Collect, organize, and prepare
documentation on the PjaoL.
a. One hard copy of files will be kept in the Pjactfie|doffine
b. Electronic documentation wilI be stored in a Project Website, uaing SharePoint software,
managed and hosted by the Consultant.
c. The Project SharePoint site will transition to "read-only" access upon expiration of the
Agreement, or upon pject completion and transfer of final records, whichever occurs
first. Transference of final records will include a digital copy of the files stored in the
Project SharePoint site. Access to SharePoint will expire following that date.
eAP,+`23-0,r"wma-w *h-,*-Stre°mDr"ftsuweg"ationoec"mm"o"="m° /n*oD7.d"cx 2 of 6
20
KBA, Inc.March 7, 2019
18. Project Closeout. Prepare Certificates of Substantial (including punch Iist), Physical, and
Final Completion for Agency approvaand signature. Prepare final pay estimate for Agency
approval and processing.
19. Final Records. Compile and convey final Pject records, transferring to the Agency for
archiving at final acceptance of the Pjeot. Records will consist of hard copy originals and
electronic records on electronic storage medium.
Deliverables
�
Monthly Construction ProgresReports
w
Schedule Review Comments
• Meeting Agendas and Notes
• Submittal Log
• Completed Record of Materials
• RFI Log
• Change Order(s)
�
Progress Pay Requests
• Certificates of Completion
• Final records — hard copy and electronic
D. Construction Phase Services — Field
1. Observe the technical conduct of the construction, including providing day-to-day contact with
the construction contractor, Agency, utilities, and other stakeholders, and monitor for
adherence to the Contract Documents. The Consultant's personnel will act in accordance
with Sections 1-05.1 and 1-05.2 of the WSDOT/APWA Standard Specifications.
2. Observe material, workmanship, and construction areas for compliance with the Contract
Documents and applicable codes. Advise the Agency of any non -conforming work observed
during site visits.
S. Prepare Inspector Daily Reports (IDRs), recording the construction contractor's operations as
actually observed by the Consultant; includes quantities of work placed that day, contractor's
equipment and crews, and other pertinent information.
4. Interpret Construction Contract Documents, in coordination with Designer.
5. Evaluate issues which may arise as to the quality and acceptability of material furnished,
work performed, and rate of progress of work performed by the construction contractor.
O. Establish communications with adjacent property owners. Respond to questions from
property owners and the general public.
7. Coordinate with permit holders on the Project to monitor compliance with approved permits, if
applicable.
8. Prepare field records and documents to help facilitate administration of the Projectin
accordance with funding agency requirements.
Q. Attend and actively participate in regular on-site meetings.
10. Take periodic digital photographs during the course of construction. Photographs to be
Iabeled and organized as detailed in the CM PIan.
11. Punch List. Upon substantial completion of work, coordinate with the Agency and affected
agenoino, to prepare a 'punch list' of items to be completed or corrected. Coordinate final
inspection with those agencies.
12. Testing. Conduct or cause to be conducted, materials and laboratory tests. Coordinate the
work of the Field Representative(s) and testing laboratories in the observation and testing of
WBP14,o*/v°ki~~worth-/st-m n*uw.d"cx 3 of 6
KBA, Inc.
21
March 7, 2019
materials used in the construction; document and evaluate results of testing; and inform
Agency and construction contractor of deficiencies.
Deliverables
• IDRs with Pject photos — submitted on a weekly basis
• Punch List(s)
• Test reports
E. Assumptions
1. Budget:
a. Staffing Ievels are anticipatedin accordance with the attached budget estimate.
Consultant services are budgeted from Marh 11, 2019 through November 15, 2019.
This is intended to span the originally planned construction duration of 160 contractor
working days, plus minimal time allotted for Pject closeout. Overtime has not been
figured nto the budget.
b. Consultant will work up to the Iimitations of the authorized budget. If additional budget is
needed to cover such instances as the following, Agency and Consultant will negotiate a
supplement to this Agreement:
i. The contractor's schedule requires inspection coverage of extra crews and shifts.
ii. The construction contract runs Ionger than the time period detailed above.
iii. Any added scope tasks.
iv. The work is anticipated to be performed during daytime hours. Should night work be
necessary, a 15 percent differential for labor will be applied to all night shift hours
worked by Consultant's employees.
c. The budget allocations shown on Exhibit B, are itemized to aid in Project tracking
purposes only. The budget may be transferred between people, or between labor and
expenses, provided the total contracted amount is not exceeded without prior
authorization.
d. The budget assumes that Consultant's standard formsIogs, and processes will be used
on the Project SharePoint site. Any customization 10 meet specialized Agency
requirements will be Extra Work.
e. Should Consultant's level of effort extend beyond the time period detailed in the attached
Exhibit B - Estimate, and into a new year, labor rates will adjust annually on January 1,
with 30 -day written notice to Agency.
2~ Items and Services Agency will provide:
a. Meeting arrangements and facilities for pre-bid and preconstruction meetings. Prepare
and distribute meeting notes from pre-bid meeting(s), if any.
b. Field C)ffioe, including:
i. Workstations (desk, chair, and storage) for 3 staif
ii. Conference table and chairs
iii. Combination printer/copier/scanner with 11x17 size and color capabilities
iv. High speed, dedicated connection, preterably with a static IP
v. Miscellaneous office supplies
vi. Utilities and sanitary facilities
c. Retain Engineer of Record for shop drawing review, RFIs, design changes, and final
record drawings.
d. Coordination with and enforcement of utility franchise agreements and/or contracts and
schedules for services related to this Project.
mproj"cts \vontra"ts \clie"1W°w~°mp,^,23*,+"kim~n.rlh-1w-Stre~w»°fts&wegm°tio"Records I"+= ,"*om*"cx 4 of 6
KBA, Inc.March 7, 2019
22
e. Verify that the required permits, bonds, and insurance have been obtained and submitted
by the construction contractor. Obtain all permits not required to be provided by
construction contractor.
f. Construction Survey. Provide projeccontrol survey and staking that is not already
assigned to the construction contractor.
3. Scope:
a. The SharePoint tool being used on this Project is proprietary to the Consultant (KBA,
Inc.), and may not be used by any other party or on any other project without the written
permission and involvement of KBA, Inc.
b. Consultant will provide observation services for the days/hours that its' Inspector(s)
personnel is/are on-site. The Inspector(s) will not be able to observe or report
construction antiviUea, or collect documentation, during the time they are not on-site.
c. The Consultant's monitoring of the construction contractor's activities is to ascertain
whether or not they are performing the work in accordance with the Contract Documents;
in case of noncompliance, Consultant wiII rejectject non -conforming work and pursue the
other remedies in the interests of the Agonoy, as detailed in the Contract Documents.
The Consultant cannot guarantee the construction contractor's performance, and it is
understood that Consultant shall assume no responsibility for proper construction means,
methods, techniqueo. Project site aafety, safety precautions or programs, or for the failure
of any other entity to perform its work in accordance with laws, contracts, regulations, or
Agency's expectations.
d. Definitions and Roles. The use of the term "inspect" in relation to Consultant services is
synonymous with "construction observation, and reference to the "Inspector" role is
synonymous with "Field Representative," and means: performing on-site observations of
the progress and quality of the Work and determining, in general, if the Work is being
performed in conformance with the Contract Documents; and notifying the Agency if
Work does not conform to the Contract Documents or requires special inspection or
testing. Where "Specialty Inspector" or "specialty inspection" is used, it refers to
inspection by a Building Official or independent agent of the Building Official, or other
licensed/certified inspector who provides a certified inspection report in accordance with
an established standard.
e. Because of the prior use of the Projecsite, there is a possibility of the presence of toxic
or hazardous materials. Consultant shall have no responsibility for the discovery,
presence, handling, removal or disposal of toxic or hazardous materials, or for exposure
of persons to toxic or hazardous materials in any form at the Prject site, including but
not limited to asbestos, asbestos products, polychlorinated biphenyl (PCB), or other toxic
substances. If the Consultant suspects the presence of hazardous materials, they will
notify the Agency immediately for resolution.
L Review of Shop Drawings, samples, and other submittals will be for general conformance
with the design concept and general compliance with the requirements of the contract for
construction. Such review will not relieve the Contractor from its responsibility for
performance in accordance with the contract for construction, nor is such review a
guarantee that the work covered by the shop drawings, samples and submittals is free of
errors, inconsistencies or omissions.
Any opinions of probable construction cost provided by the Consultant will be on the
basis of experience and professional judgment. However, since Consultant has no
control over competitive bidding or market conditions, the Consultant cannot and does
not warrant that bids or ultimate construction costs will not vary from these opinions of
probable construction costs.
h. Development of construction schedules and/or sequencing, and/or reviewing and
commenting on contractor's schedules, is for the purpose of estimating number of days to
Q.
+,am,-Y°mm"w"rth',sl-Street mrels^meg"liatio"oec" 9-0307.d"= 5 of 6
KBA, Inc.
23
March 7, 2019
complete a project, and for identifyingpotanUa schedule and coordination challenges
and determining compliance with the construction contract. It is not a guarantee that a
construction contractor will complete the Pject in that sequence or timeline, as means
and methods are the responsibility of the construction contractor.
L Consultant is not responsible for any costs, claims or judgments arising from or in any
way connected with mrnzre, omissions, conflicts or ambiguities in the Contract Documents
prepared by others. The Consultant does not have responsibility for the professional
quality or technical adequacy or accuracy of the design plans or specifications, nor for
their timely completion by others.
j. RCW 4.24.115 is applicable to Consultant's services provided under this Agreement.
k. Services provided by the Consultant under this Agreement will be performed in a manner
consistent with that degree of care and skill ordinarily exercised by members of the same
profession currently practicing under similar circumstances, in the same geographical
area and time period.
I. Agency agrees that Consultant will not be held liable for the completeness, correctness,
readability, or compatibility of any electronic media submitted to Agency, after an
acceptance period of 30 days after delivery of the electronic files, because data stored on
electronic media can deteriorate undetected or can be modified without Consultant's
knowledge.
m. Consultant will not be liable for any damage to the field office premises or utilities
provided by Agency, unless caused by Consultant's own negligence.
II. OPTIONAL SERVICES
All services not detailed above, are considered Optional Services, which, along with any other Extra Work
requested by the Agency, will be performed only when a mutually negotiated Supplement to this
Agreement is executed, specifying scope of services and budget.
lie"tW"mm°mp`+/23*,v°wma-worth-, " saeo.o*om.d"cx 6 of 6
0)
z
0(
0
0450
00
smoH J0
uopeu!wiepa
00
0)
0
a,
0,
cm_
O CV 0 <1 -
CO CO
CV CP
O 0
CO CV CO 0) 0)) CD
0-00
4 01 CP 0
CO
00, CV CO 0
00
0)
00
(06
g
E 4 + o")
-co co c_ 0 ,,,o.
,,- I— co 0
0
rch 12. 2019 - Novembyr 15,
KBA Labor Hours
1-
-Oh CD 00 CV
to ('400 c-
00 CO
'T" CD ,0, 0 00 CP
• 0 00 7-- CO
CO CO
COo CO (0 `,:t CC,
(0 CO <0, CO
ca n
0) LO ,1"
0 0 EA EA EA EA
0
00
O 0 CO 0 0 0
4 0 0 4 N, CO
4 4 M
OD • CO 0) 00 0 a-
O EA 0 0 0 0
= 2 2
In • CO CO N
CO
< co, °L1._, .2 = -`,
an 03 0 cc
0
co
0
is
0)
0)
6
z
0
c‘i
CD 0 00
4 • 4 1.0
CD CO `OF
• N-
0 0
0 CO CO
o 15 0)
41,
CD N CD CD 4
CO 0 0-0)
CD
• 1• "--
• 10 4
• 0 LO
0) 1,•.
0 0
' 0 4
• 000)
• 0 0 ID
01 0 1..=
0)0)
CO 0 CO 0)
CO 0 LC,
<I' ILO 4
0
0
00
0)
CV 4 0 '0, CO
N- CD 0 a,
co 0 to E. 4
0)
(‚4 0) CD 00 00
00 CO 0 CO 0)
0 0 m ..--
c,. 4 16
E
• E
0
E "
LL1
4-= Z•f,
20-00
8
= E
Lk'
17_ <
1--
5 • E
o F- 2
• + =
0
Ca;
EA EA b-
@.) g •d.,
,t)
-o-
00
0
0.
00
9,
to
0
0
.0
0)
0
0,
0)
(04
00
0-
00
(01
00
1-
0)
00
nsultant Costs
00
tft
gft
0
0
0)
CD CD
0,
• CD CO
0, CV
5050
• h- CP CP
h- 0)104
0 0 1
CD CV
0,
0)00
vt 0 CP 00 0
CNN- CD CP (04
0- CO LC> < 0,
0)0-
4 00 0) 0 • CA
CO 0
CO 0)104 00
CD
• 0 CV
CO a,
O 01" 0
• N,• 0 CV CV
CO 0,
aa
CD CD CD CD • 00
C4 0.- CO
I..= CO OA 0
tri
0
CO 0 c-
0, c -
CA (0
0 0
0,
0 CO
CO
CA 0)
CO
0.0.
O CD CO
• 070
• '4-
(4 CO
CO
CV
0) CD 4
CO •.,r
to co
0.1
0 co 00
N.- 0 CO
4 0 CP
0-10 00
• m
CV
00(0
00 0
10
CO CV
LO CV
0, 0-
0)
LO 0,
CV COD CO
0 0 -
CD
• <f.
CO 0
<I" CD
(0
<1.-
",}.. CV
0 0
<Ir
CO
0) 5-
E46 Na.
0) CO h-
0 CV 0-
(0 CV to
CO CV CO
(‚4 1)0
0: 05. c047
CD
a, 00 00
4 CV 5-
1,- 01 10
CO CO. CV.
(0 0- h..
• CA
GS CV
CO
CO CV h-
o CV 4
0 0
0) I, -
CO CA 0 --
CO CV 0
('4 0') (01
• h -
CO CV CO
LC, CV 4
CV- 03 c.,1
CD <1"
CO
10 (0
CO CV
00
24
00
CO
0
cd
0,
0)
cn
0
Tri
00
O CV N-0 'Cr
CO CO CD <0,
0 0 00 C.-
< h:
0-
0-00
O CV c- CD •,0'' CD
CO 0 0 cct
00 0, CD 0 .d0
1,-.7
1.0
0 0 GA EA 0 CA
O 00(0 CO
14, <
4 CP 00 0- 4
0, 0 0 00 (0 00
f0- EA 0 0 0- 0
• o m 0 to o
0 0 m
M
0) • (0 0., 00 0)
O er4 0 EA
E, 2
E
o o 3
• 12 00E -7)-
h- 00 F-
CC, 00 0
O CP
0 0) 10
tn
to a- to
et. to
cri 4(4
cv
0,00m
01c
E
00)0
8 8' 8
CA CD
O 0
Ch CO
'0
(.4
R. R.
47 0
tit 6.1
0'(50)
+
c) 0
cn
—
001 4 4
00E•
o 0
0.1 mf•
66 66 01.
0
(0
!MATED COS
-J
0
a I—
Rounded to nearest wh
CONFIDENTIAL & PR
Printed: 1712019 12:12 PM