HomeMy WebLinkAboutR-2007-033 Irrigation Systems Design Improvements Agreement with Huibregtse, Louman Associates, Inc. FUNDING RESOLUTION ( incl. rebuild phase 3)RESOLUTION NO. R-2007- 33
A RESOLUTION authorizing the City Manager to execute the attached and incorporated
engineering and consulting services agreement with Huibregtse, Louman
Associates for engineering and consulting services associated with the
design of improvements to the City of Yakima irrigation systems; also
authorizing the execution of other documents related to the design,
contract administration and construction associated with completion of
Phase 3 of the Irrigation System rebuild/refurbishment.
WHEREAS, the City of Yakima Water/Irrigation Division requires engineering,
consulting services and construction associated with Phase 3 of the irrigation System
rebuild/refurbishment of the City of Yakima irrigation systems ; and
WHEREAS, the City of Yakima Water/Irrigation Division representatives have complied
with the provisions of RCW 39.80 which concerns the procurement of engineering and
architectural services by a city; and
WHEREAS, the City of Yakima Water/Irrigation Division representatives will continue to
comply with the provisions of RCW 39.80 which concerns the procurement of engineering and
architectural services by a city for future engineering and architectural services; and
WEREAS, Huibregtse, Louman Associates has the necessary expertise and
experience to perform and provide the required engineering and surveying services and is
willing to do so in accordance with the attached agreement; and
WHEREAS, the City Council deems it to be in the best interest of the City to enter into
an agreement with Huibregtse, Louman Associates for engineering and consulting services
associated with the design of improvements to the City of Yakima irrigation systems; and
WHEREAS, the City Council deems it to be in the best interest of the City to authorize
the City Manager to execute all other documents related to the design, contract administration
and construction associated with the Phase 3 of the Irrigation System rebuild/refurbishment
project; Now, Therefore,
BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF YAKIMA:
The City Manager is hereby authorized and directed to execute the attached and
incorporated engineering and consulting services agreement with Huibregtse, Louman
Associates for engineering and consulting services associated with the design of
improvements to the City of Yakima irrigation systems; together with all other documents
related to the design, contract administration and construction associated with Phase 3 of the
Irrigation System rebuild/refurbishment project.
ADOPTED BY THE CITY COUNCIL this 20th day o March 2007.
ATTEST:
/(c_su6,1)„>)1
Deborah Moore, City Clerk
David Edler, Mayor
A - Z051-33
AGREEMENT
BETWEEN
CITY OF YAKIMA, WASHINGTON
AND
HUIBREGTSE, LOUMAN ASSOCIATES, INC.
FOR PROFESSIONAL SERVICES
THIS AGREEMENT, made and entered into on this 4dday of Arkmcii , 2007, by and
between the City of Yakima, Washington, with principal offices at 129 North Second Street, Yakima, WA
98901, hereinafter referred to as "CITY", and HUIBREGTSE, LOUMAN ASSOCIATES, INC., 801 North
39th Avenue, Yakima, WA 98902 and which corporation and its principal engineers performing this
Agreement are licensed and registered to do business in the State of Washington, hereinafter referred to
as "ENGINEER," for PHASE 3 - 308 IRRIGATION PIPELINE REPLACEMENT PROJECT (approximately
34,000 linear feet of pipeline replacement) Design Services, herein called the "PROJECT."
WITNESSETH:
RECITALS
WHEREAS, CITY desires to retain the ENGINEER to provide engineering services for design and
construction of PHASE 3 - 308 IRRIGATION PIPELINE REPLACEMENT PROJECT, as described in this
Agreement and subsequent Amendments thereto; and
WHEREAS, ENGINEER represents that it has available and offers to provide personnel with
expertise and experience necessary to satisfactorily accomplish the work within the required time and that
it has no conflicts of interest prohibited by law from entering into this Agreement;
NOW, THEREFORE, CITY and ENGINEER agree as follows:
SECTION 1 INCORPORATION OF RECITALS
1.1 The above recitals are incorporated into these operative provisions of the Agreement.
SECTION 2 SCOPE OF SERVICES
2.0.1 ENGINEER agrees to perform those services described hereafter. Unless modified in
writing by both parties, duties of ENGINEER shall not be construed to exceed those
services specifically set forth herein.
2.0.2 ENGINEER shall use its best efforts to maintain continuity in personnel and shall assign
Michael T. Battle, PE, as Project Manager and Principal -in -Charge throughout the term of
this Agreement unless other personnel are approved by the CITY.
2.1 Basic Services: ENGINEER agrees to perform those tasks described in Exhibit A, entitled "CITY
OF YAKIMA - PHASE 3 - 308 IRRIGATION PIPELINE REPLACEMENT PROJECT" (WORK)
which is part of this Agreement as if fully set forth herein.
2.2 Additional Services: CITY and ENGINEER agree that not all WORK to be performed by
ENGINEER can be defined in detail at the time this Agreement is executed, and that additional
WORK related to the Project and not covered in Exhibit A may be needed during performance of
this Agreement. CITY may, at any time, by written order, direct the ENGINEER to revise portions
of the PROJECT WORK previously completed in a satisfactory manner, delete portions of the
PROJECT, or request that the ENGINEER perform additional WORK beyond the scope of the
PROJECT WORK. Such changes hereinafter shall be referred to as "Additional Services."
2.2.1 If such Additional Services cause an increase or decrease in the ENGINEER'S cost of, or
time required for, performance of any services under this Agreement, a contract price
G:\PROJECTS\2004\04056\PROFESSIONAL SERVICES AGREEMENT.doc
Page 1
and/or completion time adjustment pursuant to this Agreement shall be made and this
Agreement shall be modified in writing accordingly.
2.2.2 Compensation for each such request for Additional Services will be negotiated by the
CITY and the ENGINEER according to the provisions set forth in Exhibit B and, if so
authorized, shall be considered part of the PROJECT WORK. The ENGINEER shall not
perform any Additional Services until so authorized by CITY and agreed to by the
ENGINEER in writing.
2.3 The ENGINEER must assert any claim for adjustment in writing within thirty (30) days from the
date of receipt by the ENGINEER of the written notification of change or of providing services
related to an asserted change, whichever is earliest.
SECTION 3 CITY'S RESPONSIBILITIES
3.1 CITY -FURNISHED DATA: The CITY will provide to the ENGINEER all technical data in the
CITY'S possession relating to the ENGINEER'S services on the PROJECT including information
on any pre-existing conditions known to the CITY that constitute hazardous waste contamination
on the PROJECT site as determined by an authorized regulatory agency.
3.2 ACCESS TO FACILITIES AND PROPERTY: The CITY will make its facilities reasonably
accessible to ENGINEER as required for ENGINEER'S performance of its services and will
provide labor and safety equipment as reasonably required by ENGINEER for such access.
3.3 TIMELY REVIEW: The CITY will examine the ENGINEER'S studies, reports, sketches, drawings,
specifications, proposals, and other documents; obtain advice of an attorney, insurance
counselor, accountant, auditor, bond and financial advisors, and other consultants as CITY
deems appropriate; and render in writing decisions required of CITY in a timely manner. Such
examinations and decisions, however, shall not relieve the ENGINEER of any contractual
obligations nor of its duty to render professional services meeting the standards of care for its
profession.
3.4 CITY shall appoint a CITY'S Representative with respect to WORK to be performed under this
Agreement. CITY'S Representative shall have complete authority to transmit instructions and
receive information. ENGINEER shall be entitled to reasonably rely on such instructions made by
the CITY'S Representative unless otherwise directed in writing by the CITY, but ENGINEER shall
be responsible for bringing to the attention of the CITY'S Representative any instructions which
the ENGINEER believes are inadequate, incomplete, or inaccurate based upon the ENGINEER'S
knowledge.
3.5 Any documents, services, and reports provided by the CITY to the ENGINEER are available
solely as additional information to the ENGINEER and will not relieve the ENGINEER of its duties
and obligations under this Agreement or at law. The ENGINEER shall be entitled to reasonably
rely upon the accuracy and the completeness of such documents, services and reports, but shall
be responsible for exercising customary professional care in using and reviewing such
documents, services, and reports and drawing conclusions therefrom.
SECTION 4 AUTHORIZATION, PROGRESS, AND COMPLETION
4.1 In signing this Agreement, CITY grants ENGINEER specific authorization to proceed with WORK
described in Exhibit A. The time for completion is defined in Exhibit A, or as amended.
SECTION 5 COMPENSATION
5.1 COMPENSATION ON A TIME SPENT BASIS AT SPECIFIC HOURLY RATES: For the services
described in Exhibit A, compensation shall be according to Exhibit C - Schedule of Specific
Hourly Rates on a time spent basis plus reimbursement for direct non -salary expenses.
5.1.1 DIRECT NON -SALARY EXPENSES: Direct Non -Salary Expenses are those costs
incurred on or directly for the PROJECT including, but not limited to, necessary
G'\PROJECTS\2004\04056\PROFESSIONAL SERVICES AGREEMENT.doc
Page 2
transportation costs, including current rates for ENGINEER'S vehicles; meals and
lodging; laboratory tests and analyses; printing, binding and reproduction charges; all
costs associated with other outside nonprofessional services and facilities; special CITY -
requested and PROJECT -related insurance and performance warranty costs; and other
similar costs. Reimbursement for Direct Non -Salary Expenses will be on the basis of
actual charges when furnished by commercial sources and on the basis of current rates
when furnished by ENGINEER. Estimated Direct Non -Salary Expenses are shown in
Exhibit B.
5.1.1.1 Travel costs, including transportation, lodging, subsistence, and incidental
expenses incurred by employees of the ENGINEER and each of the
Subconsultants in connection with PROJECT WORK; provided, as follows:
• That a maximum of U.S. INTERNAL REVENUE SERVICE allowed cents
per mile will be paid for the operation, maintenance, and depreciation
costs of company or individually owned vehicles for that portion of time
they are used for PROJECT WORK. ENGINEER, whenever possible,
will use the least expensive form of ground transportation.
• That reimbursement for meals inclusive of tips shall not exceed a
maximum of $40 per day per person This rate may be adjusted on a
yearly basis.
• That accommodation shall be at a reasonably priced hotel/motel.
• That air travel shall be by coach class, and shall be used only when
absolutely necessary.
5.1.2 Telephone charges, computer charges, in-house reproduction charges, first class
postage, and FAX charges are not included in the direct expense costs, but are
considered included in the Schedule of Specific Hourly Billing Rates.
5.1.3 Professional Subconsultants. Professional Subconsultants are those costs for
engineering, architecture, geotechnical services and similar professional services
approved by the CITY. Reimbursement for Professional Subconsultants will be on the
basis of 1.10 times the actual costs billed by the Professional Subconsultant for services
provided to the CITY through this Agreement. Estimated Subconsultant costs are shown
in Exhibit B.
5.2 Unless specifically authorized in writing by the CITY, the total budgetary amount for this
PROJECT shall not exceed that amount set forth in Exhibit B. The ENGINEER will make
reasonable efforts to complete the WORK within the budget and will keep CITY informed of
progress toward that end so that the budget or WORK effort can be adjusted if found necessary.
The ENGINEER is not obligated to incur costs beyond the indicated budget, as may be adjusted,
nor is the CITY obligated to pay the ENGINEER beyond these limits. When any budget has been
increased, the ENGINEER'S excess costs expended prior to such increase will be allowable to
the same extent as if such costs had been incurred after the approved increase, and provided
that the City was informed in writing at the time such costs were incurred.
5.3 The ENGINEER will use its best efforts to submit to the City's Representative by the 10th day of
each calendar month an invoice for payment for PROJECT services completed through the
accounting cut-off day of the previous month. Such invoices shall be for PROJECT services and
WORK performed and costs incurred prior to the date of the invoice and not covered by
previously submitted invoices. The ENGINEER shall submit with each invoice a summary of time
expended on the PROJECT for the current billing period, copies of subconsultant invoices, and
any other supporting materials determined by the City necessary to substantiate the costs
incurred. CITY will use its best efforts to pay such invoices within thirty (30) days of receipt and
upon approval of the WORK done and amount billed. CITY will notify the ENGINEER promptly if
any problems are noted with the invoice. CITY may question any item in an invoice, noting to
ENGINEER the questionable item(s) and withholding payment for such item(s). The ENGINEER
may resubmit such item(s) in a subsequent invoice together with additional supporting information
required.
G:\PROJECTS\2004\04056\PROFESSIONAL SERVICES AGREEMENT.doc
Page 3
5.4 If payment is not made within sixty (60) days following receipt of approved invoices, interest on
the unpaid balance shall accrue beginning with the sixty-first (61) day at the rate of 1.0% per
month or the maximum interest rate permitted by law, whichever is less; provided, however, that
no interest shall accrue pursuant to Chapter 39.76 RCW when before the date of timely payment
a notice of dispute is issued in good faith by the CITY to the ENGINEER pursuant to the terms of
RCW 39.76.020(4).
5.5 Final payment of any balance due the ENGINEER for PROJECT services will be made within
forty-five (45) days after satisfactory completion of the services required by this Agreement as
evidenced by written acceptance by CITY and after such audit or verification as CITY may deem
necessary and execution and delivery by the ENGINEER of a release of all known claims against
CITY arising under or by virtue of this Agreement, other than such claims, if any, as may be
specifically exempted by the ENGINEER from the operation of the release in stated amounts to
be set forth therein.
5.6 Payment for any PROJECT services and WORK shall not constitute a waiver or release by CITY
of any claims, right, or remedy it may have against the ENGINEER under this Agreement or by
law, nor shall such payment constitute a waiver, remission, or discharge by CITY of any failure or
fault of the ENGINEER to satisfactorily perform the PROJECT WORK as required under this
Agreement.
SECTION 6 RESPONSIBILITY OF ENGINEER
6.1 The ENGINEER shall be responsible for the professional quality, technical adequacy and
accuracy, timely completion, and the coordination of all plans, design, drawings, specifications,
reports, and other services furnished by the ENGINEER under this Agreement. The ENGINEER
shall, without additional compensation, correct or review any errors, omissions, or other
deficiencies in its plans, designs, drawings, specifications, reports, and other services. The
ENGINEER shall perform its WORK according to generally accepted civil engineering standards
of care and consistent with achieving the PROJECT WORK within budget, on time, and in
compliance with applicable laws, regulations, and permits.
6.2 CITY'S review or approval of, or payment for, any plans, drawings, designs, specifications,
reports, and incidental WORK or services furnished hereunder shall not in any way relieve the
ENGINEER of responsibility for the technical adequacy, completeness, or accuracy of its WORK
and the PROJECT WORK. CITY'S review, approval, or payment for any of the services shall not
be construed to operate as a waiver of any rights under this Agreement or at law or any cause of
action arising out of the performance of this Agreement.
6.3 In performing WORK and services hereunder, the ENGINEER and its subcontractors,
subconsultants, employees, agents, and representatives shall be acting as independent
contractors and shall not be deemed or construed to be employees or agents of CITY in any
manner whatsoever. The ENGINEER shall not hold itself out as, nor claim to be, an officer or
employee of CITY by reason hereof and will not make any claim, demand, or application to or for
any right or privilege applicable to an officer or employee of CITY. The ENGINEER shall be
solely responsible for any claims for wages or compensation by ENGINEER employees, agents,
and representatives, including subconsultants and subcontractors, and shall save and hold CITY
harmless therefrom.
6.4 INDEMNIFICATION:
(a) ENGINEER agrees to indemnify, defend, and hold the CITY harmless from loss, cost, or
expense, including legal fees, of any kind claimed by third parties, including without
limitation such loss, cost, or expense resulting from injuries to persons or damages to
property, caused solely by the negligence or willful misconduct of the ENGINEER, its
employees, officers, and subconsultants in connection with the PROJECT. In the event
that any lien is placed upon the property of the CITY or any of the CITY'S officers,
employees, or agents as a result of the negligence or willful misconduct of the
G.\PROJECTS\2004\04056\PROFESSIONAL SERVICES AGREEMENT.doc
Page 4
ENGINEER, the ENGINEER shall at once cause the same to be dissolved and
discharged by giving bond or otherwise.
(b) CITY agrees to indemnify, defend, and hold the ENGINEER harmless from loss, cost, or
expense, including legal fees, of any kind claimed by third parties, including without
limitation such loss, cost, or expense resulting from injuries to persons or damages to
property, caused solely by the negligence or willful misconduct of the CITY, its
employees, or agents in connection with the PROJECT.
(c) If the negligence or willful misconduct of both the ENGINEER and the CITY (or a person
identified above for whom each is liable) is a cause of such third party claim, the loss,
cost, or expense shall be shared between the ENGINEER and the CITY in proportion to
their relative degrees of negligence or willful misconduct and the right of indemnity will
apply for such proportion.
6.5 In any and all claims by an employee of the ENGINEER, any subcontractor, anyone directly or
indirectly employed by any of them, or anyone for whose acts any of them may be liable, the
indemnification obligations under this Agreement shall not be limited in any way by any limitation
on the amount or types of damages, compensation, or benefits payable by or for the ENGINEER
or a subcontractor under workers' or workmens' compensation acts, disability benefit acts, or
other employee benefit acts. The ENGINEER waives its immunity under the Industrial Insurance
Act, Title 51, RCW. Such waiver has been mutually negotiated by the ENGINEER and the CITY
as evidenced by their specific and express initialing of this paragrap
ENGINEER'S INITIALS
CITY'S INITIALS
6.6 It is understood that any resident engineering or inspection provided by ENGINEER is for the
purpose of determining compliance with the technical provisions of PROJECT specifications and
does not constitute any form of guarantee or insurance with respect to the performance of a
contractor. ENGINEER does not assume responsibility for methods or appliances used by a
contractor, for the safety of construction work, or for compliance by contractors with laws and
regulations. CITY shall use its best efforts to ensure that the construction contract requires that
the contractor(s) indemnify and name CITY, the CITY'S and the ENGINEER'S officers, principals,
employees, agents, representatives, and engineers as additional insureds on contractor's
insurance policies covering PROJECT, exclusive of insurance for ENGINEER professional
liability.
6.7 SUBSURFACE INVESTIGATIONS: In soils, foundation, groundwater, and other subsurface
investigations, the actual characteristics may vary significantly between successive test points
and sample intervals and at locations other than where observation, exploration, and
investigations have been made. Because of the inherent uncertainties in subsurface evaluations,
changed or unanticipated underground conditions may occur that could affect total PROJECT
cost and/or execution. These conditions and cost/execution effects are not the responsibility of
the ENGINEER, to the extent that ENGINEER has exercised the applicable standard of
professional care and judgment in such investigations.
SECTION 7 PROJECT SCHEDULE AND BUDGET
7.1 The general PROJECT schedule and the budget for both the entire PROJECT and its component
tasks shall be as set forth in this Agreement and attachments. The project schedule and
performance dates for the individual tasks shall be mutually agreed to by the CITY and the
ENGINEER within fifteen (15) days after execution of this Agreement. The performance dates
and budgets for tasks may be modified only upon written agreement of the parties hereto. The
performance date for tasks and the completion date for the entire PROJECT shall not be
extended, nor the budget increased because of any unwarranted delays attributable to the
ENGINEER, but may be extended or increased by the CITY in the event of a delay caused by
special services requested by the CITY or because of unavoidable delay caused by any
governmental action or other conditions beyond the control of the ENGINEER which could not be
reasonably anticipated.
G:\PROJECTS\2004\04056\PROFESSIONAL SERVICES AGREEMENT.doc
Page 5
7.2 Not later than the tenth day of each calendar month during the performance of the PROJECT, the
ENGINEER shall submit to the CITY'S Representative a copy of the current schedule and a
written narrative description of the WORK accomplished by the ENGINEER and subconsultants
on each task, indicating a good faith estimate of the percentage completion thereof on the last
day of the previous month. Additional oral or written reports shall be prepared at the request of
the CITY for presentation to other governmental agencies and/or to the public.
SECTION 8 REUSE OF DOCUMENTS
8.1 All internal WORK products of the ENGINEER are instruments or service of this PROJECT.
There shall be no reuse, change, or alteration by the CITY or others acting through or on behalf
of the CITY without written permission of the ENGINEER, which shall not be unreasonably
withheld and will be at the CITY's sole risk. The CITY agrees to indemnify the ENGINEER and its
officers, employees, subcontractors, and affiliated corporations from all claims, damages, losses,
and costs including, but not limited to, litigation expenses and attorneys fees arising out of or
related to such unauthorized reuse, change, or alteration; provided, however, that the ENGINEER
will not be indemnified for such claims, damages, losses, and costs including, without limitation,
litigation expenses and attorney fees where caused by the ENGINEER's own acts or omissions.
8.2 The ENGINEER agrees that ownership of any plans, drawings, designs, specifications, computer
programs, technical reports, operating manuals, calculations, notes, and other WORK submitted
or which are specified to be delivered under this Agreement or which are developed or produced
and paid for under this Agreement, whether or not complete, shall be vested in the CITY.
SECTION 9 AUDIT AND ACCESS TO RECORDS
9.1 The ENGINEER, including its subconsultants, shall maintain books, records, documents and
other evidence directly pertinent to performance of the WORK under this Agreement in
accordance with generally accepted accounting principles and practices consistently applied.
The CITY or the CITY'S duly authorized representative, shall have access to such books,
records, documents, and other evidence for inspection, audit, and copying for a period of three
years after completion of the PROJECT. The CITY shall also have access to such books,
records, and documents during the performance of the PROJECT WORK, if deemed necessary
by the CITY, to verify the ENGINEER'S WORK and invoices.
9.2 Audits conducted pursuant to this section shall be in accordance with generally accepted auditing
standards and established procedures and guidelines of the reviewing or auditing agency.
9.3 The ENGINEER agrees to the disclosure of all information and reports resulting from access to
records pursuant to this section provided that the ENGINEER is afforded the opportunity for an
audit exit conference and an opportunity to comment and submit any supporting documentation
on the pertinent portions of the draft audit report and that the final audit report will include written
comments, if any, of the ENGINEER.
9.4 The ENGINEER shall ensure, that substantially, the foregoing paragraphs are included in each
subcontract for WORK on the Project.
9.5 Any charges of the ENGINEER paid by the CITY which are found by an audit to be inadequately
substantiated shall be reimbursed to the CITY.
SECTION 10 INSURANCE
10.1 Prior to beginning WORK under this Agreement, the ENGINEER shall provide Certificates of
Insurance satisfactory to the CITY as evidence that policies providing the following coverage and
limits of insurance are in full force and effect. The CITY and the CITY'S officers, principals,
employees, representatives, and agents shall be designated as additional insured on all such
policies except for professional liability and Worker's Compensation. Such insurance shall be
primary to the extent covered as additional insureds and other insurance maintained or carried by
the CITY shall be separate and distinct and shall not be contributing with the insurance listed
hereunder.
G \PROJECTS\2004\04056\PROFESSIONAL SERVICES AGREEMENT doc
Page 6
10.1.1 Comprehensive general liability insurance, including personal injury liability, blanket
contractual liability, and broad -form property damage liability coverage. The combined
single limit for bodily injury and property damage shall be not less than $1,000,000 per
occurrence.
10.1.2. Automobile bodily injury and property damage liability insurance covering owned, non -
owned, rented, and hired cars. The combined single limit for bodily injury and property
damage shall be not less than $1,000,000 per occurrence.
10.1.3. Statutory workers' compensation and employer's liability insurance as required by state
law.
10.1.4. Professional liability insurance. The limit of liability shall be not less than 1,000,000.
Failure of either or all of the additional insureds to report a claim under such insurance
shall not prejudice the rights of the CITY, its officers, employees, agents, and
representatives thereunder. The CITY and the CITY'S officers, principals, employees,
representatives, and agents shall have no obligation for payment of premiums because
of being named as additional insureds under such insurance. None of the policies
issued pursuant to the requirements contained herein shall be canceled, allowed to
expire, or changed in any manner so as to affect the rights of the City thereunder until
thirty (30) days after written notice to the CITY of such intended cancellation,
expiration, or change.
SECTION 11 SUBCONTRACTS
11.1 ENGINEER shall be entitled, to the extent determined appropriate by ENGINEER, to subcontract
any portion of the WORK to be performed under this Agreement.
11.2 Any subconsultants or subcontractors to the ENGINEER utilized on this PROJECT, including any
substitutions thereof, will be subject to prior approval by CITY, which approval shall not be
unreasonably withheld. Each subcontract shall be subject to review by the CITY'S
Representative, if requested, prior to the subconsultant or subcontractor proceeding with the
WORK. Such review shall not constitute an approval as to the legal form or content of such
subcontract. The ENGINEER shall be responsible for the architectural and engineering
performance, acts, and omissions of all persons and firms performing subcontract WORK.
11.3 CITY hereby authorizes the ENGINEER to subcontract with the persons and firms listed below:
None anticipated.
11.4 The ENGINEER shall submit, along with its monthly invoices, a description of all WORK
completed by subconsultants and subcontractors during the preceding month and copies of all
invoices thereto.
SECTION 12 ASSIGNMENT
12.1 This Agreement is binding on the heirs, successors and assigns of the parties hereto. This
Agreement may not be assigned by CITY or ENGINEER without prior written consent of the
other, which consent will not be unreasonably withheld.
SECTION 13 INTEGRATION
13.1 This Agreement represents the entire understanding of CITY and ENGINEER as to those matters
contained herein. No prior oral or written understanding shall be of any force or effect with
respect to those matters covered herein. This Agreement may not be modified or altered except
in writing signed by both parties.
G:\PROJECTS\2004\04056\PROFESSIONAL SERVICES AGREEMENT.doc
Page 7
SECTION 14 JURISDICTION AND VENUE
14.1 This Agreement shall be administered and interpreted under the laws of the State of Washington.
Jurisdiction of litigation arising from this Agreement shall be in that state. If any part of this
Agreement is found to conflict with applicable laws, such part shall be inoperative, null, and void
insofar as it conflicts with said laws, but the remainder of this Agreement shall be in full force and
effect. Venue of all disputes shall be Yakima County, State of Washington.
SECTION 15 EQUAL EMPLOYMENT and NONDISCRIMINATION
15.1 In connection with the Services under this Agreement, ENGINEER agrees to comply with the
applicable provisions of State and Federal Equal Employment Opportunity and Nondiscrimination
statutes and regulations.
SECTION 16 SUSPENSION OF WORK
16.1 CITY may suspend, in writing by certified mail, all or a portion of the WORK under this Agreement
if unforeseen circumstances beyond CITY'S control are interfering with normal progress of the
WORK. ENGINEER may suspend, in writing by certified mail, all or a portion of the WORK under
this Agreement if unforeseen circumstances beyond ENGINEER's control are interfering with
normal progress of the WORK. ENGINEER may suspend WORK on PROJECT in the event
CITY does not pay invoices when due, except where otherwise provided by this Agreement. The
time for completion of the WORK shall be extended by the number of days WORK is suspended.
If the period of suspension exceeds ninety (90) days, the terms of this Agreement are subject to
renegotiation, and both parties are granted the option to terminate WORK on the suspended
portion of Project in accordance with SECTION 17.
SECTION 17 TERMINATION OF WORK
17.1 Either party may terminate this Agreement, in whole or in part, if the other party materially
breaches its obligations under this Agreement and is in default through no fault of the terminating
party. However, no such termination may be effected unless the other party is given: (1) not less
than fifteen (15) calendar days written notice delivered by certified mail, return receipt requested,
of intent to terminate; and (2) an opportunity for consultation and. for cure with the terminating
party before termination. Notice shall be considered issued within seventy-two (72) hours of
mailing by certified mail to the place of business of either party as set forth in this Agreement.
17.2 In addition to termination under subparagraph A of this Section, CITY may terminate this
Agreement for its convenience, in whole or in part, provided the ENGINEER is given: (1) not less
than fifteen (15) calendar days written notice delivered by certified mail, return receipt requested,
of intent to terminate; and (2) an opportunity for consultation with CITY before termination.
17.3 If CITY terminates for default on the part of the ENGINEER, an adjustment in the contract price
pursuant to the Agreement shall be made, but (1) no amount shall be allowed for anticipated
profit on unperformed services or other WORK, and (2) any payment due to the ENGINEER at
the time of termination may be adjusted to the extent of any additional costs or damages CITY
has incurred, or is likely to incur, because of the ENGINEER'S breach. In such event, CITY shall
consider the amount of WORK originally required which was satisfactorily completed to date of
termination, whether that WORK is in a form or of a type which is usable and suitable to CITY at
the date of termination and the cost to CITY of completing the WORK itself or of employing
another firm to complete it. Under no circumstances shall payments made under this provision
exceed the contract price. In the event of default, the ENGINEER agrees to pay CITY for any
and all damages, costs, and expenses whether directly, indirectly, or consequentially caused by
said default. This provision shall not preclude CITY from filing claims and/or commencing
litigation to secure compensation for damages incurred beyond that covered by contract
retainage or other withheld payments.
17.4 If the ENGINEER terminates for default on the part of CITY or if CITY terminates for convenience,
the adjustment pursuant to the Agreement shall include payment for services satisfactorily
performed to the date of termination, in addition to termination settlement costs the ENGINEER
G:\PROJECTS\2004\04056\PROFESSIONAL SERVICES AGREEMENT.doc
Page 8
reasonably incurs relating to commitments which had become firm before the termination, unless
CITY determines to assume said commitments.
17.5 Upon receipt of a termination notice under subsections 17.1 or 17.2 above, the ENGINEER shall
(1) promptly discontinue all services affected (unless the notice directs otherwise), and (2) deliver
or otherwise make available to CITY all originals of data, drawings, specifications, calculations,
reports, estimates, summaries, and such other information, documents, and materials as the
ENGINEER or its subconsultants may have accumulated or prepared in performing this
Agreement, whether completed or in progress, with the ENGINEER retaining copies of the same.
17.6 Upon termination under any subparagraph above, CITY reserves the right to prosecute the
WORK to completion utilizing other qualified firms or individuals; provided, the ENGINEER shall
have no responsibility to prosecute further WORK thereon.
17.7 If, after termination for failure of the ENGINEER to fulfill contractual obligations, it is determined
that the ENGINEER has not so failed, the termination shall be deemed to have been effected for
the convenience of CITY. In such event, the adjustment pursuant to the Agreement shall be
determined as set forth in subparagraph 17.4 of this Section.
17.8 If, because of death, unavailability or any other occurrence, it becomes impossible for any key
personnel employed by the ENGINEER in PROJECT WORK or for any corporate officer of the
ENGINEER to render his services to the PROJECT, the ENGINEER shall not be relieved of its
obligations to complete performance under this Agreement without the concurrence and written
approval of CITY. If CITY agrees to termination of this Agreement under this provision, payment
shall be made as set forth in subparagraph 17.3 of this Section.
SECTION 18 ARBITRATION
18.1 All claims, counterclaims, disputes, and other matters in question arising out of, or relating to, this
AGREEMENT or the breach thereof may be decided by arbitration in accordance with the
Construction Industry Arbitration Rules of the American Arbitration Association then obtaining.
Either CITY or ENGINEER may initiate a request for such arbitration, but consent of the other
party to such arbitration shall be a necessary precondition to arbitration.
SECTION 19 NOTICE
19.1 Any notice required to be given under the terms of this Agreement shall be directed to the party at
the address set forth below. Notice shall be considered issued and effective upon receipt thereof
by the addressee -party, or seventy-two hours after mailing by certified mail to the place of
business set forth below, whichever is earlier.
CITY: City of Yakima
2301 Fruitvale Boulevard
Yakima, WA 98902
Attn: Mr. David Brown, Water and Irrigation Manager
ENGINEER: HUIBREGTSE, LOUMAN ASSOCIATES, INC.
801 North 39th Avenue
Yakima, WA 98902
Attn: Jeffrey T. Louman, PE, President
IN WITNESS WHEREOF, the parties hereto have caused this agreement to be executed by their
respective authorized officers or representatives as of the day and year first above written.
G:\PROJECTS\2004\04056\PROFESSIONAL SERVICES AGREEMENT.doc
Page 9
CITY OF YAKIMA
Signature
Printed Name: R.A. Zais, Jr.
Title: City Manager
Date:
Attest
G'\PROJECTS \2004\04056\PROFESSIONAL SERVICES AGREEMENT.doc
HUIBREGTSE, LOUMAN ASSOCIATES, INC.
Printed Name: Jeffrey T. Louman
Title: President
Date: .3/8/0 `7
Page 10
STATE OF WASHINGTON
) ss.
COUNTY OF YAKIMA )
I certify that I know or have satisfactory evidence that R.A. ZAIS, JR. is the person who appeared before
me, and said person acknowledged that he signed this instrument, on oath stated that he was authorized
to execute the instrument, and acknowledged it as the CITY MANAGER of the CITY OF YAKIMA, to be
the free and voluntary act of such party for the uses and purposes mentioned in the instrument.
Dated: X3/2 2/V
Seal or Stamp
G:\PROJECTS\2004\04056\PROFESSIONAL SERVICES AGREEMENT.doc
74/ -
(Si ature)
,a2,/puly y e/'W(- /0.4 7A4
Title
Printed Name
My commission expires: ..5-/S- 20/0
Page 11
STATE OF WASHINGTON
) ss.
COUNTY OF YAKIMA
I certify that I know or have satisfactory evidence that JEFFREY T. LOUMAN, PE, is the person who
appeared before me, and said person acknowledged that he/she signed this instrument, on oath stated
that he/she was authorized to execute the instrument, and acknowledged it as the President of
Huibregtse, Louman Associates, Inc. to be the free and voluntary act of such party for the uses and
purposes mentioned in the instrument.
Dated:
`J12ar�+ h B / 2.007
Seal or Stamp
G:\PROJECTS\2004\04056\PROFESSIONAL SERVICES AGREEMENT.doc
igrature)
No -k -a 3b10
Title
ebe-e.ca, l4 . IA a 4--av,
Printed Name
My commission expires:3/ta f bi
Page 12
EXHIBIT A
CITY OF YAKIMA - PHASE 3 - 308 IRRIGATION PIPELINE REPLACEMENT PROJECT
SCOPE OF WORK
During the term of this AGREEMENT, the ENGINEER shall perform professional services in connection
with the following project:
City of Yakima Phase 3 - 308 Irrigation Pipeline Replacement Project
This scope of work shall include the furnishing of all services, labor, materials, equipment, supplies, and
incidentals necessary to conduct and complete the work as indicated hereinafter. The work to be
performed involves design engineering, preparation of plans, specifications, and estimates for up to three
(3) stages of work as shown on Exhibit D.
1. PROJECT MANAGEMENT
A. Project Management. The project manager will coordinate ENGINEER's design team to
ensure that the work is completed on schedule, is technically competent, and meets the
CITY's needs. The project manager will provide overall project management for
ENGINEER's work elements.
B. Project Meetings. Attend up to three (3) project meetings in Yakima with CITY Staff to
coordinate the design aspects of the project with the CITY.
C. Public Meetings. Attend up to three (3) public meetings in support of the CITY to
address technical aspects of the work related to final design and preparation of plans and
specifications for the Project.
2. DESIGN AND FINAL PLANS AND SPECIFICATIONS
A. Perform field investigations and field surveying necessary to supplement existing pre -
design data for the design of the identified improvements.
B. Perform the preliminary design and present preliminary plans to the CITY prior to
detailing final Plans.
C. On the basis of approved preliminary plans, perform the final design and prepare
complete Plans and Specifications for bid call on the proposed work, as authorized by the
CITY. It is anticipated that only plan view and details will be prepared and no vertical
views or profiles are included.
D. Furnish the CITY thirty (30) copies of the final Plans and Specifications for bidding and
construction. It is anticipated the Engineer will prepare up to three (3) complete sets of
plans and specifications for this Phase 3 - 308 Irrigation Pipelihe Replacement Project
with each set of plans and specifications ready for bidding in Fall 2007, Fall 2008, and
Fall 2009.
E. Furnish to the CITY engineering data for and assist in the preparation of the required
documents so that the CITY may secure approval of such governmental authorities as
have jurisdiction over design criteria applicable to the Project.
F. Answer and supply such information as is requested by prospective bidders.
G. Prepare and issue addenda, if necessary.
H. Prepare the Engineer's Estimate of construction cost.
I. Attend bid opening and participate in the bid opening and evaluation process.
G:\PROJECTS\2004\04056\PROFESSIONAL SERVICES AGREEMENT doc
Page 13
J. Prepare tabulation of all bids received by the CITY and review bidder's qualifications.
K. Make recommendation of construction contract award to the lowest responsible bidder.
The following professional services work for this project (SERVICES DURING CONSTRUCTION) is
provided for information only at this time. The scope and cost of SERVICES DURING CONSTRUCTION
professional services are intended to be negotiated and incorporated into this agreement by
supplement/addendum at a later date with the mutual agreement of CITY and ENGINEER:
3. SERVICES DURING CONSTRUCTION
A. Furnish the field survey crew necessary to set horizontal and vertical control for the
improvements authorized for construction.
B. Furnish a qualified resident engineer who shall make construction observations and be
on the job at all times that significant work is in progress, whose duty shall be to provide
surveillance of project construction for substantial compliance with Plans and
Specifications.
C. Prepare progress reports on the Project and file same with the CITY and provide monthly
progress estimates to the CITY.
D. Consult and advise the CITY during construction and make a final report of the
completed work.
E. Monitor the construction contractor's compliance with State labor standards.
F. Review Contractor's submission of samples and shop drawings, where applicable.
G. Recommend progress payments for the construction contractor to the CITY.
H. Prepare and submit proposed contract change orders when applicable.
Prepare and furnish reproducible record drawings of all completed work from as -built
drawings furnished by the CITY's construction contractor.
G:\PROJECTS\2004\04056\PROFESSIONAL SERVICES AGREEMENT.doc
Page 14
EXHIBIT B
PHASE 3 - 308 IRRIGATION PIPELINE REPLACEMENT PROJECT
Professional Fees
Compensation for professional services will be on a time spent basis at the specific hourly rates shown on
Exhibit C, plus reimbursement for direct non -salary expenses.
The following spreadsheet shows the estimated time and expenses to perform design engineering, plans,
specifications, and estimate for this Phase 3 - 308 Irrigation Pipeline Replacement Project work. The
maximum amount of compensation to the ENGINEER for this work will be $260,150.00. This maximum
amount will not be exceeded without the written agreement of the CITY and the ENGINEER.
PROJECT TITLE: PHASE 3 - 308 IRRIGATION PIPELINE REPLACEMENT PROJECT (3 STAGES)
CLIENT: CITY OF YAKIMA
JOB NUMBER: 07--- Huibregtse, Louman Associates, Inc.
DATE: March 1, 2007
ENGINEER'S HOURLY ESTIMATE
TASK
NO
PROJECT TASK
Licensed
Principal
Engineer
Project
Engineer
Principal
Land
Surveyor
TechnicianD
2 -Man
Survey
Party
Word
Processing
Technician
TOTAL
HRS
TASK
DIRECT
COSTS
$136
$94
$126
$82
$150
$55
1
PROJECT MANAGEMENT
A
Project Management
60
180
0
0
0
48
288
27,720.00
B
Project:Meetings
24
36
0
8
0
18
86
8,294.00
C
Public Meetings
18
24
0
12
0
12
66
6,348.00
2
DESIGN AND FINAL PLANS, SPECIFICATIONS, & ESTIMATE
A
Field investigations and field
surveying
24
80
36
64
240
0
444
56,568.00
B
Perform the preliminary design
40
240
12
480
12
24
808
71,992.00
C
In-house project review, quality
control
12
24
8
8
0
6
58
5,882.00
D
Incorporate Agency Review
comments
6
48
0
80
0
6
140
12,218.00
E
Final design, Plans, and
Specifications
24
144
8
280
8
16
480
42,848.00
F
Furnish copies of Plans and
Specifications
2
8
0
0
0
12
22
1,684.00
G
Furnish engineering data for
approvals
6
18
0
0
0
6
30
2,838.00
H
Answer bidders questions
6
18
0
0
0
0
24
2,508.00
I
Prepare and issue addenda
4
18
0
16
0
12
50
4,208.00
J
Prepare Estimate of construc-
tion cost
4
18
0
16
0
4
42
3,768.00
K
Attend bid opening
4
12
0
0
0
0
16
1,672.00
L
Prepare tabulation of bids
2
8
0
0
0
8
18
1,464.00
M
Make recommendation of
construction contract award
4
6
0
0
0
6
16
1,438.00
Labor Subtotal
240
882
64
964
260
178
2,588
$251,450.00
G:\PROJECTS\2004\04056\PROFESSIONAL SERVICES AGREEMENT.doc
Page 15
PROJECT TITLE: PHASE 3 - 308 IRRIGATION PIPELINE REPLACEMENT PROJECT (3 STAGES)
CLIENT: CITY OF YAKIMA
EXPENSES:
hours
$/hr
Computers:
0.00
Travel:
Cost/
Unit
Air Trips
Ground
Trp.
Days
Trip
Miles
Air Travel
$0.00
0.00
Mileage
$0.34
0.00
Meals/Lodging
$0.00
0.00
Misc. expenses:
ADVERTISEMENT
$4,500.00
FAX
00.00
TELEPHONE
100.00
POSTAGE
100.00
OUTSIDE PRINTING
$4,000.00
SUB -CONSULTANTS:
1. NONE ANTICIPATED
x 1.1
0.00
Subtotal - Labor
$251,450.00
Subtotal - Expenses
$8,700.00
Subtotal - Subconsultants
0.00
Total - DESIGN AND FINAL PLANS AND SPECIFICATIONS
$260,150.00
G:\PROJECTS\2004\04056\PROFESSIONAL SERVICES AGREEMENT.doc
Page 16
EXHIBIT "C"
SCHEDULE OF RATES
FOR
HUIBREGTSE, LOUMAN ASSOCIATES, INC.
(January 1, 2007, Through December 31, 2007)
Licensed Principal Engineer $136.00 per hour
Licensed Principal Land Surveyor $126.00 per hour
Licensed Professional Engineer $113.00 per hour
Licensed Professional Land Surveyor $104.00 per hour
Project Engineer $94.00 per hour
CAD Technician $82.00 per hour
Resident Engineer/Inspector $78.00 per hour
Surveyor $78.00 per hour
Senior Engineering Technician 78.00 per hour
Engineering Technician $55.00 per hour
Word Processing Technician $55.00 per hour
Two Man Survey Party $150.00 per hour
Three Man Survey Party $195.00 per hour
Vehicle Mileage $0.34 per mile
Global Positioning Survey System Fee $75.00 per hour
G:\PROJECTS\2004\04056\PROFESSIONAL SERVICES AGREEMENT.doc
Page 17
EXHIBIT "C"
SCHEDULE OF RATES
FOR
HUIBREGTSE, LOUMAN ASSOCIATES, INC.
(January 1, 2008, Through December 31, 2008)
Licensed Principal Engineer $141.00 per hour
Licensed Principal Land Surveyor $131.00 per hour
Licensed Professional Engineer $117.00 per hour
Licensed Professional Land Surveyor $108.00 per hour
Project Engineer $97.00 per hour
CAD Technician $85.00 per hour
Resident Engineer/Inspector $81.00 per hour
Surveyor $81.00 per hour
Senior Engineering Technician $81.00 per hour
Engineering Technician $57.00 per hour
Word Processing Technician $57.00 per hour
Two Man Survey Party $155.00 per hour
Three Man Survey Party $202.00 per hour
Vehicle Mileage $0.35 per mile
Global Positioning Survey System Fee $77.00 per hour
G:\PROJECTS\2004\04056\PROFESSIONAL SERVICES AGREEMENT.doc
Page 18
EXHIBIT "C"
SCHEDULE OF RATES
FOR
HUIBREGTSE, LOUMAN ASSOCIATES, INC.
(January 1, 2009, Through December 31, 2009)
Licensed Principal Engineer $148.00 per hour
Licensed Principal Land Surveyor $136.00 per hour
Licensed Professional Engineer $123.00 per hour
Licensed Professional Land Surveyor $112.00 per hour
Project Engineer $101.00 per hour
CAD Technician $89.00 per hour
Resident Engineer/Inspector $84.00 per hour
Surveyor $84.00 per hour
Senior Engineering Technician $84.00 per hour
Engineering Technician $59.00 per hour
Word Processing Technician $59.00 per hour
Two Man Survey Party $161.00 per hour
Three Man Survey Party $210.00 per hour
Vehicle Mileage $0.40 per mile
Global Positioning Survey System Fee $78.00 per hour
G:\PROJECTS\2004\04056\PROFESSIONAL SERVICES AGREEMENT.doc
Page 19
EXHI aLr D
ti
Legend
Canal
River
NTS
Fourth Street System Pipes
All Other Pipes
Phase 3 Stages
Stage 1
Stage 2
Stage 3
System Rehabiliatation
Preliminary Phasing
Phase tif
.1.1.
Q
STAG c1
sti" ,4
3RD.
P. C* + * �r�#r
nilINT
..41.
i.yl...l". T I 1 ..,..
11: i -
!182641±
•
Match Line
Figure a,
Phase 3 Staging
General -308 Irrigation System
Preliminary Design
City of Yakima
1
ITEM TITLE:
BUSINESS OF THE CITY COUNCIL
YAKIMA, WASHINGTON
AGENDA STATE 1ENT
Item No. ' 1 O
For Meeting of March 20, 2007
Consideration of Resolution authorizing execution of a professional services
agreement with Huibregtse, Louman Associates, Inc. for Phase 3 of the Irrigation
System Replacement / Rebuilding Project
SUBMITTED BY: Dave Brown, Water/Irrigation Manager
Dave Zabel!, Assistant City Manager
CONTACT PERSON/TELEPHONE: Dave Brown / 575-6204,
SUMMARY EXPLANATION:
In July of 2003, Council chose to rebuild / refurbish the Irrigation Systems, with the General -308 System as
one of the highest priority projects, along with the necessary rate increases to fund the projects. In October
2003, Council approved a Revenue Bond Ordinance and the first revenue bond was obtained to finance the
rebuilding of the Irrigation Systems. In the winter of 2006-2007, Phase 2 of the rebuild / replacement was
completed. Phase 3 of this project is ready to begin.
Staff respectfully requests City Council to approve the attached resolution authorizing the City Manager to
execute all documents related to the design, contract administration and construction for Phase 3 of the
Irrigation System rebuild/refurbishment. Contracts will require design Engineers to develop a design,
produce construction documents and perform contract administration; contracts will also be for the
construction of the replacement / rebuilding of the Irrigation Systems. Financial support for this contract will
be from appropriations approved by Council in the 479 Irrigation CIP Fund, using proceeds from a revenue
bond and transfers from rates collected for the rebuilding / refurbishment of the Irrigation Systems. The first
contract will be with Huibregtse, Louman Associates for the design and contract administration for Phase
3/Stage 1 of the General -308 project.
Resolution _X_ Ordinance Contract X Other Specify)
Mall to: Mike Battle; Huibregtse, Louman Associates; 801 N. 39th Ave.; Yakima, WA 98902 _Phone: 509-966-7000
Funding Source 479 IrrTga on CIP FunandBond Proceeds
APPROVED FOR SUBMITTAL:
City Manager
STAFF RECOMMENDATION:
Approve resolution authorizing the City Manager to execute the accompanying contract for the General -308
Phase3/Stage 1 design and subsequent contracts for the production of construction documents and contact
administration by Huibregtse, Louman Associates, of Yakima, Washington; for the City Manager to execute
all other documents related to the design, contract administration and construction for Phase 3 of the
Irrigation System rebuild/refurbishment.
BOARD/COMMISSION RECOMMENDATION:
COUNCIL ACTION:
Resolution adopted. RESOLUTION NO. R-2007-33